MOBILE COUNTY PUBLIC NOTICES 10-18-2023 CLICK HERE

By Call News | October 18, 2023 |

ADVERTISEMENT FOR BIDS

The Evergreen Conecuh Capital Improvement Cooperative District (ECCICD) is requesting competitive sealed bids for an earthwork, grading, and drainage project described as Liberty Hill Drainage Improvements. Project consists of the construction of a stormwater detention facility, and generally consists of the excavation and grading of on-site materials.

Sealed bids will be received by the Evergreen Conecuh Capital Improvement

Cooperative District (ECCICD), 100 Depot Square, Evergreen, AL, until 9 A.M. on 8 November, 2023, and then publicly opened for furnishing all labor and materials, and performing all work required by Evergreen-Conecuh Development Cooperative and described as follows:

Project: Liberty Hill Drainage Improvements

Project No.: 017826000

150 calendar days are allowed for the construction of the project.

All bids must be on blank forms provided in the specifications and submitted in its entirety. A cashier’s check drawn Conecuh County, on an Alabama bank or a bidder’s bond, payable to the ECCICD for an amount not less than five percent (5%) of the amount bid, but in no event more than ten thousand dollars ($10,000.00), shall be filed with the bid, as a bid guaranty. The bidder’s bond shall be prepared on the form specified and issued by a surety company authorized to do business in the State of Alabama.

A performance bond in the form and terms approved by the ECCICD in an amount not less than the contract price will be required at the signing of the contract. A labor and materials bond in the form and terms approved by the ECCICD in an amount not less than the contract price, insuring payment for all labor and materials, shall also be required at the signing of the contract. In addition, the contractor must furnish to the

ECCICD at the time of the signing of the contract a certificate of insurance coverage as provided in the specifications. The right is reserved to reject any and/or all bids and to waive informalities and to furnish any item of material or work to change the amount of said contract.

Liquidated damages for non‑completion of the work within the time limit agreed upon will be assessed in accordance with the terms of the contract.

Specifications are on file and may be viewed in the ECCICD, 100 Depot Square, Evergreen, AL and in the office of Kimley- Horn and Associates, 11 North Water Street, Suite 9290, Mobile, Alabama. Specifications may be obtained by prime contractor bidders by depositing $100.00 with the Project Engineer for each set. This deposit shall be refunded in full upon return of the documents in reusable condition within ten (10) days after bid opening. The cost of and return of additional sets of specifications shall be in accord with Section 39-2-3(b), Code of Alabama (1975). No Specifications will be issued later than twenty‑four (24) hours prior to the time indicated above for receiving bids.

A pre-bid conference will be held on 1 November, 2023 at 2:00 PM Central Time, at the ECCICD at 100 Depot Square, Evergreen, AL. All prospective bidders should have a representative present at the pre-bid conference. No bids will be considered unless the bidder, whether resident or non‑resident of Alabama, is properly licensed and qualified to perform the work described herein in accordance with all applicable laws of the State of Alabama. This shall include evidence of holding a current certificate to engage in general contracting in the State of Alabama, issued by the State of Alabama Licensing Board for General Contractors, Montgomery, Alabama, as required by Section 34-8-2, Code of Alabama (1975). Any contractor that desires to bid as a prime contractor must have at least one of the following major classifications of license per Section 230-X-1-.27 of the State of Alabama Licensing Board for General Contractors Administrative Code:

1.c.) Highways and Streets

1.d) Municipal and Utility

1.e) Heavy and Railroad Construction

Out of state corporations shall furnish a certificate of authority to transact business in Alabama. Out of state limited liability companies shall provide proof of registration to transact business in this state.

Prior to the award of a competitively bid contract to a contractor having one or more employees in the State of Alabama, Alabama law requires that the contractor provide the County proof of enrollment in E-Verify (see www.uscis.gov/everify).

No bid shall be withdrawn for a period of thirty (30) days subsequent to the opening of bids without the consent of the ECCICD. A tabulation of the bids will be available for public viewing within two (2) weeks of the award of the bid by request.

Call News October 18, 25, and November 1, 2023

INVITATION TO BID

The Water Works Board of the City of Birmingham will be accepting bids covering the installation of water mains and appurtenances connected thereto and 119 water services along Fern Street; Rosewood Street; Alpine Street; Texas Avenue; Bankhead Court; Bush Street and Chestnut Street located in the City of Birmingham, Alabama. Plans and specifications may be obtained by contacting Douglass W. Stockham, IV via email at doug.stockham@bwwb.org or Janice Acoff at janice.acoff@bwwb.org. Please state the bid name in the subject field when sending plans and specifications request. A Mandatory Pre-Bid Conference will be held on Wednesday, November 1, 2023, at 10:00 a.m. local via conference call Number: 1-888-278-0296 / Access Code: 2875407. Bids will not be accepted from Contractors who do not attend the Pre-Bid Conference. Sealed Bids will be received by The Water Works Board of the City of Birmingham, System Development Department, 3600 First Avenue North, Birmingham, Alabama until 9:00 a.m. local time on Thursday, November 16, 2023. The Sealed Bids will be opened and read at 10:00 a.m. local time on Thursday, November 16, 2023, by System Development staff in the System Development Conference Room on the Second Floor of the Main Campus Building located at 3600 First Avenue, North in Birmingham, Alabama via conference call as stated above.

Call News October 18, 25, 2023

INVITATION TO BID

The Water Works Board of the City of Birmingham will be accepting bids covering the installation of water mains and appurtenances connected thereto and 119 water services along Walnut Avenue Southwest; Pine Avenue Southwest; Maple Avenue Southwest; Oak Avenue Southwest; 39th Street Southwest and 36th Street Southwest located in the City of Birmingham, Alabama. Plans and specifications may be obtained by contacting Douglass W. Stockham, IV via email at doug.stockham@bwwb.org or Janice Acoff at janice.acoff@bwwb.org. Please state the bid name in the subject field when sending plans and specifications request. A Mandatory Pre-Bid Conference will be held on Wednesday, November 1, 2023, at 10:30 a.m. local via conference call Number: 1-888-278-0296 / Access Code: 2875407. Bids will not be accepted from Contractors who do not attend the Pre-Bid Conference. Sealed Bids will be received by The Water Works Board of the City of Birmingham, System Development Department, 3600 First Avenue North, Birmingham, Alabama until 9:00 a.m. local time on Thursday, November 16, 2023. The Sealed Bids will be opened and read at 10:15 a.m. local time on Thursday, November 16, 2023, by System Development staff in the System Development Conference Room on the Second Floor of the Main Campus Building located at 3600 First Avenue, North in Birmingham, Alabama via conference call as stated above.

Call News October 18, 25, 2023

LEGAL NOTICE – INVITATION TO BID

A MANDATORY pre-bid conference is REQUIRED

for ALL Prospective bidders. Pre-bid conference

will be held Thursday, November 2, 2023 at approximately 9:00 A.M.

Dodge Elementary School

2615 Longleaf Drive

Mobile, AL 36693

BID ON: DODGE ELEMENTARY SCHOOL

PLAYGROUND EQUIPMENT AND INSTALLATION

BSC #23-23

BID OPENING DATE: Thursday, November 16, 2023 @ 2:00 P.M.

Call News October 18, 25 and November 1, 2023

Notice to Contractors Federal Aid

Project No. NH-HSIP-0013(621)

MOBILE COUNTY, ALABAMA

Sealed bids will be received by the Director of Transportation at the office of the Alabama Department of Transportation, Montgomery, Alabama until 10:00 AM on November 03, 2023 and at that time publicly opened for constructing the Planing, Resurfacing, Guardrail Upgrades (Steel Blockout Replacement), Traffic Signal Upgrades (Signal Backplates), and Traffic Stripe on SR-13 (US-43) from the junction of SR-158 in Saraland to the intersection of Plateau Avenue in Satsuma. Length 4.377 mi.

The total amount of uncompleted work under contract to a contractor must not exceed the amount of his or her qualification certificate.

The Entire Project Shall Be Completed By December 31, 2024. A 2.00% DBE Contract Obligation Is Required.

A Bidding Proposal may be purchased for $5.00. Plans may be purchased for $15.00 per set. Plans and Proposals are available at the Alabama Department of Transportation, 1409 Coliseum Boulevard, Room E-108, Montgomery, AL 36110. Checks should be made payable to the Alabama Department of Transportation. Plans and Proposals will be mailed only upon receipt of remittance. No refunds will be made.

Minimum wage rates for this project have been pre-determined by the Secretary of Labor and are set forth in the advertised specifications. This project is subject to the contract work hours and Safety Standards Act and its implementing regulations.

Cashier’s check or bid bond for 5% of bid (maximum – $50,000.00) made payable to the Alabama Department of Transportation must accompany each bid as evidence of good faith.

The bracket range is shown only to provide general financial information to contractors and bonding companies concerning the project’s complexity and size. This Bracket should not be used in preparing a bid, nor will this bracket have any bearing on the decision to award this contract.

The Bracket Estimate On This Project Is From $3,475,925 To $4,248,353 .

The proposed work shall be performed in conformity with the rules and regulations for carrying out the Federal Highway Act.

Plans and Specifications are on file in Room E-108 of the Alabama Department of Transportation at Montgomery, Alabama 36110.

In accordance with the rules and regulations of The Alabama Department of Transportation, proposals will be issued only to prequalified contractors or their authorized representatives, upon requests that are received before 10 AM., on the day previous to the day of opening of bids.

The bidder’s proposal must be submitted on the complete original proposal furnished him or her by the Alabama Department of Transportation.

The Alabama Department of Transportation, in accordance with Title VI of the Civil Rights Act of 1964, 78 Stat. 252, 42

U.S.C. 2000D TO 2000D-4 and Title 49 code of Federal Regulations, Department of Transportation, Subtitle A, Office of The Secretary, Part 21, nondiscrimination in federally-assisted programs of the Department of Transportation issued pursuant to such act, hereby notifies all bidders that it will affirmatively insure that in any contract entered into pursuant to this advertisement, minority business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, religion, sex, or national origin in consideration for an award.

The right to reject any or all bids is reserved.

JOHN R. COOPER

Transportation Director

Call News October 18, 25 & November 1, 2023

Notice to Contractors

State Project No.

ATRP2-49-2022-346

MOBILE COUNTY, ALABAMA

Sealed bids will be received by the Director of Transportation at the office of the Alabama Department of Transportation, Montgomery, Alabama until 10:00 AM on November 03, 2023 and at that time publicly opened for constructing the Intersection Improvements (Traffic Signal Upgrades) on SR-16 (US-90), SR-42 (US-98), and on SR-17 (US-45) at various locations in the Southwest Region (Mobile Area) as indicated in the plans.

The total amount of uncompleted work under contract to a contractor must not exceed the amount of his or her qualification certificate.

The Entire Project Shall Be Completed In One Hundred Eighty (180) Working Days.

A Bidding Proposal may be purchased for $5.00. Plans may be purchased for $21.00 per set. Plans and Proposals are available at the Alabama Department of Transportation, 1409 Coliseum Boulevard, Room E-108, Montgomery, AL 36110. Checks should be made payable to the Alabama Department of Transportation. Plans and Proposals will be mailed only upon receipt of remittance. No refunds will be made.

Cashier’s check or bid bond for 5% of bid (maximum – $50,000.00) made payable to the Alabama Department of Transportation must accompany each bid as evidence of good faith.

The Bracket Estimate On This Project Is From $1,731,362 To $2,116,109 .

Plans and Specifications are on file in Room E-108 of the Alabama Department of Transportation at Montgomery, Alabama 36110.

The bidder’s proposal must be submitted on the complete original proposal furnished him or her by the Alabama Department of Transportation.

Section 34-8-8. Code of Alabama 1975 as amended states in part as follows: ‘… it will be necessary for him or her to show evidence of license before his or her bid is considered,’ Further, Section 34-8-8, Code of Alabama 1975 as amended also states in part as follows: ‘All Owners, Architects, and engineers receiving bids pursuant to this chapter shall require the person, firm, or corporation to include his or her current license number on the bid.’

The right to reject any or all bids is reserved.

JOHN R. COOPER

Transportation Director

Call News October 18, 25 & November 1, 2023

ADVERTISEMENT FOR BIDS

Sealed proposals will be received by Board of School Commissioners of Mobile County at the office of Facilities Department, Bldg. F, 1 Magnum Pass, Mobile, AL 36618 until 1:00pm CST, Tuesday, November 7, 2023 for the Alma Bryant High School New Tennis Courts for the Mobile County Public School System, at which time and place they will be publicly opened and read.

A mandatory pre-bid conference will be held Tuesday, October 31, 2023 at 2:00 pm CST at MCPSS Alma Bryant High School job site.

A cashier’s check or bid bond payable to Board of School Commissioners of Mobile County in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder’s proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract.

Drawings and specifications may be examined at the office of Clark Geer Latham & Associates, Inc., 3901 Springhill Ave. Mobile, AL 36608, (251)344-7073 and F.W. Dodge Plan Rooms.

Bid Documents may be obtained from the Architect upon deposit of $75.00 per hard copy set, which will be refunded in full on the first (2) sets issued to each general contract bidder submitting a bonafide bid, upon return of documents in good condition within ten days of bid opening. There shall be no charge for electronic plans.

Bids must be submitted on proposal forms furnished by the Board of School Commissioners of Mobile County or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner’s judgement, the best interests of the Owner will thereby be promoted.

Board of School Commissioners of Mobile County- Louis Anderson, Mobile County Public School System, Facilities- Clark Geer Latham & Associates, Inc.

Call News October 18, 25 and November 1, 2023

ADVERTISEMENT FOR PREQUALIFICATION OF CONTRACTORS

AND FOR BIDS FROM BIDDERS WHO ARE PREQUALIFIED

Prequalification Proposals (Letters of Interest (LOI) and Statements of Qualifications (SOQ)) from General Contractors (Construction Service Firms) shall be submitted and will be received by the Board of Water and Sewer Commissioners of the City of Mobile, Alabama (“Board”), at the Wesley A. James Operations Center, 4725 Moffett Road, Suite A, Mobile, AL 36618-0249; UNTIL 2:00 PM, LOCAL TIME, October 31, 2023, for the following project: CWSRF Contract No. CS010281-19, ESLAVA CREEK FORCE MAIN REPLACEMENT SLIPLINING OF EXISTING 48 INCH FORCE MAIN – PHASE 3(S): BAKER STREET TO WILLIAMS WASTEWATER TREATMENT FACILITY, PHASE 2(S): AMPAC FACILITY TO BROAD STREET, PHASE 1(S): I-10 CROSSING, McCrory & Williams, Inc Project No. M5712-2650 for consideration of approval to bid this project. Prequalified Bidders will be notified in writing on or about November 2, 2023, at which time Bid and Construction Documents will be made available to bidders.

Instructions for SOQ packages may be inspected at the Board’s offices at 4725 Moffett Road, Suite A, Mobile, AL, or requested at the offices of McCrory & Williams, Inc, 3207 International Drive, Suite G, Mobile, Alabama 36606.

As one of the conditions of submitting a SOQ, it must be understood that knowledge and experience is extremely important. Therefore, the construction firm will have to submit evidence and proof acceptable to the Board of their ability, knowledge, experience, training of supervisory personnel and labor, and will be required to submit evidence and proof that construction firm has performed work of a similar nature within the last twenty-four (24) months and that such work was satisfactorily and safely completed.

Qualifications of any sub-contractor(s) used to obtain prequalification status are to be included in the firm’s statement of qualifications. Contractors should pay special attention to the Board’s Supplier Diversity Program requirements to ensure prequalification packages include the required documentation as to participation of diverse sub-contractor(s) and suppliers to meet the Board’s goals of the Contractor’s good faith efforts to secure such participation.

The Owner reserves the right to reject any or all proposals, to waive technical errors, and/or abandon this process if, in their judgment, the best interests of the Owner will thereby be promoted.

All General contractors seeking prequalification status are required to submit the prequalification documents enclosed and clearly marked on the outside of the package as follows: “CONFIDENTIAL – STATEMENT OF QUALIFICATIONS – ESLAVA CREEK FORCE MAIN REPLACEMENT SLIPLINING OF EXISTING 48 INCH FORCE MAIN – PHASE 3(S): BAKER STREET TO WILLIAMS WASTEWATER TREATMENT FACILITY, PHASE 2(S): AMPAC FACILITY TO BROAD STREET, PHASE 1(S): I-10 CROSSING” Board of Water and Sewer Commissioners of the City of Mobile, Alabama ATTN: Douglas L. Cote, PE, Assistant Director of Operations, 4725 Moffett Road, Suite A, Mobile, AL 36618-0249.

Sealed bid proposals will be received only from Prequalified General Contractor Bidders by the Board of Water and Sewer Commissioners of the City of Mobile, Alabama (“Board”), at Wesley A. James Operations Center, 4725 Moffett Road, Suite A, Mobile, AL 36618-0249; UNTIL 12:00 PM LOCAL TIME; ON MONDAY, December 4, 2023, and then publicly opened and read at 1:00 p.m.

The Work of the project includes, but is not limited to the following:

Sliplining of approximately 10,000 LF of 36” HDPE sanitary sewer forcemain pipe into existing 48” PCCP pipe and approximately 400 LF of 32” HDPE into existing 36” PCCP pipe.

Numerous connections utilizing ductile iron fitting and PVC pipe will be required as the existing PCCP pipe contains bends and interconnections.

Copies of the Bidding Documents may be obtained from the Consulting Engineer, upon payment of $200.00 for each (printed) set. Said cost represents the cost of printing, reproduction, handling, and distribution, therefore no refund will be granted. Checks shall be made payable to “McCrory & Williams, Inc.” Bid documents will be mailed only upon receipt of deposit. No Contract Documents will be issued later than twenty-four (24) hours prior to bid submission time.

Refer to MAWSS Policy No. DBE 16-01 Disadvantaged Business Enterprise Policy for Public Works Act Contracts, which states that contractors shall make a demonstrated good faith effort to award fifteen percent (15%) of the contract amount to certified Disadvantaged Business Enterprises as subcontractors and/or suppliers performing commercially useful functions which are consistent with contract requirements. Further information for requirements during the bidding and contract performance phases are provided in Policy No. DBE 16-01 and should be considered by prospective bidders. Also, bidders must list all DBE subcontractors and suppliers on the provided Subcontracting Plan form to be submitted with the package.

A Mandatory Pre-Bid Conference will be held at the MAWSS Main Training Room at the Park Forest Facility, 4725A Moffett Road, Mobile, AL 36618 on November 8, 2023 at 10:00 A.M. Local Time, to discuss bidding and project requirements. Prospective prequalified bidders and subcontractors are required to attend.

Bids must be submitted on the standard forms included with the Contract Documents. The following contract bid documents, Bid Proposal, Bid Bond, Subcontracting Plan, SSO and Unpermitted Discharge Prevention Notification, and any addendum attachments shall be printed on yellow color paper and tabbed. The Contractor shall be responsible for preparing its bid package in accordance with this guideline.

The Owner’s intent is to use funding through the Clean Water State Revolving Loan for this project. Additional requirements beyond those of the Board of Water and Sewer Commissioners of the City of Mobile, Alabama and the State of Alabama bid law are included in this project and are outlined in Supplemental General Conditions for SRF Assisted Wastewater Facilities Construction Contracts of the project specifications.

Envelopes containing bids must be sealed and delivered to the Director, Board of Water and Sewer Commissioners of the City of Mobile, Alabama, Wesley A. James Operations Center, 4725 Moffett Road, Suite A, Mobile, AL 36618-0249: “Bid for Constructing CWSRF Contract No. CS010281-19, ESLAVA CREEK FORCE MAIN REPLACEMENT SLIPLINING OF EXISTING 48 INCH FORCE MAIN – PHASE 3(S): BAKER STREET TO WILLIAMS WASTEWATER TREATMENT FACILITY, PHASE 2(S): AMPAC FACILITY TO BROAD STREET, PHASE 1(S): I-10 CROSSING McCrory & Williams, Inc Project No. M5712-2650, to be opened at 1:00 p.m., Local Time, December 4, 2023 ”. The Bidder’s Alabama State Contractor’s License Number and discipline shall be on the envelope.

Bid guarantee in the form of certified check, bid bond, or Irrevocable Letter of Credit acceptable to the Board will be required for at least 5% of the bid amount, not to exceed $10,000.

The Board reserves the right to reject any and all bids and to waive any informality in bids received.

THIS INVITATION FOR PREQUALIFICATION OF CONTRACTORS AND FOR BIDS FROM BIDDERS WHO

ARE PREQUALIFIED IS CONDENSED FOR ADVERTISING PURPOSES. ADDITIONAL

INFORMATION/REQUIREMENTS FOR BIDDERS CAN BE FOUND IN THE CONTRACT DOCUMENTS.

THE BOARD OF WATER AND SEWER

COMMISSIONERS OF THE CITY OF

MOBILE, ALABAMA

Call News October 18, 2023

INVITATION FOR BIDS

Sealed bids will be received by the Board of Water and Sewer Commissioners of the City of Mobile, Alabama (“Board”), at the Wesley A. James Operations Center, 4725 Moffett Road, Suite A, Mobile, AL 36618-0249 until 12:00 p.m., Local Time, November 13, 2023, and then publicly opened and read at 1:00 p.m. for furnishing all labor, materials, and performing all work for the following project: Contract No: M5712-2767, Project Name: 2024 Annual Contract for Waterline Loops.

Plans and Specifications may be inspected at the Board’s offices at 4725 Moffett Road, Suite A, Mobile, AL, or at the office of McCrory & Williams, Inc. Consulting Engineers, 3207 International Drive, Suite G, Mobile, AL. Electronic Plans and Specifications may be obtained via e-mail for review only from McCrory & Williams, Inc, Telephone: (251)476-4720.

Copies of the Plans, Specifications, and other Contract Documents may be obtained from McCrory & Williams, Inc at 3207 International Drive, Suite G upon a non-refundable payment of $75.00 per set. No Contract Documents will be issued later than twenty-four (24) hours prior to bid submission time.

A mandatory Pre-bid Conference will be held at 4725 Moffett Road, Mobile, AL 36618 on October 31, 2023 at 8:00 a.m., Local Time, to discuss bidding and project requirements. Prospective bidders and subcontractors should attend.

Bids must be submitted on the standard forms included with the Contract Documents.

Envelopes containing bids must be sealed and delivered to the Director, Board of Water and Sewer Commissioners of the City of Mobile, Alabama, 4725A Moffett Road, Mobile, Alabama 36618-0249: “Bid for constructing (Contract No.) M5712-2767 (Project Name) 2024 Annual Contract for Waterline Loops to be opened at 1:00 p.m., Local Time, November 13, 2023”. The Bidder’s Alabama State Contractor’s License Number and discipline shall be on the envelope.

Bid guarantee in the form of certified check, bid bond, or irrevocable Letter of Credit acceptable to the Board will be required for at least 5% of the bid amount, not to exceed $10,000.

The Board reserves the right to reject any and all bids and to waive any informality in bids received.

THIS INVITATION FOR BIDS IS CONDENSED FOR ADVERTISING PURPOSES. ADDITIONAL INFORMATION/REQUIREMENTS FOR BIDDERS CAN BE FOUND IN THE CONTRACT DOCUMENTS.

THE BOARD OF WATER AND SEWER COMMISSIONERS

OF THE CITY OF MOBILE, ALABAMA

Call News October 18, 2023

MOWA Choctaw Housing Authority

Refurbishment of Press Box and Dugouts

Invitation Bid Meeting

RFQ-10-05-2023

NOTICE IS HEREBY GIVEN that the MOWA Choctaw Housing Authority (MCHA) is soliciting for sealed bids for Project: RFQ-10-05-2023-001.

This project includes refurbishment of press box and dugouts in Mt. Vernon, AL. The Contractor shall furnish all labor, tools, equipment, and incidentals thereto required for completion of the project. The contractor will furnish all material for the project. A mandatory Pre-Bid meeting will be held at the MOWA Choctaw Housing Authority, 1080 A Red Fox Road, Mt. Vernon, AL 36560 on October 23, at 10:00 AM (CT). Bids are due on October 30, 2023, at the MOWA Choctaw Housing Authority by 12:00 PM (CT) at 1080 A Red Fox Road, Mt. Vernon, AL 36560, Bids will be opened and publicly read aloud at the MCHA Conference Room on October 30, 2023 @ 12:00pm. MCHA reserves the right to reject any or all the bids. The awarding of bids will be pending approval of the MOWA Choctaw Housing Authority.

This invitation for Bid is open to selected General Contractors; however, the award shall be made under unrestricted solicitation to the lowest/responsive/responsible bidder using the “X” Factor tabulation (Indian Preference). The Project will be awarded to one Prime Contractor.

All bids must be sealed and addressed to the MOWA Choctaw Housing Authority and plainly marked with the Bidder’s name and the Project name. Bids shall be on a Lump Sum basis per the Project documents; segregated bids will not be accepted. Bid documents and specfications are made a part of this Invitation for Bid.

For additional information contact Lillie Steiner at lilliesteiner@mowachoctaw.com or Darren Snow at 251-431-5151.

MOWA Choctaw Housing Authority 1080 A Red Fox Road, Mt. Vernon, AL 36560 251-829-5000

Call News October 11, 18, 2023

BID 23-05-36

The Birmingham Water Works will be accepting sealed bids for Main Campus Lawn Maintenance on BID23-05-36, until Monday, October 23, 2023, @ 10:00 a.m. Bid opening will be held via Teams meeting. An invite and bid specifications can be obtained and examined in the office of the Purchasing Manager, Matthew Shiver, at 3600 First Avenue North, Birmingham, AL 35222, or by calling @205-244-4302, emailing at Matthew.shiver@bwwb.org or on our website at bwwb.org. You can mail your sealed bid to 3600 First Avenue North, Birmingham, AL 35222 to the attention of the Purchasing Manager and marked in the lower left-hand corner of the envelope as follows: Main Campus Lawn Maintenance on BID23-05-36.

Call News October 11, 18, 2023

ADVERTISEMENT FOR BIDS

Sealed proposals will be received from qualified General Contractors at the offices of:

The Mobile County Public School System’s Facilities Conference Room, 1 Magnum Pass Building F, Mobile, Alabama 36618

until 2:00 PM local prevailing time, NOVEMBER 7, 2023, and thereafter opened publicly for construction for the following projects (separate bid for each project):

Booth Elementary School Controls Upgrade for Mobile County Public School System, Irvington, Alabama (Architect’s Project No.: 2219SC / FPN No.: 22-08)

The work includes Controls Upgrades for approximately 67,600 sf of existing area, with all trades incorporated in the General Contract.

Gilliard Elementary School Controls Upgrade for Mobile County Public School System, Mobile, Alabama (Architect’s Project No.: 2220SC / FPN No.: 22-10)

The work includes Controls Upgrades for approximately 88,300 sf of existing area, with all trades incorporated in the General Contract.

Will Elementary School Controls Upgrade for Mobile County Public School System, Mobile, Alabama (Architect’s Project No.: 2221SC / FPN No.: 22-11)

The work includes Controls Upgrades for approximately 93,400 sf of existing area, with all trades incorporated in the General Contract.

Obtaining Bid Documents: Electronic images of bid documents may be viewed on-line at no cost through Alabama Graphics web site (www.algraphicsplanroom.com) and hard copies at the office of the Architect. Questions pertaining to accessing the web site should be directed to Bryant Haynie 334/263-0529. Access jobs under “PUBLIC JOBS” for the above-named project. Bidders may obtain Bid Documents as directed below. Bid Documents may only be obtained from:

Alabama Graphics

350 E. Fred D. Gray Ave

Montgomery, Alabama 36104

Bid Documents: Bid Documents either paper copies OR full sets of electronic copies (pdf format) may be purchased through the Alabama Graphics DPR web site upon payment to Alabama Graphics. The cost will be $60.00 per set for each project. This is the full cost of printing, handling, and distribution.

Official interpretations will be based on complete, full-size sets. Bid documents may be used only for the purpose of bidding and constructing this project. Documents may not be copied in whole or in part by electronic or other means. Anyone placing an order for plans and specifications will be notified of all addenda by e-mail. The architect retains all copyrights and ownership of the documents.

Award will be made only to competent and responsible bidders as mandated by Title 39 of the Code of Alabama respondents who have the experience and other qualifications as set forth in the bid documents. Pre-bid qualification is not required. All bidders must be licensed under Title 34 of the Code of Alabama and evidence thereof must appear on the proposal envelope (outside in clear view) or it will not be opened.

A MANDATORY Pre-bid conference for all three projects will be held at 10:00 AM, local time on OCTOBER 31, 2023, at: The Mobile County Public School System’s Facilities Conference Room, 1 Magnum Pass Building F, Mobile, Alabama 36618 for the purpose of reviewing the projects and answering Bidder’s questions.

These projects qualify for the Sales Tax Saving Program and the Owner intends to implement this program.

Bidders must comply with Alabama House Bill 289 (Act 2009-657) in reference to Fire Alarm Systems.

Pursuant to State Law a cashier’s check or bid bond payable to the Owner in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000.00, must be enclosed with the bid to secure the bid for at least 30 days. Conditional bids will be rejected. A list of major subcontractors must be submitted as indicated in the Supplemental Instructions to Bidders. Performance and Payment Bonds and evidence of specified insurance are pre-requisites of contract award. Right is reserved by the Awarding Authority to reject all bids and to waive irregularities.

The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner’s judgment, the best interests of the Owner will thereby be promoted.

BY: Chresal D. Threadgill

Title: Superintendent of Schools

Mobile Public School System

By; PH&J ARCHITECTS, INC.

807 S. McDonough St.(36104) P.O. Box 215 (36101)

Montgomery, Alabama

Telephone (334) 265-8781

Email: phj@phjarch.com

Call News October 11, 18, 25, 2023

ADVERTISEMENT FOR BIDS

Semmes Fire Station No. 3 Project Address: Schillinger Rd. Semmes, AL 36575

The Architect for this project is: Adams Stewart Architects, 22615 AL-59, PO Box 529, Robertsdale, AL 36567

Phone: 251-947-3864

Email: tstweart@adamsstewart.com

Sealed proposals will be received for the Semmes Fire Station project at Semmes City Hall-One Main Street Semmes, AL 36575 until 2:00 PM CST on October 24, 2023 at which time and place they will be publicly opened and read. A Pre-Bid Conference will be held on October 17, 2023 at 10:00am CST at the Semmes City Hall. A bid bond or cashier’s check made payable to the City of Semmes in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder’s proposal. Performance and Payment Bonds and evidence of insurance mentioned in the bid documents will be required at the signing of the contract. Bid Documents may be obtained from the Architect upon deposit of $300.00, which will be refunded in full on the first set issued to each general contract bidder submitting a bonafide bid, upon return of documents in good condition within ten days of bid date. Bids must be submitted on proposal forms furnished by the Architect or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect. The bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner’s judgment, the best interests of the Owner will thereby be promoted. GENERAL PROJECT DESCRIPTION: Construction of a new 7,172 sq. ft. fire station. This work includes but is not limited to; site work, pre-engineered truss building, concrete foundation and sidewalks, mechanical and electrical services. Owner’s Representative: City of Semmes

Brandon Van Hook, Mayor

One Main Street

Semmes, AL 36575

Call News October 4, 11, 18, 2023

ADVERTISEMENT FOR BIDS

Sealed proposals will be received by Goodwyn Mills Cawood, LLC, 11 N. Water St., Suite 15250, Mobile, Alabama, 36602; at 2:00 PM LOCAL TIME ON THURSDAY, NOVEMBER 1, 2023, at which time and place they will be publicly opened and read, for:

RSA Multi-Properties Package – MP6

Mobile, Alabama

for

The Retirement Systems of Alabama

The Work of the project includes, but is not limited to, the General Works, Glass & Glazing, Flooring and Wall Tile, Drywall, Painting, Mechanical, Electrical and Fire Protection, and all related work (refer to Scope of Work). Coordination and supervision of the entire project; and all related work, as indicated in the Bid and Contract Documents.

All bid envelopes should contain the bidder’s name and mailing address, the name of the bid item, and Certificate of Responsibility Number on the face of the sealed envelope.

A cashier’s check or bid bond payable to Retirement Systems of Alabama in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder’s proposal. Performance and statutory Labor and Material Payment Bonds, insurance in compliance with requirements, and verification of E-Verify enrollment (also with Proposals), will be required at the signing of the Contract.

The Issuing Office for the Bidding Documents is Goodwyn Mills Cawood, LLC, 11 North Water Street, Suite 15250, Mobile, AL 36602, Attn: Doris Furr (251) 338-6840 doris.furr@gmcnetwork.com. Prospective Bidders may examine the Bidding Documents at the Issuing Office on Mondays through Fridays between the hours of 8:00 a.m. – 5:00 p.m. and may obtain copies of the Bidding Documents from the Issuing Office as described below.

General Contractors may procure plans and specifications from the Architect upon payment of a deposit of Twenty dollars ($20.00) for a one-time administrative fee for digital/file sharing access or One Hundred Fifty dollars ($150.00) (printed) per set. Contractors are encouraged to use the digital plans. Refunds will be issued for printed sets only issued by the Architect to each general contract bidder on the first two (2) sets issued submitting a bonafide bid, upon return of documents in good and reusable condition within ten (10) days of bid date. Additional sets for General Contractors, and sets for subs and vendors, may be obtained with the same deposit, which will be refunded as above, less cost of printing, reproduction, handling and distribution, which is estimated to be the same as the deposit amount.

Checks shall be made payable to “Goodwyn Mills Cawood, LLC.” Bid documents will be mailed only upon receipt of deposit. No bid documents will be distributed later than 24 hours prior to the scheduled opening of bids. Partial sets of Bidding Documents will not be available from the Issuing Office. Neither Owner nor Architect will be responsible for full or partial sets of Bidding Documents, including Addenda if any, obtained from sources other than the Issuing Office.

Bid Documents may be obtained from the Architect, by digital access/file sharing access by emailing your request to Doris Furr at doris.furr@gmcnetwork.com. Bid Documents will be available on or about OCTOBER 4, 2023.

For the list of plan holders on this project visit http://www.gmcnetwork.com/bids/.

The OWNER reserves the right to waive any informality or to reject any and all bids.

Bids must be submitted on proposal forms furnished by the Architect or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the Provision of Title 34, Chapter 8, Code of Alabama, 1975, as amended, and must show such evidence of license before bidding or bid will not be received or considered by Architect or Owner; The bidder shall show such evidence by clearly displaying their current license number on the outside of the sealed envelope in which the proposal is delivered; Bidder must also include their current license number on the Proposal Form. No bid may be withdrawn after the scheduled closing time for receipt of bids for a period of SIXTY (60) days.

A PRE-BID CONFERENCE will be held at the GMC Office, 11 N. Water St., Suite 15250, at 10:00 AM local time on WEDNESDAY, OCTOBER 18, 2023, for the purpose of reviewing the project, answering Bidder’s questions and touring the work areas. Attendance at the Pre-Bid Conference is recommended for all Bidders intending to submit a Proposal, and for Subcontractors.

This project is being bid EXCLUDING TAXES, and requires the Contractor comply with the requirements of Act 2013-205, which was signed into law on May 9, 2013. The Contractor and the Owner will be required to apply for Certificates of Exemption with the Alabama Department of Revenue which will handle administration of the Certificates. The Contractor shall account for the tax savings on the Proposal Form.

Additional qualifications and requirements for General Contractor Bidders and separate Subcontractors are indicated in the Bid and Contract Documents.

The Owner reserves the right to reject any or all proposals and to waive technical errors if, in their judgment, the best interests of the Owner will thereby be promoted.

Retirement Systems of Alabama

Montgomery, Alabama

GOODWYN MILLS CAWOOD LLC

MEMBERS, AMERICAN INSTITUTE OF ARCHITECTS

11 N. Water St. Suite 15250

Mobile, AL 36602

Phone: (251) 460-4006

Fax: (251) 460-4423

Call News, October 4, 11 and 18, 2023

INVITATION FOR BIDS

Sealed bids will be received by the Board of Water and Sewer Commissioners of the City of Mobile, Alabama (“Board”), at the Wesley A. James Operations Center, 4725 Moffett Road, Suite A, Mobile, AL 36618-0249 until 12:00 p.m., Local Time, November 13, 2023, and then publicly opened and read at 1:00 p.m. for furnishing all labor, materials, and performing all work for the following project: Contract No: M5712-2783, Project Name: 2024 Annual Contract for Cleaning & Video Inspection of Various Sanitary Sewer Segments.

Plans and Specifications may be inspected at the Board’s offices at 4725 Moffett Road, Suite A, Mobile, AL, or at the office of McCrory & Williams, Inc, Consulting Engineers, 3207 International Drive, Suite G, Mobile, AL. Electronic Plans and Specifications may be obtained via e-mail for review only from McCrory & Williams, Inc, Telephone: (251)476-4720.

Copies of the Plans, Specifications, and other Contract Documents may be obtained from McCrory & Williams, Inc at 3207 International Drive, Suite G, upon a non-refundable payment of $75.00 per set. No Contract Documents will be issued later than twenty-four (24) hours prior to bid submission time.

A Pre-bid Conference will be held at MAWSS, 4725 Moffett Road, Mobile, AL 36618 on October 31, 2023 at 10:00 A.M. Local Time, to discuss bidding and project requirements. Prospective bidders and subcontractors should attend.

Bids must be submitted on the standard forms included with the Contract Documents.

Envelopes containing bids must be sealed and delivered to the Director, Board of Water and Sewer Commissioners of the City of Mobile, Alabama, 4725A Moffett Road, Mobile, Alabama 36618-0249: “Bid for constructing (Contract No.) M5712-2783 (Project Name) 2024 Annual Contract for Cleaning & Video Inspection of Various Sanitary Sewer Segments to be opened at 9:00 a.m., Local Time, November 13, 2023”. The Bidder’s Alabama State Contractor’s License Number and discipline shall be on the envelope.

Bid guarantee in the form of certified check, bid bond, or irrevocable Letter of Credit acceptable to the Board will be required for at least 5% of the bid amount, not to exceed $10,000.

The Board reserves the right to reject any and all bids and to waive any informality in bids received.

THIS INVITATION FOR BIDS IS CONDENSED FOR ADVERTISING PURPOSES. ADDITIONAL INFORMATION/REQUIREMENTS FOR BIDDERS CAN BE FOUND IN THE CONTRACT DOCUMENTS.

THE BOARD OF WATER AND SEWER COMMISSIONERS

OF THE CITY OF MOBILE, ALABAMA

Call News October 18, 2023

INVITATION FOR BIDS

Sealed bids will be received by the Board of Water and Sewer Commissioners of the City of Mobile, Alabama (“Board”), at the Wesley A. James Operations Center, 4725 Moffett Road, Suite A, Mobile, AL 36618-0249 until 12:00 p.m., Local Time, November 13, 2023, and then publicly opened and read at 1:00 p.m. for furnishing all labor, materials, and performing all work for the following project: Contract No: M5712-2780, Project Name: Access Roads Annual Contract 2024 Construction and Sewer Easement Maintenance.

A Pre-bid Conference will be held at MAWSS, 4725 Moffett Road, Mobile, AL 36618 on October 31, 2023 at 9:00 A.M. Local Time, to discuss bidding and project requirements. Prospective bidders and subcontractors should attend.

Bids must be submitted on the standard forms included with the Contract Documents.

Envelopes containing bids must be sealed and delivered to the Director, Board of Water and Sewer Commissioners of the City of Mobile, Alabama, 4725A Moffett Road, Mobile, Alabama 36618-0249: “Bid for constructing (Contract No.) M5712-2780 (Project Name) Access Roads Annual Contract 2024 Construction and Sewer Easement Maintenance to be opened at 1:00 p.m., Local Time, November 13, 2023”. The Bidder’s Alabama State Contractor’s License Number and discipline shall be on the envelope.

Bid guarantee in the form of certified check, bid bond, or irrevocable Letter of Credit acceptable to the Board will be required for at least 5% of the bid amount, not to exceed $10,000.

The Board reserves the right to reject any and all bids and to waive any informality in bids received.

THIS INVITATION FOR BIDS IS CONDENSED FOR ADVERTISING PURPOSES. ADDITIONAL INFORMATION/REQUIREMENTS FOR BIDDERS CAN BE FOUND IN THE CONTRACT DOCUMENTS.

THE BOARD OF WATER AND SEWER COMMISSIONERS

OF THE CITY OF MOBILE, ALABAMA

Call News October 18, 2023

NOTICE OF BID

To all Bidders: The Mobile County Health Department (MCHD) is currently soliciting sealed bids for the renovation of the second floor of the MCHD Southwest Clinic located at 5580 Inn Road Mobile, AL 36619. The sealed bid MCHD project # is 2024-01. This project will include but not limited to the wall removal, roof re-framing/bracing and re-construction of demolition space. Contractors will be responsible for removing and rebuilding interior and some exterior spaces based on the construction documents and plans provided by Bowden Architecture, 1657 Springhill Ave. Mobile, AL 36604 Office Telephone: (251) 433-0704, email: office@bowdenarchitecture.com. Contractors eligible to bid must not be on the U.S. General Services Administration list of Parties Excluded from Federal Procurement or Non-Procurement Programs. Bids will be submitted for furnishing all labor and materials and performing all work for this project. The Contract will be awarded to the Contractor with the lowest responsible bid for the completed construction for this project. Prospective bidders must attend and must sign the attendance log for one of the two scheduled Pre-Bid Meetings to be held at MCHD Southwest Clinic located at 5580 Inn Road Mobile, AL 36619. The first meeting will take place Thursday, October 19, 2023, at 10:30 A.M. and the second meeting will take place Thursday, October 26, 2023, at 10:30 A.M. Please note that attendance at one meeting is a mandatory requirement for bidding and all Bidders must sign the “attendance log’ to be posted at the meeting. A Bid Bond or certified check (drawn on an Alabama based bank) equal to five percent (5%) of the bid payable to the Mobile County Health Department must accompany each bid. A Performance Bond (drawn on an Alabama Surety Company) will be required as follows: 100% of the contract amount must be furnished within 15 days of the contract being presented to the bidder for signature and must be payable to Mobile County Health Department. A payment Bond will be required as follows: 50% of the contract amount plus a reasonable estimate of attorney’s fees, payable to Mobile County Health Department. No bid will be considered unless the bidder, whether resident or non-resident of Alabama, is properly qualified to submit a proposal for the construction. Contractors must have insurance coverage of no less than $1,000,000. Submit the Insurer’s Power of Attorney for the representing Agent. The requirements shall include, among other qualifications, evidence of holding a current Contractor’s license from the Alabama Licensing Board for General Contractors, Montgomery, Alabama. All required documentation must be attached to the bid and enclosed within the sealed envelope to be presented prior to bid opening. The contractor must initiate the project within 10 days of the bid award. No adjustments to the contract time will be made for a delayed start. Liquidated damages will apply for failure to complete the project on time. No bid may be withdrawn for a period of sixty (60) days following the bid opening unless approved by the Mobile County Health Department. Each bid must be submitted in a sealed envelope on the official bid form, along with the State of Alabama Disclosure Statement, W-9 form, Beason-Hammon Affidavit, Certification of Insurance, and other required information. Please visit www.mchd.org, “Forms and Resources,” “Legal Notices and Bids,” to view the complete legal bid requirements for this project. The front of the sealed envelope shall be clearly marked with Sealed Bid # 2024-01. Sealed bids will be received Thursday, November 9, 2023, at 2:00 P.M. at which time bids will be publicly opened and read. Please report to the main lobby at Mobile County Health Department Keeler Building located at 251 N. Bayou St. Mobile, AL 36603, from there security will direct everyone to Building # 2. Questions may be directed to: Bowden Architecture at (251) 433-0704 or email office@bowdenarchitecture.com. Mobile County Health Department point of contact, Christopher Thomas, Project Manager at (251) 690-8985, email CThomas@mchd.org. The Mobile County Health Department reserves the right to reject all bids and to waive any formalities in the bidding, and to be the final authority in any conflict. This project is being 100% funded by Federal Funds. The bidding and contracting process will follow the laws and regulations, whether defined in this notice or not, as defined by the State of Alabama in the Code of Alabama (1975), Title 39, Public Works Law.

Call News September 27 and October 4, 11, 18, 2023

Divorce

IN THE CIRCUIT COURT OF

MOBILE COUNTY, ALABAMA

DOMESTIC RELATIONS DIVISION

NOTICE OF DIVORCE ACTION

CASE NO. DR 2023-90113.00 WHH

LINDSEY MICHELLE SEITZ, Plaintiff

vs.

JOSEPH BERNARD SEITZ, Defendant

JOSEPH BERNARD SEITZ, (Defendant), whose whereabouts is unknown, must answer the plaintiff’s Petition for Divorce and other relief by December 11, 2023 or, thereafter, a Judgment by Default may be rendered against him/her in the above styled case. The Defendant’s written answer must be filed with the Court and a copy mailed to the Plaintiff’s attorney of record at the address provided below.

Done this 28th day of September, 2023.

Sharla Knox, Circuit Clerk

Attorney for plaintiff: Thomas F. Monk

1111 Easts I-65 Service Rd. S Suite 112

Mobile, AL 36606

monk@mobileattorney.net

Call News October 18, 25 and November 1, 8, 2023

IN THE CIRCUIT COURT OF

MOBILE COUNTY ALABAMA

DOMESTIC RELATIONS DIVISION

NOTICE OF DIVORCE ACTION

CASE NO. 02-DR-2023-900624.00S

Kizzy McKeller Williams, Plaintiff

Tyrone Williams, Defendant

Tyrone Williams (Defendant), whose whereabouts is unknown, must answer the Plaintiff’s Petition for Divorce and other relief by November 20, 2023 or, thereafter, a Judgment of default may be rendered against him/her in the above styled case. The defendant’s written answer must be filed with the court and a copy mailed to the plaintiff’s attorney of record at the address provided below.

Done this 13th September 2023.

s/Sharla Knox

SHARLA KNOX, CIRCUIT CLERK

ATTY: Ms. Kizzy M. Williams

6611 Cherokee Trail North

Theodore, AL 36582

TELEPHONE 251-623-8233

Pro-Se

Call News September 27, 2023, October 4, 2023, October 11, 2023, October 18, 2023

Complaint

LEGAL NOTICE

NOTICE TO DEFENDANT, SHELLEY NELSON, OF COMPLAINT ISSUED OUT OF THE CIRCUIT COURT OF

MOBILE COUNTY, AL

CASE NO. CV-2023-901431

NOTICE is hereby given in the above-entitled cause on the 14 day of July, 2023, D & D CONSTRUCTION, LLC, Plaintiff, filed in said Circuit Court, a cause of action against the above named Defendant to eject her from the property located at 4951 Fairview Hills, Wilmer, AL 36587 .

NOW THEREFORE, Defendant is hereby commanded to answer or plead on or before November 17, 2023, to the Complaint filed in the above entitled case of suffer the entry of a Default Judgment against her.

WITNESS my hand on this the 21st day of September, 2023.

ATTEST

/s Sharla Knox

CLERK OF THE CIRCUIT COURT OF

MOBILE COUNTY, AL

CLIFFORD C. (KIP) SHARPE

Attorney for Plaintiff

307 Morgan Ave.

Mobile, AL 36606

(251) 343-6700 (251) 423-1157

Call News SEPT. 27, OCT. 4, OCT. 11 & OCT. 18. 2023

NOTICE OF PUBLICATION

IN THE CIRCUIT COURT OF

MOBILE COUNTY, ALABAMA

HISTORIC MOBILE, LLC, Plaintiff

PARCEL OF REAL PROPERTY SITUATED IN MOBILE COUNTY, ALABAMA, HAVING PARCEL IDENTIFICATION OF Parcel No. R022906400003148.01, and legally described as: The East half of that property described as follows: Beginning 100.6 feet Southwardly of the Southwest corner of Congress and Dearborn Streets running Westwardly 110 feet, thence Southwardly 48.7 feet, thence nearly 50.3 feet to beginning of #Sec 40 T4S R1W #MP29 06 40 0 004 in the Office of the Judge of the Probate of Mobile County, Alabama,

AND

ETTA REE PENDLETON, NINA JACKSON ROBINSON, and LINDA JACKSON, Defendants.

CIVIL ACTION NO.:

CV-2023-901717

NOTICE OF PUBLICATION

The Defendants or any party having any right, lien, encumbrance of interest in the described land in the above-styled action, must answer Plaintiff’s Bill to Quiet Title by the 8th day of December, 2023 or, thereafter a judgment by default may be entered against them.

GIVEN under my hand this 12th day of October, 2023.

Sharla Knox, CIRCUIT CLERK, MOBILE COUNTY

Plaintiff’s Attorney:

Keri Coumanis

Helmsing, Leach, Herlong, Newman & Rouse, PC

P O Box 2767

Mobile, AL 36652

Phone: 251-432-5521

E-mail: ktm@helmsinglaw.com

Call News October 18, 25, November 1, 8, 2023

LIS PENDENS

IN THE CIRCUIT COURT OF

MOBILE COUNTY, ALABAMA

CV-2023-901942

STEVE A. JOHNSON, SR., Plaintiff

REAL PROPERTY COMMONLY KNOWN AS 4010 MICHIGAN, AVE., CODEN, AL 36523; DESEREE LYONS ROCCO and all other persons claiming any present, future contingent, remainder, reversion or other interest in said lands, Defendants.

LIS PENDENS NOTICE

I, Charles Lewis, Clerk of the Circuit Court of Mobile County, Alabama, do hereby certify that the above-styled action is now pending in the Circuit Court and that the Complaint in said action seeks to quiet title to the following described property in Mobile County, Alabama, to-wit:

Commencing at the Northwest intersection of Alabama Port – Caden Road (also known as Highway 188) and 13th Street; thence run North 556 feet, more or less, to a point; thence run Northeastwardly 80 feet, more or less, to the point of beginning; thence run Northwestwardly 558 feet, more or less, to a point; thence run East 950 feet, more or less, to a point; thence run Southwestwardly 746 feet, more or less, to a point; thence run West 13 feet, more or less, to a point; thence run North 50 feet, more or less, to the point of beginning; said property being located in Section 12, Township 8 South, Range 2 West, Mobile County, Alabama. Lots 1, 2 & 3 Bradford Park as recorded in Map Book 5, Page 605 in the records in the Office of the Judge of Probate of Mobile County, Alabama.

The address of the property is commonly known as: 4010 Michigan Ave.,

Coden, AL 36523

Anyone having any interest, lien, encumbrance or claim to these lands must file a

written Answer with the Clerk of the Circuit Court on or before November 17, 2023

and send a copy of the Answer to the attorney for the plaintiff, or suffer the entry of a

Default Judgment against them.

GIVEN under my hand and seal of the Court on this 21st day of September, 2023.

/s Sharla Knox

Mobile County Circuit Court Clerk

Plaintiff’s Attorney:

John R. Parker

182 St. Francis Street

Suite 101

Mobile, AL 36602

Phone: 251-621-2116

E-mail: john@jparkerlaw.net

Call News Sept. 27, Oct. 4, Oct. 11 & Oct. 18, 2023

CIVIL ACTION

ORDER OF NOTICE BY PUBLICATION

DOCKET NUMBER: 2377CV00359

Trial Court of Massachusetts, The Superior Court

CASE NAME: Bank of New York Mellon Trust Company, N.A. Trustee for Mortgage Assets Management Series I Trust

vs.

Aimee Sanford et al

RE: Kane, Steven James

WHEREAS a civil action has been begun against you in our Superior Court by Bank of New York Mellon Trust Company, N.A. Trustee for Mortgage Assets Management Series I Trust wherein it is seeking to; Bank of New York Mellon Trust Company, N.A., as Trustee for Mortgage Assets Management Series I Trust (hereinafter “BONY Mellon”), the foreclosing mortgagee is currently holding surplus funds that it wishes to pay into the Court so that the Court can determine who is entitled to the surplus funds. BONY Mellon further request that it be discharged from any further obligation involving this matter. We COMMAND YOU if you intend to make any defense, that on 11/16/2023 or within such further time as the law allows you do cause your written pleading to be filed in the office of the Clerk of Court named above, in said Commonwealth, and further that you defend against said suit according to law if you intend any defense, and that you do and receive what the Court shall order and adjudge therein. Hereof fail not, at your peril, or as otherwise said suit may be adjudged and orders entered in your absence. It appearing to this Court that no personal service of the Complaint has been made on the defendant a deputy sheriff having made a return on the summons that after diligent search he can find no one upon whom he can lawfully make service, a copy of which is hereto attached and made part of this notice, it is ORDERED that notice of this suit be given to them by publishing, once a week for three successive weeks, the last publication to be at least 20-days before said return day in the:

Newspaper: Citronelle Call News &Birmingham News

City/ Town: City of Lawrence

DATE ISSUED: 10/05/2023

Thomas H. Driscoll, Jr., Clerk of Courts, Essex County

CLERK OF COURTS/ ASST. CLERK

COURT NAME & ADDRESS: Essex County Superior Court – Lawrence, 43 Appleton Way Lawrence, MA 01841

Call News October 18, 25 and November 1, 2023

ORDER OF NOTICE BY PUBLICATION

DOCKET NUMBER: 2377CV00359

Trial Court of Massachusetts, The Superior Court

CASE NAME: Bank of New York Mellon Trust Company, N.A. Trustee for Mortgage Assets Management Series I Trust

vs.

Aimee Sanford et al

RE: Sanford, Joseph

Newspaper: Citronelle Call News &Birmingham News

City/ Town: City of Lawrence

DATE ISSUED: 10/05/2023

Thomas H. Driscoll, Jr., Clerk of Courts, Essex County

CLERK OF COURTS/ ASST. CLERK

COURT NAME & ADDRESS: Essex County Superior Court – Lawrence, 43 Appleton Way Lawrence, MA 01841

Call News October 18, 25 and November 1, 2023

SERVICE BY PUBLICATION

LEGAL NOTICE

IN THE CIRCUIT COURT OF

MOBILE COUNTY, ALABAMA

CASE NO. CV-2022-900765

BEFORE THE AMERICAN ARBITRATION ASSOCIATION

CASE NO 01-22-0002-7098

Roy Benton and Aurelia Hooks Benton, Plaintiffs/Claimants v. Terminix International Co, LP,

Trevor Butler

Roy Benton and Aurelia Hooks Benton, Plaintiffs/Claimants v. Terminix International Co, LP,

Michael Johnson

Claim Amounts:

In excess of the jurisdictional minimum of the Court, including compensatory, mental anguish, and punitive damages for asserted claims of fraud, fraudulent suppression and concealment, breach of warranty, negligence, wantonness/willfulness, breach of contract,

Negligent training and supervision.

Affidavit having been filed herein that service of process cannot be made because either the residence of the Defendants are unknown and cannot with reasonable diligence be ascertained, or, the identity of the Defendant is unknown, or the resident Defendant has been absent for more than thirty (30) days since the filing of this suit, or that Defendant avoids service and averring fact showing such avoidance.

On September 1, 2023 the Circuit Court of Mobile County, Alabama entered an Order for serving Defendants, Trevor Butler and Michael Johnson by publication as service both for the pending case in Mobile County Circuit Court and the Arbitration pending before the American Arbitration Association. The Court’s Order for service by Publication was amended on September 29, 2023.

Now, therefore, said Defendants, Trevor Butler and Michael Johnson are hereby commanded to within thirty (30) days of the last date of publication hereof plead or answer to said Complaint or Demand in Arbitration, or suffer the entry of a Default Judgment against them.

Given under my hand this 12th day of October, 2023.

/s Sharla Knox

Circuit Clerk of Mobile County, Alabama

Plaintiff’s Attorney

Daniel Mims

The Mims Firm P C

952 Government St

Mobile, AL 36604

Phone: 252-433-0161

E-mail: Corrine Busby corrinebusby@mimsfirm.com

Call News Oct. 18, Oct. 25, Nov. 1 & Nov. 8, 2023

PERMANENT CUSTODY/TERMINATION

LEGAL NOTICE

IN THE JUVENILE COURT OF

MOBILE COUNTY, ALABAMA

CASE NO. JU-14-0638.05

IN THE MATTER OF ELIAS LE’SHUN JERMAINE HARRIS, A Minor

Notice is hereby given to Jontae Harris, the father of Elias Le’Shun Jermaine Harris, born 6-19-2009, whose present whereabouts are unknown and cannot be ascertained after diligent search and inquiry; or any other person or persons who claim to have a legal interest in the following proceedings in the Juvenile Court of Mobile County, Alabama viz:

IN THE MATTER OF ELIAS LE’SHUN JERMAINE HARRIS, A Minor

CASE NO. JU-14-0638.05

In the matter of the permanent custody and termination of parental rights of the parents of Elias Le’Shun Jermaine Harris, born 6-19-2009;

Heretofore/This 2nd day of March 2023, came the STATE OF ALABAMA DEPARTMENT OF HUMAN RESOURCES and filed in this Court a petition asking for the permanent custody and termination of parental rights of the parents of said child for the purpose of placing said minor for adoption.

The said Jontae Harris, father, shall respond to the complaint no later than 30 days after the last date of publication shown herein.

It is ORDERED by the Court that the 17th day of October, 2023, at 1:00 p.m., be appointed a day for hearing said petition, at which time all parties who claim to have a legal interest can appear and contest the same if they think proper.

Linda C, Jensen, District Judge

Call News 09-27-23, 10-04-23, 10-11-23, 10-18-23

LEGAL NOTICE

IN THE JUVENILE COURT OF

MOBILE COUNTY, ALABAMA

CASE NO. JU-14-0638.05

IN THE MATTER OF ELIAS LE’SHUN JERMAINE HARRIS, A Minor

CASE NO. JU-14-0638.05

In the matter of the permanent custody and termination of parental rights of the parents of Elias Le’Shun Jermaine Harris, born 6-19-2009;

The said Jontae Harris, father, shall respond to the complaint no later than 30 days after the last date of publication shown herein.

Call News 09-27-23, 10-04-23, 10-11-23, 10-18-23

LEGAL NOTICE

IN THE JUVENILE COURT OF

MOBILE COUNTY, ALABAMA

IN THE MATTER OF TREYVAUGHN THOMAS STEINBORN, A Minor

CASE NO. JU-18-0932.04

Notice is hereby given to Andrew Thomas Steinborn, the father of Treyvaughn Thomas Steinborn, born 3-13-14, whose present whereabouts are unknown and cannot be ascertained after diligent search and inquiry; or any other person or persons who claim to have a legal interest in the following proceedings in the Juvenile Court of Mobile County, Alabama viz:

IN THE MATTER OF TREYVAUGHN THOMAS STEINBORN, A Minor

CASE NO. JU-18-0932.04

In the matter of the permanent custody and termination of parental rights of the parents of Treyvaughn Thomas Steinborn, born 3-13-14;

Heretofore/This 22nd day of May 2023, came the STATE OF ALABAMA DEPARTMENT OF HUMAN RESOURCES and filed in this Court a petition asking for the permanent custody and termination of parental rights of the parents of said child for the purpose of placing said minor for adoption.

The said Andrew Thomas Steinborn, father, shall respond to the complaint no later than 30 days after the last date of publication shown herein.

It is ORDERED by the Court that the 10th day of January 2024 at 12:00 p.m., be appointed a day for hearing said petition, at which time all parties who claim to have a legal interest can appear and contest the same if they think proper.

Linda C, Jensen, District Judge

Call News 10-04-23, 10-11-23, 10-18-23, 10-25-23

LEGAL NOTICE

IN THE JUVENILE COURT OF

MOBILE COUNTY, ALABAMA

IN THE MATTER OF FRANCES LYNN STEINBORN, A Minor

CASE NO. JU-18-0931.04

Notice is hereby given to Andrew Thomas Steinborn, the father of Frances Lynn Steinborn, born 5-06-15, whose present whereabouts are unknown and cannot be ascertained after diligent search and inquiry; or any other person or persons who claim to have a legal interest in the following proceedings in the Juvenile Court of Mobile County, Alabama viz:

IN THE MATTER OF FRANCES LYNN STEINBORN, A Minor

CASE NO. JU-18-0931.04

In the matter of the permanent custody and termination of parental rights of the parents of Frances Lynn Steinborn, born 5-06-15;

The said Andrew Thomas Steinborn, father, shall respond to the complaint no later than 30 days after the last date of publication shown herein.

Linda C, Jensen, District Judge

Call News 10-04-23, 10-11-23, 10-18-23, 10-25-23

LEGAL NOTICE

IN THE JUVENILE COURT OF

MOBILE COUNTY, ALABAMA

IN THE MATTER OF JOAQUIN LAMAR MACK, A Minor

CASE NO. JU-21-0951.02

Notice is hereby given to Joaquin Mack, the father of Joaquin Lamar Mack, born 11-14-19, whose present whereabouts are unknown and cannot be ascertained after diligent search and inquiry; or any other person or persons who claim to have a legal interest in the following proceedings in the Juvenile Court of Mobile County, Alabama viz:

IN THE MATTER OF JOAQUIN LAMAR MACK, A Minor

CASE NO. JU-21-0951.02

In the matter of the permanent custody and termination of parental rights of the parents of Joaquin Lamar Mack, born 11-14-19;

Heretofore/This 6th day of December 2022, came the STATE OF ALABAMA DEPARTMENT OF HUMAN RESOURCES and filed in this Court a petition asking for the permanent custody and termination of parental rights of the parents of said child for the purpose of placing said minor for adoption.

The said Joaquin Mack, father, shall respond to the complaint no later than 30 days after the last date of publication shown herein.

It is ORDERED by the Court that the 30th day of January 2024 at 12:00 p.m., be appointed a day for hearing said petition, at which time all parties who claim to have a legal interest can appear and contest the same if they think proper.

Linda C, Jensen, District Judge

Call News 10-04-23, 10-11-23, 10-18-23, 10-25-23

LEGAL NOTICE

IN THE JUVENILE COURT OF

MOBILE COUNTY, ALABAMA

IN THE MATTER OF ANDREW THOMAS STEINBORN JR, A Minor

CASE NO. JU-18-0937.03

Notice is hereby given to Andrew Thomas Steinborn, the father of Andrew Thomas Steinborn, Jr., born 4-29-16, whose present whereabouts are unknown and cannot be ascertained after diligent search and inquiry; or any other person or persons who claim to have a legal interest in the following proceedings in the Juvenile Court of Mobile County, Alabama viz:

IN THE MATTER OF ANDREW THOMAS STEINBORN, JR, A Minor

CASE NO. JU-18-0937.03

In the matter of the permanent custody and termination of parental rights of the parents of Andrew Thomas Steinborn, Jr., born 4-29-16;

The said Andrew Thomas Steinborn, father, shall respond to the complaint no later than 30 days after the last date of publication shown herein.

Linda C, Jensen, District Judge

Call News 10-04-23, 10-11-23, 10-18-23, 10-25-23

LEGAL NOTICE

IN THE JUVENILE COURT OF

MOBILE COUNTY, ALABAMA

JU-20-0780.03

IN THE MATTER OF LUKE ALEXANDER OWENS, A Minor

Notice is hereby given to Megan Danielle Phelps, the mother of Luke Alexander Owens, born 11-26-18, whose present whereabouts are unknown and cannot be ascertained after diligent search and inquiry; or any other person or persons who claim to have a legal interest in the following proceedings in the Juvenile Court of Mobile County, Alabama viz:

IN THE MATTER OF LUKE ALEXANDER OWENS, A Minor

JU-20-0780.03

In the matter of the permanent custody and termination of parental rights of the mother of Luke Alexander Owens, born 11-26-18.

Heretofore on March 22, 2023, came BRADLEY OWENS and filed in this Court a petition asking for the permanent custody and termination of parental rights of the mother of said child for the purpose of adoption.

The said Megan Danielle Phelps, mother, shall respond to the complaint no later than 30 days after the last date of publication shown herein.

It is ORDERED by the Court that the 23rd day of January, 2024, at 1:00 p.m., be appointed a day for hearing said petition, at which time all parties who claim to have a legal interest can appear and contest the same if they think proper.

Linda C. Jensen, Judge

Call News 10-04-23, 10-11-23, 10-18-23, 10-25-23

LEGAL NOTICE

NOTICE OF MORTGAGE

FORECLOSURE SALE

STATE OF ALABAMA

COUNTY OF MOBILE

THIS IS AN ATTEMPT TO COLLECT A DEBT. ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.

Default having been made in the payment of the debt secured by that certain mortgage executed by Mose Aron James, Jr, Mortgagor(s), to Citifinancial Corporation, LLC, Mortgagee, on August 9, 2007, said mortgage being recorded on August 13, 2007 in the Probate Office of Mobile County, Alabama in Instrument Number 2007062644, Book 6239, Page 172, and later assigned to U.S. Bank Trust National Association, as Trustee for LB-Dwelling Series V Trust, by reason of such default, having declared all the indebtedness secured by said mortgage due and payable, and such default continuing, notice is hereby given that, acting under the power of sale contained in said mortgage, U.S. Bank Trust National Association, as Trustee for LB-Dwelling Series V Trust will sell at public outcry, for cash, to the highest bidder, in front of the Courthouse door in the City of Mobile, Mobile County, Alabama during the legal hours of sale on November 15, 2023 the following described real estate situated in Mobile County, Alabama, to wit:

Lot 2, Block 1, of the resubdivision of the resubdivision of the First Unit of Gulf Heights, according to a plat thereof recorded in Map Book 5, Page 633, 634, of the records in the Office of the Judge of Probate Court of Mobile County, Alabama.

Subject to all restrictions, reservations, rights, easements, rights-of-way, provisions, covenants, terms, conditions and building set back line of record.

Commonly known as: 704 Caton Avenue, Mobile, AL 36617

Tax ID #: 29 02 44 0 027 010.XXX

THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO.

Said sale will be made subject to any outstanding ad valorem taxes (including taxes which are a lien, whether or not now due and payable), any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, zoning ordinances, restrictions, covenants, and matters of record superior to the mortgage first set out above and restrictions of record in the Probate Office aforesaid, matters of survey, and to any Federal or State Tax liens, if any, and/or special assessments, if any, which might adversely affect the title to the premises.

Said sale will be made for the purpose of paying the indebtedness secured by the above described mortgage to U.S. Bank Trust National Association, as Trustee for LB-Dwelling Series V Trust, Mortgagee, and the proceeds thereof will be applied as provided for in the terms of said mortgage.

The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to McMichael Taylor Gray LLC at the time and place of the sale. The balance of the purchase price must be paid in certified funds by noon the next business day to McMichael Taylor Gray LLC at 3550 Engineering Drive, Suite 260, Peachtree Corners, GA 30092.

McMichael Taylor Gray, LLC reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation.

U.S. Bank Trust National Association, as Trustee for LB-Dwelling Series V Trust

AS ATTORNEY IN FACT FOR

Mose Aron James, Jr.

TONI B. SMOKE, Attorney for Mortgagee

McMichael Taylor Gray, LLC

3550 Engineering Drive, Suite 260

Peachtree Corners, GA 30092

404-474-7149

MTG File No.: AL2023-00164

Call News October 18, 25 and November 1, 2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by George W. Cox and Crystal L. Cox aka Crystal Lynn Cox, husband and wife., originally in favor of Mortgage Electronic Registration Systems, Inc., as a nominee for Mortgage Research Center, LLC dba Veterans United Home Loans, on October 27, 2017, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Bk: LR7572 Pg: 1590; with loan modification agreement recorded in Instrument Number 2019004349 and Instrument Number 2022076840; the undersigned PennyMac Loan Services, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 29, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: A portion of Lot 4, according to map of Forest Home Subdivision, recorded in the Office of the Judge of Probate, Mobile County, Alabama, in Deed Book 114, Page 15 and being more particularly described as follows: Beginning at the Southwest corner of said Lot 4; said point being on the Easterly right of way line of U.S. Highway No. 45; thence North 64 degrees 24 minutes 10 seconds East a distance of 970.23 feet to a point on the East line of said Lot 4; said point also being on the Westerly right of way line of I. C. and G. Railroad; thence run Northwestwardly and along the Easterly line of said Lot 4 and also along the Westerly right of way line of the I. C. and G. Railroad a distance of 193.88 feet to the Northeast corner of said Lot; thence South 81 degrees 03 minutes 20 seconds West along the Northerly line of said Lot 4 a distance of 59.17 feet; thence South 64 degrees 24 minutes 10 seconds West a distance of 908.04 feet to a point on the Easterly right of way line of U.S. Highway No. 45; thence run Southeastwardly along the Easterly right of way line of said Highway a distance of 210.00 feet to the Point of Beginning.. Property street address for informational purposes: 5740 Highway 45 , Eight Mile, AL 36613. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. PennyMac Loan Services, LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223

www.tblaw.com

TB File Number: 23-07442

Call News 10/18/2023, 10/25/2023, 11/01/2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Kevin D. Graham and Catherine W. Graham, husband and wife, originally in favor of Mortgage Electronic Registration Systems, Inc., acting solely as nominee for Resmae Mortgage Corporation, on August 25, 2006, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 6034 Page 345; the undersigned U.S. Bank National Association, as Trustee, successor in interest to Bank of America, National Association, as Trustee, successor by merger to LaSalle Bank National Association, as Trustee for Merrill Lynch Mortgage Investors Trust, Mortgage Loan Asset-Backed Certificates, Series 2006-RM5 , as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 29, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 36, Ridgefield, Unit 1, Section A, as recorded in Map Book 16, Page 121 in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 616 Cumberland Rd E , Mobile, AL 36608. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. U.S. Bank National Association, as Trustee, successor in interest to Bank of America, National Association, as Trustee, successor by merger to LaSalle Bank National Association, as Trustee for Merrill Lynch Mortgage Investors Trust, Mortgage Loan Asset-Backed Certificates, Series 2006-RM5 , (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223

www.tblaw.com

TB File Number: 23-07377

Call News 10/18/2023, 10/25/2023, 11/01/2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Devan Robert Smullen, a married man, originally in favor of Mortgage Electronic Registration SYstems, Inc., acting solely as nominee for GMFS, LLC, on April 27, 2018, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book LR7631 Page 560; the undersigned MidFirst Bank, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 30, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 1, John Dixon Subdivision, according to plat thereof recorded in Map Book 102, Page 93 of the records in the Office of the Judge of Probate, Mobile County, Alabama. Less and except Commencing at the Northeast corner of Lot 1, John Dixon Subdivision, as recorded in Map Book 102, Page 93 in the Office of the Judge of Probate, Mobile County, Alabama; thence South 00 degrees 04 minutes 50 seconds East, 185.00 feet to the point of beginning of the property herein described; thence South 00 degrees 04 minutes 50 seconds East, 35.00 feet; thence South 89 degrees 56 minutes 46 seconds West, 520.00 feet; thence North 00 degrees 04 minutes 50 seconds West, 220.00 feet; thence North 89 degrees 56 minutes 46 seconds East, 137.08 feet; thence South 00 degrees 04 minutes 50 seconds East 185.00 feet; thence North 89 degrees 56 minutes 46 seconds East 382.92 feet to the point of beginning.. Property street address for informational purposes: 12226 Potter Tract Road , Grand Bay, AL 36541. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. MidFirst Bank, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223

www.tblaw.com

TB File Number: 23-06736

Call News 10/18/2023, 10/25/2023, 11/01/2023

NOTICE OF FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Richard Ashley Sanderson, a married man, to Mortgage Electronic Registration Systems, Inc., as Mortgagee, as nominee for Century Lending Company, its successors and assigns, on August 5, 2014, said mortgage being recorded in the Office of the Judge of Probate of Mobile County, Alabama, on August 14, 2014 at Book LR7177, at Page 1695, as Document Number 2014040932. Freedom Mortgage Corporation, the current holder, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Mobile County Courthouse, in Mobile, Alabama, on November 16, 2023, during the legal hours of sale, the following described real estate, situated in Mobile County, Alabama, to-wit:

LOT 2, OAKLEIGH ESTATES, FIRST ADDITION, ACCORDING TO THE PLAT THEREOF RECORDED IN MAP BOOK 30, PAGE 2 OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA.

More commonly known as: 624 Oakview Dr, Saraland, AL 36571

This Property will be sold on as “as is, where is” basis, without warranty or recourse, expressed or implied as to title, use and/or enjoyment and will be sold subject to the right of redemption of all parties entitled thereto. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expense of foreclosure. The successful bidder must tender certified funds by noon the next business day to Law Office of Halliday, Watkins & Mann, P.C. Certified funds must be in the form of a wire transfer, bank or credit union’s cashier’s check, or bank official check payable to Halliday, Watkins & Mann, P.C. Halliday, Watkins & Mann, P.C. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. If sale is voided, Mortgagee/Transferee shall return the bid amount to the successful purchaser and the Mortgagee/Transferee shall not be liable to the purchase for any damages. If the sale is set aside for any reason, the purchaser at the sale shall be only entitled to a return of the deposit and bid amount, if paid. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit is purchase price against the expenses of sale and indebtedness secured by the real estate. This sale is subject to postponement or cancellation.

Freedom Mortgage Corporation (“Transferee”)

Halliday, Watkins & Mann, P.C.

244 Inverness Center Drive

Birmingham, AL 35242

Phone: (801) 355-2886

Call News October 18, 2023, October 25, 2023, November 1, 2023

NOTICE OF FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Steven J. Boyd and Amy J. Boyd, husband and wife, as joint tenants with right of survivorship, to Mortgage Electronic Registration Systems, Inc., as Mortgagee, as nominee for Freedom Mortgage Corporation, its successors and assigns, on January 20, 2022, said mortgage being recorded in the Office of the Judge of Probate of Mobile County, Alabama, on January 28, 2022, as Document Number 2022007040. Freedom Mortgage Corporation, the current holder, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Mobile County Courthouse, in Mobile, Alabama, on November 16, 2023, during the legal hours of sale, the following described real estate, situated in Mobile County, Alabama, to-wit:

LOT 20, YOUNGSTOWNE HILL, ACCORDING TO PLAT THEREOF RECORDED IN MAP BOOK 102, PAGE 66 OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE OF MOBILE COUNTY, ALABAMA.

More commonly known as: 2075 Jonah Ct, Semmes, AL 36575

Freedom Mortgage Corporation (“Transferee”)

Halliday, Watkins & Mann, P.C.

244 Inverness Center Drive

Birmingham, AL 35242

Phone: (801) 355-2886

Call News October 18, 2023, October 25, 2023, November 1, 2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Kenneth O. McLaughlin and Stephanie B. McLaughlin, husband and wife, originally in favor of Mortgage Electronic Registration Systems, Inc., acting solely as nominee for PrimeLending, a Plainscapital Company, on August 20, 2010, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 6693 Page 99; as re-recorded in Book 6716 Page 402; with loan modification agreement(s) recorded in BK: LR7172 Page 84 and Instrument Number 2022028481; the undersigned Wells Fargo Bank, N.A., as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on December 7, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 12, The Legacy at Saybrook, Unit One, according to plat thereof recorded in Map Book 121, Page 43, of the records in the Office of the Judge of Probate of Mobile County, Alabama.. Property street address for informational purposes: 3842 Dwight Court , Mobile, AL 36619-1272. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Wells Fargo Bank, N.A., (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223

www.tblaw.com

TB File Number: 23-40501

Call News 10/18/2023, 10/25/2023, 11/01/2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Cellestine Kennedy, a single woman, originally in favor of Mortgage Electronic Registration Systems, Inc., as nominee for Dream House Mortgage Corporation, on July 9, 2007, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 6229 Page 920; the undersigned U.S. Bank National Association, as trustee successor in interest to Bank of America, National Association, as trustee, successor by merger to LaSalle Bank National Association, as Trustee for Morgan Stanley Mortgage Loan Trust 2007-13, Mortgage Pass-Through Certificates, Series 2007-13, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 15, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: The North Half of the North Half of the West Half of the South Half of the South Half of the Northwest Quarter of the Southeast Quarter of Section, 31, Township 6 South, Range 3 West Mobile County Alabama EXCEPT however the East 15 feet for public right of way.. Property street address for informational purposes: 10294 Moores Rd , Grand Bay, AL 36541. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. U.S. Bank National Association, as trustee successor in interest to Bank of America, National Association, as trustee, successor by merger to LaSalle Bank National Association, as Trustee for Morgan Stanley Mortgage Loan Trust 2007-13, Mortgage Pass-Through Certificates, Series 2007-13, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223

www.tblaw.com

TB File Number: 23-07385

Call News 10/18/2023, 10/25/2023, 11/01/2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed on January 30, 2008 by Eldred Hall aka Eldred M. Hall, a married person, joined by his wife, Erica V. Hall, originally in favor of Wells Fargo Bank, N.A., and recorded in 6326 at 1788 on February 1, 2008, in the Office of the Judge of Probate of Mobile County, Alabama. LOGS Legal Group LLP, as counsel for Mortgagee or Transferee and under and by virtue of power of sale contained in the said mortgage will, on December 12, 2023, sell at public outcry to the highest bidder at the main entrance of the Mobile County, Alabama, Courthouse in the City of Mobile, during the legal hours of sale, the following real estate situated in Mobile County, Alabama, to wit:

LOT 24 EDGEWOOD PLACE UNIT NINE ACCORDING TO PLAT THEROF RECORDED IN MAP BOOK 59 PAGE 39 OF THERECORDS IN THE OFFICE OF THE JUDGE OF PROBATE OF MOBILE COUNTY, ALABAMA.

For informational purposes only, the property address is: 9470 Lexington Ct, Mobile, AL 36695.

Any property address provided is not part of the legal description of the property sold herein and in the event of any discrepancy, the legal description referenced herein shall control.

This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. Furthermore, the property to be offered pursuant to this notice of sale is being offered for sale, transfer and conveyance AS IS, WHERE IS. Neither the mortgagee, nor the officers, directors, attorneys, employees, agents or authorized representative of the mortgagee make any representation or warranty relating to the title or any physical, environmental, health or safety conditions existing in, on, at or relating to the property offered for sale. Any and all responsibilities or liabilities arising out of or in any way relating to any such condition, including those suggested by Code of Ala. (1975) § 35-4-271, expressly are disclaimed. This sale is subject to all prior liens and encumbrances and unpaid taxes and assessments including any transfer tax associated with the foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars and no/100 ($5,000.00) in certified or cash funds at the time and place of the sale. The balance of the purchase price must be paid in certified funds by close of business on the next business day thereafter at the Law Office of LOGS Legal Group LLP at the address indicated below. LOGS Legal Group LLP reserves the right to award the bid to the next highest bidder, or to reschedule the sale, should the highest bidder fail to timely tender the total amount due.

Wells Fargo Bank, N.A., and its successors and assigns

Mortgagee or Transferee

LOGS LEGAL GROUP LLP

1878 Jeff Rd. NW, Suite “I”

Huntsville, AL 35806

704-333-8107/ 23-023214

Attorneys for Mortgagee or Transferee

Call News October 18, 2023 and October 25, 2023 and November 1, 2023

FORECLOSURE NOTICE

Default having been made in the payment of the indebtedness described in and secured by that certain vendor’s lien deed conveyed from MARGARITA NEAL and MARIA AURELIA GALVAN to MARIA FRANCISCA GASPAR MIGUEL and EMILIO RAYMUNDO DIEGO, recorded in Mobile County, AL Probate Ct. records Instrument No. 2023023208, said default continuing notice is hereby given that the undersigned will, under and by virtue of the power of sale contained in said vendor’s lien deed, sell at public outcry for cash to the highest bidder at 12:00 noon on Nov. 15, 2023, at the front door of the Mobile County Courthouse the following described property to wit:

Lot 42 GREENLAWN SUB MBK 9 P 212 #SEC 31 T3S R2W #MP23 09 31 2 000 of the records in the Office of the Judge of Probate Court, Mobile County, AL. The property address is 2416 Alta Fescue Dr., Semmes, AL 36575.

Alabama Law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as part of the foreclosure process.

Said sale will be made for the purpose of paying said indebtedness and expenses incident to said sale, including a reasonable attorney’s fee.

CLIFFORD C. SHARPE

Attorney for Lienholder

307 Morgan Ave.

Mobile, AL 36606

Call News on Oct. 25, Nov. 1, 8, 2023

NOTICE OF

MORTGAGE FORECLOSURE SALE

STATE OF ALABAMA

COUNTY OF MOBILE

Default having been made of the terms of the loan documents secured by that certain mortgage executed by Mary Denaro And Emanuel C Denaro Wife And Husband to Option One Mortgage Corporation dated June 24, 2005; said mortgage being recorded on June 30, 2005, in Book 5803, Page 723 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to U.S. Bank, National Association, as Indenture Trustee on behalf of the holders of the Terwin Mortgage Trust 2005-11, Asset-Backed Securities, TMTS Series 2005-11 in Instrument 2023055249 in the Office of the Judge of Probate of Mobile County, ALABAMA.

The undersigned, U.S. Bank, National Association, as Indenture Trustee on behalf of the holders of the Terwin Mortgage Trust 2005-11, Asset-Backed Securities, TMTS Series 2005-11under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 16th day of November, 2023 the following property, situated in Mobile County, Alabama, to-wit:

Lot 4, Camelot Subdivision, according to plat thereof recorded in Map Book 20, Page 3 of the records in the Office of the Judge of Probate, Mobile County, Alabama.

Said property is commonly known as 307 Camelot Dr, Saraland, AL 36571.

Should a conflict arise between the property address and the legal description the legal description will control.

Said property will be sold subject to any outstanding ad valorem taxes (including taxes which are a lien, but not yet due and payable), the right of redemption of any taxing authority, all outstanding liens for public utilities which constitute liens upon the property, any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, easements, rights-of-way, zoning ordinances, restrictions, special assessments, covenants, the statutory right of redemption pursuant to Alabama law, and any matters of record including, but not limited to, those superior to said Mortgage first set out above. Said property will be sold on an “as-is” basis without any representation, warranty or recourse against the above-named or the undersigned. The successful bidder must present certified funds in the amount of the winning bid at the time and place of sale.

The sale will be conducted subject (1) to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and (2) to final confirmation and audit of the status of the loan with the holder of the Mortgage.

U.S. BANK, NATIONAL ASSOCIATION, AS INDENTURE TRUSTEE ON BEHALF OF THE HOLDERS OF THE TERWIN MORTGAGE TRUST 2005-11, ASSET-BACKED SECURITIES, TMTS SERIES 2005-11

as holder of said mortgage

McCalla Raymer Leibert Pierce, LLC

Two North Twentieth

2 20th Street North, Suite 1000

Birmingham, AL 35203

(205) 216-4238

FT21@mccalla.com

File No. 23-04986AL

www.foreclosurehotline.net

Call News 10/18/2023,10/25/2023,11/01/2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Jonathan Leland Polite to Mortgage Electronic Registration Systems, Inc., as nominee for Village Capital and Investment LLC, dated September 20, 2021 said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Instrument Number 2021064873. Said mortgage was subsequently sold, assigned and transferred to Planet Home Lending, LLC. Under and by virtue of the power of sale contained in said mortgage, the undersigned, Planet Home Lending, LLC, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse in Mobile County, Alabama on November 9, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following describe real estate situated in Mobile County, Alabama, to-wit: LOT #14 SILVER ACRES, UNIT II PHASE II AS SHOWN IN MAP BOOK 106, PAGE 28 AS RECORDED IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA. Property Street Address for Informational Purposes: 9571 Hwy 45 Chunchula AL 36521 Said property will be sold “AS IS”. NO REPRESENTATION OR WARRANTY, EXPRESSED OR IMPLIED, IS MADE AS TO THE TITLE OF SAID PROPERTY. Said property is subject to any title deficiencies including but not limited to: any outstanding ad valorem taxes – including taxes which are a lien but not yet due and payable, federal tax liens any matters which might be disclosed by an accurate survey and inspection of the property, any assessments liens, encumbrances, zoning ordinances, restrictions, covenants, and matters of record superior to the Mortgage first set out above. Said property will be sold subject to the right of redemption of all parties entitled thereto. The highest bidder must tender the total amount of the winning bid in certified funds at the time and place of sale. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand the rights and programs as a part of the foreclosure process. This sale will be made for the purpose of paying the same and all expenses of this sale, as provided in said Mortgage and by Alabama law. This sale is subject to postponement or cancellation. **This is an attempt to collect a debt and any information obtained may be used for that purpose.** Planet Home Lending, LLC, Mortgagee or Transferee Jonathan Smothers, Esq ALAW One Independence Plaza, Suite 416 Birmingham, AL 35209 Attorney for Mortgagee/Transferee 23-008614 A-4796214

Call News 10/18/2023, 10/25/2023, 11/01/2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Michael W Howell Jr aka Michael Howell, Jr, an unmarried man, originally in favor of Mortgage Electronic Registration Systems, Inc. as a nominee for Pacific Residential Mortgage, on September 24, 2021, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Instrument Number 2021064152; the undersigned PennyMac Loan Services, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 9, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 69, Woodside, Unit Two, according to the plat thereof recorded in Map Book 76, Page 63, of the records in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 6363 Woodside Dr S , Theodore, AL 36582. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. PennyMac Loan Services, LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223

www.tblaw.com

TB File Number: 23-07125

Call News 10/18/2023, 10/25/2023, 11/01/2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Michael R. Payne, a married man joined by his wife Dee Ann Payne, originally in favor of Mortgage Electronic Registration Systems, Inc., acting solely as nominee for SMG Mortgage Group, on January 26, 2018, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in BK: LR7602 Pg: 1917; with Loan Modification Agreement recorded May 26, 2022 in Instrument Number 2022037152; the undersigned Allied First Bank, SB dba Servbank, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 9, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 62, Windgate Estates, according to plat thereof recorded in Map Book 28, Page 105, of the records in the Office of the Judge of Probate of Mobile County, Alabama.. Property street address for informational purposes: 1301 Repoll Rd , Mobile, AL 36695. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Allied First Bank, SB dba Servbank, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223

www.tblaw.com

TB File Number: 23-06804

Call News 10/18/2023, 10/25/2023, 11/01/2023

MORTGAGE FORECLOSURE NOTICE

Default having been made in the terms of that certain Mortgage, executed on 06/29/2010, by Robert Davis, Jr. a/k/a Robert L. Davis, Jr., a married man, as Mortgagor, to MORTGAGE ELECTRONIC REGISTRATION SYSTEMS, INC AS A NOMINEE FOR HOMETOWN MORTGAGE SERVICES, INC. as Mortgagee, which said Mortgage is recorded in the Office of the Judge of Probate, Mobile County, Alabama, in Book 6672, Page 402 on 07/01/2010, and Modified in Instrument # 2020011166 recorded 2/26/2020 and Carrington Mortgage Services, LLC is currently the holder of the Mortgage, and underlying promissory note secured thereby, and Carrington Mortgage Services, LLC is authorized to enforce the terms of the Mortgage secured by said promissory note; and default having continued under the terms of said Mortgage, and by virtue of Alabama Code Section 35-10-3 and 35-10-2, the following described real property will be sold at public outcry, for cash, to the highest bidder, in front of the Courthouse door of said County, during the legal hours of sale, on 11/15/2023

LOT 66, HUNTERS COVE, UNIT ONE, PHASE TWO, ACCORDING TO PLAT THEREOF RECORDED IN MAP BOOK 116, PAGE 59, OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE OF MOBILE COUNTY, ALABAMA.

Subject to all easements, restrictions and reservations appearing of record. Said sale will also be made subject to any Federal Tax Liens and/or Special Assessments of any nature, if any, which might adversely affect the title to the property.

The property is being sold “as is, where is”. Said property is sold without warranty or recourse, expressed or implied as to title, use or enjoyment.

This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure.

This sale is subject to postponement or cancellation.

Kent D. McPhail

McPhail Sanchez, LLC

Attorney for Mortgagee/Transferee

126 Government Street

Mobile, AL 36602

251-438-2333

Call News 10/18/2023, 10/25/2023, 11/01/2023

NOTICE OF SALE UNDER POWER

FORECLOSURE NOTICE

WHEREAS, default has occurred in the performance of the covenants, terms and conditions of a mortgage from HANABLE SMITH JR, RHODA TAMERA DAVIS HUSBAND AND WIFE to MORTGAGE ELECTRONIC REGISTRATION SYSTEMS, INC., AS MORTGAGEE, AS NOMINEE FOR NEW SOUTH FEDERAL SAVINGS BANK, on the 19th day of February, 2007, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, on March 5, 2007, in Deed/Mortgage Book 6139, Page 1441, Mobile County, Alabama Records, said Mortgage having subsequently been transferred and assigned to Nationstar Mortgage LLC, by instrument recorded in the aforesaid Probate Office; notice is hereby given that the undersigned Nationstar Mortgage LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash at the main entrance to the Mobile county courthouse located at 205 Government Street, Mobile, AL 36652 in Mobile, Mobile County, Alabama, on December 13, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:

LOT 14, BLOCK 1, MARTIN PLACE, ACCORDING TO PLAT THEREOF RECORDED IN MAP BOOK 5, PAGE 141, OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA.

Said legal description being controlling, however the property is more commonly known as 1581 E MARTIN DR, MOBILE, AL 36605.

This property will be sold on an “as is, where is” basis, subject to any easements, encumbrances, and exceptions reflected in the mortgage and those contained in the records of the Office of the Judge of Probate in the county where the above-described property is situated. This property will be sold subject to the right of redemption of all parties entitled thereto and subject to any outstanding ad valorem taxes (including taxes which are a lien, whether or not now due and payable). This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation.

Nationstar Mortgage LLC, Mortgagee/Transferee

THE BELOW LAW FIRM MAY BE HELD TO BE ACTING AS A DEBT COLLECTOR, UNDER FEDERAL LAW. IF SO, ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.

Rubin Lublin, LLC, Attorney for Mortgagee/Transferee

11 N. Water Street, Suite 10290, Mobile, AL 36602

Telephone Number: (877) 813-0992 Case No. NAT-23-04545-1

rlselaw.com/property-listing

Call News 10/18/2023, 10/25/2023, 11/01/2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed on June 20, 2019 by Kevin G. Zedler and Mary V. Zedler, originally in favor of Mortgage Electronic Registration Systems, Inc., as nominee for Nationstar Mortgage, LLC DBA Mr.Cooper, and recorded in Instrument # 2019035257 on June 24, 2019, and modified in and modified by agreement recorded March 2, 2022 in Instrument Number 2022015209, in the Office of the Judge of Probate of Mobile County, Alabama. LOGS Legal Group LLP, as counsel for Mortgagee or Transferee and under and by virtue of power of sale contained in the said mortgage will, on December 7, 2023, sell at public outcry to the highest bidder at the main entrance of the Mobile County, Alabama, Courthouse in the City of Mobile, during the legal hours of sale, the following real estate situated in Mobile County, Alabama, to wit:

Lot 108, “SPANISH TRACE”, First Unit as recorded in Map Book 23, Page 14 of the records in the Office of the Judge Of Probate, Mobile County, Alabama.

For informational purposes only, the property address is: 2009 Chase Drive, Saraland, AL 36571.

Any property address provided is not part of the legal description of the property sold herein and in the event of any discrepancy, the legal description referenced herein shall control.

Nationstar Mortgage LLC, and its successors and assigns

Mortgagee or Transferee

LOGS LEGAL GROUP LLP

1878 Jeff Rd. NW, Suite “I”

Huntsville, AL 35806

704-333-8107/ 23-023205

Attorneys for Mortgagee or Transferee

Call News October 11, 2023 and October 18, 2023 and October 25, 2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Roger Floyd, Jr, a single person, originally in favor of Wells Fargo Bank, N.A., on February 27, 2015, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Bk: LR7237 Pg: 1789; with Loan Modification Agreement recorded in Instrument Number 2022030880; the undersigned Wells Fargo Bank, N.A., as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on December 7, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: A portion of Lot 10 of Frank Woodard, Jr. Subdivision as recorded in Map Book 5, Pages 599 and 600 of the records in the Office of the Judge of Probate, Mobile County, Alabama, being a lot lying along the East line of a lot conveyed by the Grantors herein to Luegens and Catherine Pollock by deed dated October 4, 1965 and recorded in Real Property Book 630, Page 325, said lot herein conveyed being more particularly described as follows: From the Southwest corner of Lot 10 run Easterly along South line of Lot 10, 69 feet to the Southeast corner of lot above mentioned conveyed to Pollock for Point of Beginning, thence run North along the East line of Pollock 315.8 feet to North line of Lot 10, thence run 69 feet East to a point, thence South 315.8 feet to South line of Lot 10, thence West along said South line 69 feet to Point of Beginning.. Property street address for informational purposes: 10751-8 Joe Carl Road W #8 , Theodore, AL 36582. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Wells Fargo Bank, N.A., (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223

www.tblaw.com

TB File Number: 23-40495

Call News 10/11/2023, 10/18/2023, 10/25/2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Yong Chung, originally in favor of PNC Bank, N.A., on December 28, 2021, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Instrument No. 2022001086; the undersigned PNC Bank National Association, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 16, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: East 97 feet of Block 8, Hakanson Subdivision, according to plat thereof recorded in Map Book 4, Page 521 of the records in the Office of the Judge of Probate of Mobile County, Alabama.. Property street address for informational purposes: 2057 Faye St, Mobile, AL 36605. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. PNC Bank National Association, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223

www.tblaw.com

TB File Number: 23-06456

Call News 10/11/2023, 10/18/2023, 10/25/2023

NOTICE OF FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Thomas C. Malone, Jr. and Cathey E. Ready, to Mortgage Electronic Registration Systems, Inc., as Mortgagee, as nominee for Stearns Lending, LLC, its successors and assigns, on July 25, 2014, said mortgage being recorded in the Office of the Judge of Probate of Mobile County, Alabama, on August 15, 2014 at Book LR7178, at Page 99, as Document Number 2014041037. Freedom Mortgage Corporation, the current holder, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Mobile County Courthouse, in Mobile, Alabama, on November 9, 2023, during the legal hours of sale, the following described real estate, situated in Mobile County, Alabama, to-wit:

LOTS 5 AND 6 OF MURRAY ESTATES, AN UNRECORDED SUBDIVISION PLAT, PROPERTY BEING MORE PARTICULARLY DESCRIBED AS FOLLOWS: COMMENCING AT THE NORTHWEST CORNER OF SOUTHWEST QUARTER OF SECTION 36, TOWNSHIP 6 SOUTH, RANGE 3 WEST, MOBILE COUNTY, ALABAMA, THENCE RUN NORTH 89 DEGREES 47 MINUTES 33 SECONDS EAST 1945.94 FEET TO THE POINT OF BEGINNING OF THE PROPERTY HEREIN DESCRIBED; THENCE CONTINUING NORTH 89 DEGREES 47 MINUTES 33 SECONDS EAST 225.78 FEET TO A POINT, THENCE RUN NORTH 89 DEGREES 47 MINUTES 10 SECONDS EAST 79.29 FEET TO A POINT; THENCE RUN SOUTH 00 DEGREES 05 MINUTES 46 SECONDS WEST 605.19 FEET TO A POINT ON THE NORTH LINE OF MURRAY ROAD, (HAVING A RIGHT OF WAY OF 60 FEET), THENCE RUN SOUTH 89 DEGREES 55 MINUTES 31 SECONDS WEST ALONG SAID NORTH LINE 304.84 FEET TO A POINT; THENCE RUN NORTH 00 DEGREES 04 MINUTES 30 SECOND EAST 604.47 FEET TO THE POINT OF BEGINNING.

THIS CONVEYANCE IS MADE SUBJECT TO THE FOLLOWING:

ANY CLAIM ARISING BY REASON OF FENCE BEING LOCATED INSIDE AND OUTSIDE TRUE PROPERTY LINES AS SHOWN ON PLAT OF SURVEY BY POLYSURVEYING OF MOBILE DATED SEPTEMBER 28, 1995.
DIFFERENCE BETWEEN RECORD AND ACTUAL DISTANCES AND/OR BEARINGS ALONG ALL PROPERTY LINES AS SHOWN ON PLAT OF SURVEY BY POLYSURVEYING OF MOBILE DATED SEPTEMBER 28, 1995
ANY AND ALL RESTRICTIONS, EASEMENTS, RIGHTS OF WAY, RESERVATIONS OR OTHER EXCEPTIONS WHICH MAY BE OF PUBLIC RECORD AFFECTING SAID PROPERTY.

TOGETHER WITH ALL AND SINGULAR THE RIGHTS, MEMBERS, PRIVILEGES AND APPURTENANCES THEREUNTO BELONGING, OR IN ANYWISE APPERTAINING.

More commonly known as: 8222 Murray Rd, Irvington, AL 36544

Freedom Mortgage Corporation (“Transferee”)

Halliday, Watkins & Mann, P.C.

244 Inverness Center Drive

Birmingham, AL 35242

Phone: (801) 355-2886

Call News October 11, 2023, October 18, 2023, October 25, 2023

FORECLOSURE NOTICE

Default having been made in the payment of the indebtedness described in and secured by that certain Mortgage executed by ELIJAH HOUSE, INC. dated September 30, 2020 and recorded as Instrument No. 2020060909 Probate Records of Mobile County, Alabama to Thames, Jackson, Harris Company, Inc.; said Mortgage was thereafter assigned to Curtis Wilson, Jr. by instrument dated October 6, 2020 and recorded as Instrument No. 2020061559 of the aforesaid Probate Court Records; and the undersigned holder of said mortgage having declared the entire indebtedness due and payable notice is hereby given that the undersigned, under and by virtue of the powers contained in said mortgage, will sell at public outcry for cash to the highest bidder during the legal hours of sale on the 6th day of NOVEMBER, 2023, at the front or main door of the Government Street entrance of Government Plaza, the Courthouse of Mobile County Alabama, , the following described real property lying and being situated in the County of Mobile, State of Alabama, to-wit:

PARCEL A

Lots 23, 24, 25 and 26, Houston Street, Second Extension, according to plat thereof recorded in Map Book 3, Page 477 of the records in the Office of the Judge of Probate of Mobile County, Alabama.

PARCEL B

Lot 1, Elijah House Subdivision, according to plat thereof recorded in Map Book 121, Page 45 of the records in the Office of the Judge of Probate, Mobile County, Alabama.

Said sale is made for the purpose of paying the indebtedness secured by said Mortgage and all charges as provided therein and the expense incident thereto, including a reasonable attorney’s fee.

Said property will be sold on an “as is, where is” basis subject to any easements, encumbrances, and exceptions contained in said mortgage and those contained in the records of the Office of the Judge of Probate where the above-described property is situated. Said property will be sold without warranty or recourse, expressed or implied as to title, use and/or enjoyment, and will be sold subject to the right of redemption of all parties entitled thereto.

ALABAMA LAW GIVES SOME PERSONS WHO HAVE AN INTEREST IN PROPERTY THE RIGHT TO REDEEM THE PROPERTY UNDER CERTAIN CIRCUMSTANCES. PROGRAMS MAY ALSO EXIST THAT HELP PERSONS AVOID OR DELAY THE FORECLOSURE PROCESS. AN ATTORNEY SHOULD BE CONSULTED TO HELP YOU UNDERSTAND THESE RIGHTS AND PROGRAMS AS A PART OF THE FORECLOSURE PROCESS.

CURTIS WILSON, JR.

Holder of said Mortgage

JIM H. FERNANDEZ

FERNANDEZ, CRANE & COMBS, L.L.C.

Attorneys for Holder of said Mortgage

Post Office Box 162

Mobile, Alabama 36601 / (251) 433-0738

Call News October 18, 2023, October 25, 2023 and November 1, 2023

FORECLOSURE NOTICE

Default having been made in the payment of the indebtedness described in and secured by that certain mortgage executed by ARTEMISE A. SAVAGE aka ARTEMISE N. WALKER, unmarried, as Mortgagor(s) to Regions Bank, as Mortgagee, dated the 4th day of August, 2017, and recorded in Book LR7543, Page 1413, et seq. of the records in the Office of the Judge of Probate Court of Mobile County, Alabama; said default continuing, notice is hereby given that the undersigned will, under and by virtue of the power of sale contained in said mortgage sell at public outcry for cash to the highest bidder during legal hours of sale, on the 7th day of November, 2023, in the city of Mobile, at the front door of the Court House of Mobile County, Alabama, the following described real property situated in the County of Mobile, State of Alabama, to-wit:

ALL OF THAT REAL PROPERTY LOCATED IN THE COUNTY OF MOBILE, STATE OF ALABAMA, WHICH IS DESCRIBED AS FOLLOWS: LOT 20, BLOCK C, EDGEWOOD PARK SUBDIVISION, ACCORDING TO PLAT THEREOF RECORDED IN MAP BOOK 5, PAGES 69-72 OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA. SUBJECT TO RESTRICTIONS, RESERVATIONS, EASEMENTS, COVENANTS, OIL, GAS OR MINERAL RIGHTS OF RECORD, IF ANY.

This property will be sold on an “as is, where is” basis, subject to any easements, encumbrances, reservations and exceptions reflected in the mortgage and/or those contained in the records of the office of the Judge of Probate of the county where the above-described property is situated. This property will be sold without warranty or recourse, expressed or implied as to title, use and/or enjoyment and will be sold subject to the right of redemption of all parties entitled thereto. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.

Said sale will be made for the purpose of paying said indebtedness and the expenses incident to this sale, including a reasonable attorney’s fee, and the other purposes set out in said mortgage. The sale will be conducted subject to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and also to final confirmation and audit of the status of the loan with the Mortgagee.

REGIONS BANK

Holder of said Mortgage

Goodman G. Ledyard

PIERCE LEDYARD JOHNSTON, P.C.

Attorneys for Mortgagee

Post Office Box 161389

Mobile, Alabama 36616

(251) 338-1300

Call News October 11, 18, 25, 2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Rose Ellen Stanbery and Lester J. Stanbery, Jr., husband and wife, originally in favor of Mortgage Electronic Registration Systems, Inc., acting solely as nominee for American Advisors Group, on March 21, 2018, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in BK: LR7619 Pg: 1503; the undersigned Carrington Mortgage Services LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on December 13, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 9, Square 2 of Flo-Claire, on South side of Government Street West of Catherine Street, according to the plat thereof recorded in Deed Book 137 NS, Page 272 of the records in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 262 McDonald Ave , Mobile, AL 36604. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Carrington Mortgage Services LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223

www.tblaw.com

TB File Number: 23-06775

Call News 10/11/2023, 10/18/2023, 10/25/2023

NOTICE OF SALE UNDER POWER

FORECLOSURE NOTICE

WHEREAS, default has occurred in the performance of the covenants, terms and conditions of a mortgage from JEFFERY K STANLEY AND SPOUSE, LORI A STANLEY to Compass Bank, on the 6th day of October, 2004, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, on October 19, 2004, in Deed/Mortgage Book 5674, Page 576, Mobile County, Alabama Records, said Mortgage having subsequently been transferred and assigned to Interstate Intrinsic Value Fund A LLC, by instrument recorded in the aforesaid Probate Office; notice is hereby given that the undersigned Interstate Intrinsic Value Fund A LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash in front of the main entrance of the Courthouse in Mobile, Mobile County, Alabama, on November 15, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:

LOT 7, ROBINS HEIGHTS, FIRST UNIT, ACCORDING TO PLAT THEREOF RECORDED IN MAP BOOK 20, PAGE 80 OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA.

Said legal description being controlling, however the property is more commonly known as 3131 GRAHAM RD, MOBILE, AL 36618.

Interstate Intrinsic Value Fund A LLC, Mortgagee/Transferee

THE BELOW LAW FIRM MAY BE HELD TO BE ACTING AS A DEBT COLLECTOR, UNDER FEDERAL LAW. IF SO, ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.

Rubin Lublin, LLC, Attorney for Mortgagee/Transferee

11 N. Water Street, Suite 10290, Mobile, AL 36602

Telephone Number: (877) 813-0992 Case No. PHL-23-04217-1

rlselaw.com/property-listing

Call News 10/11/2023, 10/18/2023, 10/25/2023

NOTICE OF MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain Commercial Mortgage, Security Agreement and Assignment of Leases and Rents dated December 17, 2020, granted by GLOBAL INSPECTIONS PROPERTIES LLC, an Alabama limited liability company (the “Mortgagor”), in favor of BancorpSouth Bank, a Mississippi state chartered bank (now known as Cadence Bank) (“Mortgagee”), and recorded on December 28, 2020 in the Office of the Judge of Probate of Mobile County, Alabama (the “Recording Office”), at Instrument Number 2020078728 (the “Mortgage”), please take notice that the Mortgagee, the owner of said Mortgage and the indebtedness secured thereby, under and by virtue of the power of sale contained in said Mortgage, will sell by public outcry to the highest bidder for cash, in front of the main entrance of the Mobile County, Alabama Courthouse located at 205 Government Street, Mobile, Alabama 36602, on the 1st day of November 2023, at 12:00 p.m. (Central), the following described real estate (the “Real Estate”) situated in Mobile County, Alabama, to-wit:

LOT 17, ALVAREZ’S SECOND ADDITION TO SARALAND, ACCORDING TO PLAT THEREOF RECORDED IN MAP BOOK 9, PAGE 249 OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA

This sale is conducted for the purpose of paying the indebtedness secured by the Mortgage and all expenses incident to this sale, including reasonable attorneys’ fees.

The Real Estate will be sold on an “AS IS, WHERE IS” basis subject to all easements, encumbrances, and exceptions contained in the Mortgage and those contained in the records of the Recording Office as of the date of the recordation of the Mortgage. The Real Estate will be sold without warranty or recourse, expressed or implied as to title, use and/or enjoyment and will be sold subject to the right of redemption of all parties entitled thereto.

Please take further notice that pursuant to Section 7-9A-604 et seq. of the Code of Alabama, 1975 (the “Alabama Uniform Commercial Code”), Mortgagee will also sell at the public sale, for cash, the property described below. The sale will be held to enforce the rights of the Mortgagee with respect to indebtedness owed to the Mortgagee by Mortgagor under that certain One Year Adjustable Term Note dated December 17, 2020, in the principal amount of $76,000.00 executed by Mortgagor payable to the order of Mortgagee (the “Note”), which indebtedness is secured by, among other things, the Real Estate and other property described in the Mortgage.

Specifically, the Mortgagee will sell the Mortgagor’s entire right, title and interest in and to the following property (collectively, the “Collateral”) in which Mortgagee was granted a security interest pursuant to the terms of the Mortgage:

The following categories of assets as defined in the Uniform Commercial Code: goods (including inventory, equipment, and any accessions thereto), instruments (including promissory notes), documents, accounts (including health-care-insurance receivables), chattel paper (whether tangible or electronic), deposit accounts, letter-of-credit rights (whether or not the letter of credit is evidenced by a writing), securities and all other investment property, general intangibles (including payment intangibles and software), supporting obligations and any and all proceeds of any thereof, whether now owned or hereafter acquired [by Mortgagor], that are located on or used in connection with, or that arise in whole or in part out of the Mortgagor’s use of or business conducted on or respecting, the [Real Estate] and any substitutions, replacements, accessions and proceeds of any of the foregoing.

The Collateral will be offered for sale in bulk and/or in individual lots, at Mortgagee’s election. The Collateral will be offered for sale together with the Real Estate and/or separate from the Real Estate, at Mortgagee’s election.

Persons interested in viewing or inspecting the Collateral during normal business hours or who have questions regarding the proposed public sale of the Collateral may contact Cathleen C. Moore, at telephone number (205) 521-8301.

The public sale of the Collateral will take place in front of the main entrance of the Mobile County, Alabama Courthouse located at 205 Government Street, Mobile, Alabama 36602, on the 1st day of November 2023, contemporaneously with or beginning immediately following the foreclosure sale of the Real Estate as described above.

The Collateral will be sold “AS IS” and with all faults, without recourse against the Mortgagee, and with no express or implied warranties with respect to fitness for any particular purpose, merchantability, title, or otherwise.

Payment terms for the sale of the Real Estate and the Collateral are cash or cashier’s check (United States Dollars in immediately available funds) made payable to Mortgagee and delivered to Mortgagee on the date of the public sale.

The Mortgagee reserves the right to bid for and purchase the Real Estate and/or the Collateral and to credit its purchase price against the expenses of sale and the indebtedness secured by the Mortgage, as provided by the terms of the Mortgage.

The foreclosure sale is subject to postponement or cancellation. Contact the person named below prior to attendance.

CADENCE BANK, formerly known as BancorpSouth Bank

Cathleen C. Moore

Bradley Arant Boult Cummings LLP

One Federal Place

1819 Fifth Avenue North

Birmingham, Alabama 35203-2104

(205) 521-8301

Attorney for Mortgagee

Call News October 11, 2023, October 18, 2023, and October 25, 2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by John A. O’Gwynn, Jr. aka John A O’Gwynn, a single man, originally in favor of Mortgage Electronic Registration Systems, Inc., solely as nominee for Quicken Loans, LLC, on November 24, 2020, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Instrument No. 2020075746; the undersigned Rocket Mortgage, LLC f/k/a Quicken Loans, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 16, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 48, Jefferson Acres Subdivision, according to plat thereof recorded in Map Book 9, Page 301 of the records in the Office of the Judge of probate, Mobile County, Alabama.. Property street address for informational purposes: 8405 Cindy Lou Dr, Theodore, AL 36582. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Rocket Mortgage, LLC f/k/a Quicken Loans, LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223

www.tblaw.com

TB File Number: 23-07021

Call News 10/11/2023, 10/18/2023, 10/25/2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Annie M. Willliams aka Annie Steele, an unmarried woman, originally in favor of Mortgage Electronic Registration Systems, Inc. solely as nominee for Consumer First Mortgage, Inc., on June 10, 2009, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 6544 Page 1273 and modified in Book 7315 Page 1446; the undersigned MidFirst Bank, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 30, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 17 and the East half of Lot 18, Block 2, George’s Subdivision, according to plat thereof recorded in Deed Book 120, Page 44 of the records in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 609 E Elm St , Prichard, AL 36610. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. MidFirst Bank, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223

www.tblaw.com

TB File Number: 23-07122

Call News 10/11/2023, 10/18/2023, 10/25/2023

FORECLOSURE NOTICE

Default having been made in the payment of the indebtedness described in and secured by that certain mortgage executed by PEARIS F. HOWARD aka PEARIS FITZGERALD HOWARD aka PEARIS HOWARD, an unmarried man, as Mortgagor(s) to Regions Bank, as Mortgagee, dated the 21st day of January, 2021, and recorded in Instrument No. 2021006742 et seq. of the records in the Office of the Judge of Probate Court of Mobile County, Alabama; said default continuing, notice is hereby given that the undersigned will, under and by virtue of the power of sale contained in said mortgage sell at public outcry for cash to the highest bidder during legal hours of sale, on the 7th day of November, 2023, in the city of Mobile, at the front door of the Court House of Mobile County, Alabama, the following described real property situated in the County of Mobile, State of Alabama, to-wit:

THE FOLLOWING LANDS AND PROPERTY, TOGETHER WITH ALL IMPROVEMENTS LOCATED THEREON. LYING IN MOBILE COUNTY. AL TO WIT: LOT 22SPICE POND PINES, UNIT ONE, ACCORDING TO THE PLAT THEREOF RECORDED IN MAP BOOK 56, PAGE 106 OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY. ALABAMA. SUBJECT TO: 1. BUILDING SETBACK LINE(S) AND EASEMENT(S) AS SHOWN ON RECORDED PLAT OF SUBDIVISION. 2. RESTRICTIVE COVENANTS CONTAINED IN INSTRUMENT(S) RECORDED IN REAL PROPERTY BOOK 4047 PAGE 492; REAL PROPERTY BOOK 4041, PAGE 1533 AND REAL PROPERTY BOOK 4253 PAGE 329(BUT OMITTING ANY COVENANT OR RESTRICTION BASED ON RACE, COLOR, RELIGION, SEX, HANDICAP, FAMILIAL STATUS OR NATIONAL ORIGIN.) 3. 30 FOOT ALABAMA POWER COMPANY EASEMENT AS SHOWN ON RECORDED PLAT OF SAID SUBDIVISION. 4. RESERVATION(S) OF OIL, GAS AND MINERALS CONTAINED IN INSTRUMENT(S) RECORDED IN REAL PROPERTY BOOK 4047, PAGE 492; REAL PROPERTY BOOK 4253. PAGE 329 AND REAL PROPERTY BOOK 512. PAGE 146. 5. EASEMENT(S) GRANTED ALABAMA POWER COMPANY BY INSTRUMENT(S) RECORDED IN DEED BOOK 557, PAGE 321 AND REAL PROPERTY BOOK 650PAGE 692. 6. CONVEYANCE OF OIL, GAS AND MINERALS RECORDED IN REAL PROPERTY BOOK 3225 PAGE 825: REAL PROPERTY BOOK 3225, PAGE 827 AND REAL PROPERTY BOOK 1427, PAGE 911. 7. OIL, GAS AND MINERAL LEASE(S) RECORDED IN REAL PROPERTY BOOK 3224 PAGE 180. 8. RIGHT(S) OF WAY GRANTED MOBILE COUNTY BY INSTRUMENT(S) RECORDED IN REAL PROPERTY BOOK 3680. PAGE 316 AND REAL PROPERTY BOOK 3680, PAGE 318. 9. TERMS. CONDITIONS. OBLIGATIONS AND REQUIREMENTS SET FORTH IN THE ARTICLES OF INCORPORATION OF SPICE POND PINES PROPERTY OWNERS ASSOCIATION RECORDED IN REAL PROPERTY BOOK 4041 PAGE 1503. AND RULES AND REGULATIONS CURRENTLY EXISTING OR WHICH MAY BE IMPOSED FROM TIME TO TIME BY SAID ASSOCIATION THIS BEING THE SAME PROPERTY CONVEYED TO PEARIS F. HOWARD DATED 04/10/2002 AND RECORDED ON 04/12/2002 IN BOOK 5145, PAGE 1143. IN THE MOBILE COUNTY RECORDERS OFFICE. PARCEL NO18 09 310 000 010.022.

REGIONS BANK

Holder of said Mortgage

Goodman G. Ledyard

PIERCE LEDYARD JOHNSTON, P.C.

Attorneys for Mortgagee

Post Office Box 161389

Mobile, Alabama 36616

(251) 338-1300

Call News October 11, 18, 25 and November 1, 2023

NOTICE OF

MORTGAGE FORECLOSURE SALE

STATE OF ALABAMA

COUNTY OF MOBILE

Default having been made of the terms of the loan documents secured by that certain mortgage executed by Eric D Karlstad to Mortgage Electronic Registration Systems, Inc., as mortgagee, as nominee for Renasant Bank, its successors and assigns dated November 23, 2020; said mortgage being recorded on December 3, 2020, as Instrument No. 2020073355 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to Renasant Bank in Instrument 2023002604 in the Office of the Judge of Probate of Mobile County, ALABAMA.

The undersigned, Renasant Bankunder and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 1st day of November, 2023 the following property, situated in Mobile County, Alabama, to-wit:

Lots 56 and 57, Jefferson Acres Subdivision, according to map or plat thereof recorded in Map Book 9, Page 301 of the records in the Office of the Judge of Probate of Mobile County, Alabama.

Said property is commonly known as 5470 Robert Jefferson Dr E, Theodore, AL 36582.

Should a conflict arise between the property address and the legal description the legal description will control.

RENASANT BANK

as holder of said mortgage

McCalla Raymer Leibert Pierce, LLC

Two North Twentieth

2 20th Street North, Suite 1000

Birmingham, AL 35203

(205) 216-4238

FT21@mccalla.com

File No. 23-05184AL

www.foreclosurehotline.net

Call News 10/04/2023,10/11/2023,10/18/2023, 10/25/2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed on February 25, 2010 by Brandi Powell Stuart, an unmarried woman, originally in favor of Mortgage Electronic Registration Systems, Inc. as nominee for Coastal Community Bank dba Coastal Community Mortgage, A Corporation, and recorded in Book 6631 at Page 718 on March 3, 2010, and modified in and modified by agreement recorded May 12, 2023 in Instrument Number 2023030012, in the Office of the Judge of Probate of Mobile County, Alabama, and secured indebtedness having been transferred or assigned to Truist Bank, successor by merger to Suntrust Bank as reflected by instrument recorded in 2023000515 of the same Office. LOGS Legal Group LLP, as counsel for Mortgagee or Transferee and under and by virtue of power of sale contained in the said mortgage will, on December 7, 2023, sell at public outcry to the highest bidder at the main entrance of the Mobile County, Alabama, Courthouse in the City of Mobile, during the legal hours of sale, the following real estate situated in Mobile County, Alabama, to wit:

Lot 42, Stonewall Park, according to plat thereof recorded in Map Book 107, Page 41 and re-recorded in Map Book 107, Pages 58-59 of the records in the office of the Judge of Probate, Mobile County, Alabama.

For informational purposes only, the property address is: 5509 Travellers Ct, Satsuma, AL 36572.

Any property address provided is not part of the legal description of the property sold herein and in the event of any discrepancy, the legal description referenced herein shall control.

Truist Bank, successor by merger to Suntrust Bank, and its successors and assigns

Mortgagee or Transferee

LOGS LEGAL GROUP LLP

10130 Perimeter Parkway, Suite 400

Charlotte, NC 28216

704-333-8107/ 22-022361

Attorneys for Mortgagee or Transferee

Call News October 11, 2023 and October 18, 2023 and October 25, 2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed on March 23, 2010 by Tray Forister, an unmarried man and Amy Baker, an unmarried woman, originally in favor of Mortgage Electronic Registration Systems, Inc., as nominee for MortgageAmerica, Inc, and recorded in 6638 at 1961 on March 26, 2010, in the Office of the Judge of Probate of Mobile County, Alabama, and secured indebtedness having been transferred or assigned to Wells Fargo Bank, N.A. as reflected by instrument recorded in LR7251, Page 1972 of the same Office. LOGS Legal Group LLP, as counsel for Mortgagee or Transferee and under and by virtue of power of sale contained in the said mortgage will, on November 20, 2023, sell at public outcry to the highest bidder at the main entrance of the Mobile County, Alabama, Courthouse in the City of Mobile, during the legal hours of sale, the following real estate situated in Mobile County, Alabama, to wit:

That real property situated in the County of Mobile, State of Alabama, described as follows, to-wit:

Lot 12, Block 3, Map of Tennessee Coal, Iron and Railroad Company’s First Addition to Chickasaw Bogue Subdivision, according to plat thereof recorded in Map Book 5, pages 93¬96 of the records in the office of the Judge of Probate, Mobile County, Alabama.

For informational purposes only, the property address is: 309 Valley Road, Chickasaw, AL 36611.

Any property address provided is not part of the legal description of the property sold herein and in the event of any discrepancy, the legal description referenced herein shall control.

Wells Fargo Bank, N.A., and its successors and assigns

Mortgagee or Transferee

LOGS LEGAL GROUP LLP

10130 Perimeter Parkway, Suite 400

Charlotte, NC 28216

704-333-8107/ 23-023078

Attorneys for Mortgagee or Transferee

Call News October 11, 2023 and October 18, 2023 and October 25, 2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Debera F. Adams to Mortgage Electronic Registration Systems, Inc., as nominee for Nationstar Mortgage LLC d/b/a Mr. Cooper, dated October 3, 2017 said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book LR7569, Page 278 . Said mortgage was subsequently sold, assigned and transferred to NewRez LLC d/b/a Shellpoint Mortgage Servicing. Under and by virtue of the power of sale contained in said mortgage, the undersigned, NewRez LLC d/b/a Shellpoint Mortgage Servicing, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse in Mobile County, Alabama on November 16, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following describe real estate situated in Mobile County, Alabama, to-wit: LOT 35, BEAU TERRA SUBDIVISION, UNIT NO. 5-A, ACCORDING TO PLAT THEREOF RECORDED IN MAP BOOK 11, PAGE 91 IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA. EXCEPTING THEREFROM SUCH OIL, GAS AND OTHER MINERALS IN, ON AND UNDER SAID REAL PROPERTY, TOGETHER WITH ALL RIGHTS IN CONNECTION THEREWITH, AS HAVE PREVIOUSLY BEEN RESERVED BY OR CONVEYED TO OTHERS THAN THE GRANTOR. Property Street Address for Informational Purposes: 2116 Beau Terra Drive W Mobile AL 36618 Said property will be sold “AS IS”. NO REPRESENTATION OR WARRANTY, EXPRESSED OR IMPLIED, IS MADE AS TO THE TITLE OF SAID PROPERTY. Said property is subject to any title deficiencies including but not limited to: any outstanding ad valorem taxes – including taxes which are a lien but not yet due and payable, federal tax liens any matters which might be disclosed by an accurate survey and inspection of the property, any assessments liens, encumbrances, zoning ordinances, restrictions, covenants, and matters of record superior to the Mortgage first set out above. Said property will be sold subject to the right of redemption of all parties entitled thereto. The highest bidder must tender the total amount of the winning bid in certified funds at the time and place of sale. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand the rights and programs as a part of the foreclosure process. This sale will be made for the purpose of paying the same and all expenses of this sale, as provided in said Mortgage and by Alabama law. This sale is subject to postponement or cancellation. **This is an attempt to collect a debt and any information obtained may be used for that purpose.** NewRez LLC d/b/a Shellpoint Mortgage Servicing, Mortgagee or Transferee Jonathan Smothers, Esq ALAW One Independence Plaza, Suite 416 Birmingham, AL 35209 Attorney for Mortgagee/Transferee 22-013784 A-4797956

Call News 10/11/2023, 10/18/2023, 10/25/2023

NOTICE OF

MORTGAGE FORECLOSURE SALE

STATE OF ALABAMA

COUNTY OF MOBILE

Default having been made of the terms of the loan documents secured by that certain mortgage executed by Fernando Antonio Ramos A/K/A Fernando Ramos Sole Ownership to Mortgage Electronic Registration Systems, Inc., as mortgagee, as nominee for Caliber Home Loans, Inc., its successors and assigns dated May 11, 2017; said mortgage being recorded on May 23, 2017, in Book LR7512, Page 1257 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to NewRez LLC d/b/a Shellpoint Mortgage Servicing in Instrument 2023007107 in the Office of the Judge of Probate of Mobile County, ALABAMA.

The undersigned, NewRez LLC d/b/a Shellpoint Mortgage Servicing

under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 9th day of November, 2023 the following property, situated in Mobile County, Alabama, to-wit:

Lot 2, Aden Hills Subdivision, Unit One, according to the plat thereof recorded in Map Book 25, page 87, in the Office of the Judge of Probate, Mobile County, Alabama.

Said property is commonly known as 1832 Aden Rd, Mobile, AL 36695.

Should a conflict arise between the property address and the legal description the legal description will control.

NEWREZ LLC D/B/A SHELLPOINT MORTGAGE SERVICING

as holder of said mortgage

McCalla Raymer Leibert Pierce, LLC

Two North Twentieth

2 20th Street North, Suite 1000

Birmingham, AL 35203

(205) 216-4238

FT21@mccalla.com

File No. 23-05245AL

www.foreclosurehotline.net

Call News 10/04/2023,10/11/2023,10/18/2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Jacob Glen Johnson an unmarried man, originally in favor of Mortgage Electronic Registration Systems, Inc. acting solely as nominee for Magnolia Mortgage Company LLC, on December 5, 2017, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book LR7582 Page 1512 and modified in Instrument No. 2021035837 and Instrument No. 2022069942; the undersigned PennyMac Loan Services, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 9, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: That certain parcel of land bounded by a line beginning at a point on the West line of Block 3, in the town of Citronelle, a distance of 769 feet South of the Northwest corner of said Block 3, thence run East and parallel with Lebaron Ave. a distance of 220 feet, more or less to a point on the West line of Thompson Drive a public road heretofore conveyed by Harold Jernigan to the Town of Citronelle by instrument dated May 3rd, 1961 and recorded in Real Property Book 260, Page 564 of the records in the Office of the Judge of Probate Court of Mobile County, Alabama, thence run South and parallel with said Thompson Drive a distance of 100 feet to a point, thence run West and parallel with Lebaron Ave, a distance of 220 feet, more or less to a point on the West line of said Block 3, thence running North along the West line of said Block 3 a distance of 100 feet to the Point of Beginning. Property street address for informational purposes: 19225 Thompson Drive , Citronelle, AL 36522. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. PennyMac Loan Services, LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223

www.tblaw.com

TB File Number: 23-06953

Call News 10/04/2023, 10/11/2023, 10/18/2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Leslie Monique Young, an unmarried woman, originally in favor of Mortgage Electronic Registration Systems, Inc. solely as nominee for Mortgage Team 1, on April 30, 2021, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Instrument No. 2021030116; the undersigned Nationstar Mortgage LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 15, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 52, Park Forest Estates, as recorded in Map Book 10, Page 264 of the Probate Records of Mobile County, Alabama.. Property street address for informational purposes: 914 Graymont Dr , Mobile, AL 36608. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Nationstar Mortgage LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223

www.tblaw.com

TB File Number: 23-06648

Call News 10/04/2023, 10/11/2023, 10/18/2023

STATE OF ALABAMA

COUNTY OF MOBILE

NOTICE OF MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage and security agreement executed by SOMPHETH MIXAY and PHONGPHETH MIXAY, a married couple, on the 20th day of October 2022, to 21ST MORTGAGE CORPORATION, as recorded in Inst. # 2022068525 in the office of the Probate Judge of Mobile County, Alabama; 21ST MORTGAGE CORPORATION, as Mortgagee, by reason of such default having declared all of the indebtedness secured by said mortgage and security agreement due and payable and such default continuing, notice is hereby given that, acting under the power of sale contained in said mortgage and security agreement, and as authorized by Section 7-9A-604(a)(2) of the Code of Alabama of 1975 as amended, 21ST MORTGAGE CORPORATION, as Mortgagee, will sell at public outcry, for cash to the highest bidder, in front of the Courthouse door, in the City of Mobile, Mobile County, Alabama, during the legal hours of sale on October 25, 2023, the following described real and personal property situated in Mobile County, Alabama, to-wit:

Lot 42, Beverly Gardens, Unit Three, according to plat thereof recorded in Instrument No. 2022027392 of the records in the Office of the Judge of Probate, Mobile County, Alabama.

INCLUDING a security interest in one (1) 2022 CMH 32’ x 80’ manufactured home, Serial Nos. WHC027425GAA and WHC027425GAB;

together with the hereditaments and appurtenances thereunto belonging and all fixtures now attached to and used in connection with the premises herein described.

Said sale will be made subject to any existing Federal Tax Lien, if any, and/or Special Assessments, if any, which might adversely affect the title to the subject property.

Said sale will be made for the purpose of paying the indebtedness secured by the above-described mortgage, and the proceeds thereof will be applied as provided by the terms of the said mortgage. This sale is subject to postponement or cancellation; contact Margery Oglesby at the phone number shown below prior to attending the sale.

Kristofor D. Sodergren

Attorney for 21st Mortgage Corporation

ROSEN HARWOOD, P.A.

2200 Jack Warner Pkwy Ste 200

P.O. Box 2727

Tuscaloosa, AL 35403

(205) 344-5000

Call News October 4, October 11, and October 18, 2023

FORECLOSURE NOTICE

Default having been made in the payment of the indebtedness described in and secured by that certain Vendors Lien Deed executed by Shannon Blackwell, Jr and Deanna Richardson, husband and wife, to Powers Real Estate Joint Venture LLC, an Alabama Limited Liability Company, dated April 9th, 2021, and recorded in Instrument Number: 2021024497 of the records in the Office of the Judge of Probate, Mobile County, Alabama; and said default continuing; notice is hereby given that the undersigned will, under and by virtue of the power of sale contained in said Vendors Lien Deed, sell at public outcry for cash, at the Government Street entrance of the Mobile County Courthouse at 205 Government Street, Mobile, Alabama, to the highest bidder, on October 26th, 2023, during the legal hours of sale, the following described real property situated in the County of Mobile, State of Alabama, to-wit:

Lot A, Deerwood Hills, Unit Two, according to plat thereof recorded in Map Book 46, Page 40, of the records in the Office of the Judge of Probate of Mobile County, Alabama. Raw Land

SUBJECT TO:

Except therefrom such oil, gas and other minerals in, on and under said real property, together with all rights in connection therewith, as have previously been reserved by or conveyed to others than the grantor.
Easements, reservations, restrictions, rights-of-way and setback lines as reserved and shown on record Map of subdivision.
All matters of Public record including any utility easement as recorded in the Office of the Judge of Probate, Mobile County, Alabama.
Any prior reservations or conveyance of minerals, together with release of damages of minerals of every kind and character, including but not limited to oil and gas in, on and under subject property.
No Penalty for Pre-Payment.
Purchaser is hereby notified and responsible for adhering to all governmental regulations concerning perc test, wetlands, and any stipulation the law requires and agrees to hold seller and agents harmless from any claims arising from such regulations.
Property is sold “AS IS” “WHERE IS” with no warranties expressed or implied.
2023 Taxes are due and payable as of October 1, 2023.

Said sale will be made for the purpose of paying said indebtedness and the expenses incidental to said sale, including a reasonable attorney’s fee.

POWERS REAL ESTATE JOINT VENTURE LLC, an Alabama Limited Liability Company as holder of said Vendors Lien Deed

William C. Poole, LLC

Attorneys at Law

917 Western America Circle

Suite 210

Mobile, Alabama 36609

(251) 344-5015

THIS IS AN ATTEMPT TO COLLECT A DEBT ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.

Call News October 4, 11, 18, 2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Mondy M. Reem, single woman, originally in favor of Mortgage Electronic Registration Systems, Inc. (“MERS”), as mortgagee, as nominee for Advance Mortgage & Investment Company, LLC, on October 22, 2019, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Instrument Number 2019062231; the undersigned Freedom Mortgage Corporation, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 20, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 4, Shenandoah, Phase 4, according to plat thereof recorded in Map Book 83, Page 48, of the records in the Office of the Judge of Probate of Mobile County, Alabama.. Property street address for informational purposes: 3381 Dubose Ave , Semmes, AL 36575. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Freedom Mortgage Corporation, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223

www.tblaw.com

TB File Number: 23-06794

Call News 10/04/2023, 10/11/2023, 10/18/2023

FORECLOSURE NOTICE

Default having been made in the payment of the indebtedness described in and secured by that certain Vendors Lien Deed executed by Michael Johnson and Aneesah Johnson, husband and wife, to Power Real Estate, Inc., An Alabama Corporation dated March 17th, 2023, and recorded in Instrument Number 2023015663, of the records in the Office of the Judge of Probate, Mobile County, Alabama; and said default continuing; notice is hereby given that the undersigned will, under and by virtue of the power of sale contained in said Vendors Lien Deed, sell at public outcry for cash, at the Government Street entrance of the Mobile County Courthouse at 205 Government Street, Mobile, Alabama, to the highest bidder, on October 26th, 2023, during the legal hours of sale, the following described real property situated in the County of Mobile, State of Alabama, to-wit:

Lot 75, Bridgewater, Unit Two, according to plat thereof recorded in Map Book 124, Page 100 of the records in the Office of the Judge of Probate of Mobile County, Alabama.

SUBJECT TO:

The lien for taxes hereafter falling due.
All existing easements and rights of way and utility easement as recorded in Mobile County Probate.
All building setback lines and restrictive covenants of record.
Title to minerals within and underlying the premises, together with all mining rights and other rights privileges and immunities relating thereto as recorded in Deed Book 610, Page 676 and Deed Book 614, Page 343.
Bridgewater Unit 11 Restrictive Covenants filed in Real Property Book 6705, Page 0041-0048.
Articles of Incorporation of Bridgewater, Unit One Property Owners’ Association, Inc., as contained in Instrument recorded in Real Property Book 6422, Page 879; and amendments modified in Real Property Book LR7521, Page 625, Instrument # 2017033779.
Easement granted Century Tel of Alabama, LLC as contained in instrument recorded in Real Property Book 6705, Page 54.
25’ Non-Exclusive easement for ingress and egress as noted on plat of Bridgewater Unit 11 for Bridgewater Drive and Bridgewater Drive East and Bridgewater Drive South and Easement and right of way deed for Bridgewater Drive of Unit 1 as recorded in Real Property Book 6705, Page 50, all are private roads.
Except therefrom such oil, gas and other minerals in, on and under said real property, together with all rights in connection therewith, as have previously been reserved by or conveyed to others than the grantor.
Easements, reservations, restrictions, rights-of-way and setback lines as reserved and shown on record Map of subdivision.
All matters of Public record including any utility easements as recorded in the Office of the Judge of Probate, Mobile County, Alabama.
Property is sold “AS IS” “WHERE IS” with no warranties expressed or implied.
Property has up to a 1 year Right of Redemption 12/1/2023
2023 taxes are due and payable as of October 1st, 2023.

Said sale will be made for the purpose of paying said indebtedness and the expenses incidental to said sale, including a reasonable attorney’s fee.

POWER REAL ESTATE, INC., An Alabama Corporation as holder of said Vendors Lien Deed

William C. Poole, LLC

Attorneys at Law

917 Western America Circle

Suite 210

Mobile, Alabama 36609

(251) 344-5015

THIS IS AN ATTEMPT TO COLLECT A DEBT ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.

Call News October 4, 11, 18, 2023

MORTGAGE FORECLOSURE NOTICE

Default having been made in the terms of that certain Mortgage, executed on 7/3/2012, by Douglas Willard, a single man and Eddie Pace Jr., a single man, as Mortgagors, to Mortgage Electronic Registration Systems, Inc. as nominee for Quicken Loans, Inc. as Mortgagee, which said Mortgage is recorded in the Office of the Judge of Probate, Mobile County, Alabama, in Book 6912, Page 828 on 7/13/2012, and subsequently assigned to Nationstar Mortgage LLC and recorded in the Office of the Judge of Probate, Mobile County, Alabama on 09/18/2023 in Instrument # 2023056180 and default having continued under the terms of said Mortgage, and by virtue of Alabama Code Section 35-10-3 and 35-10-2, the following described real property will be sold at public outcry, for cash, to the highest bidder, in front of the Courthouse door of said County, during the legal hours of sale, on 11/02/2023.

LAND SITUATED IN THE CITY OF MOBILE IN THE COUNTY OF MOBILE IN THE STATE OF AL

LOT 57, GULF HAVEN 1ST UNIT, ACCORDING TO PLAT HEREOF RECORDED IN MAP BOOK 11, PAGE 76, OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE OF MOBILE COUNTY, ALABAMA.

COMMONLY KNOWN AS: 1722 EAST HARBOR DRIVE, MOBILE, AL 36605

The property is being sold “as is, where is”. Said property is sold without warranty or recourse, expressed or implied as to title, use or enjoyment.

This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure.

This sale is subject to postponement or cancellation.

Kent D. McPhail

McPhail Sanchez, LLC

Counsel for Mortgagee/Transferee

126 Government Street

Mobile, AL 36602

251-438-2333

Call News 10/11/2023, 10/18/2023, and 10/25/2023

FORECLOSURE NOTICE

Default having been made in the payment of the indebtedness described in and secured by that certain Vendors Lien Deed executed by Fearfully and Wonderfully Made Builds, LLC, An Alabama Limited Liability Company, to Power Partnership, LLC, an Alabama Limited Liability Company dated December 19th, 2022, and recorded in Instrument No. 2022077510, of the records in the Office of the Judge of Probate, Mobile County, Alabama; and said default continuing; notice is hereby given that the undersigned will, under and by virtue of the power of sale contained in said Vendors Lien Deed, sell at public outcry for cash, at the Government Street entrance of the Mobile County Courthouse at 205 Government Street, Mobile, Alabama, to the highest bidder, on October 26th, 2023, during the legal hours of sale, the following described real property situated in the County of Mobile, State of Alabama, to-wit:

Lot 9, Deer Landing, according to plat thereof recorded in Instrument No. 2021082638 of the records in the Office of the Judge of Probate of Mobile County, Alabama.

– RAW LAND-

SUBJECT:

Except therefrom such oil, gas and other minerals in, on and under said real property, together with all rights in connection therewith, as have previously been reserved by or conveyed to others than the grantor.
Easements, reservations, restrictions, rights-of-way and setback lines as reserved and shown on record Map of subdivision.
All matters of Public record including any utility easement as recorded in the Office of the Judge of Probate, Mobile County, Alabama.
Any prior reservations or conveyance of minerals, together with release of damages of minerals of every kind and character, including but not limited to oil and gas in, on and under subject property.
Encroachments, overlaps, boundary line disputes and other matters that would be revealed by an accurate survey or inspection of the Property.
Utility easements and facilities serving the Property, whether of record or not.
A non-exclusive easement for ingress and egress access as noted on common area access driveway for the plat of Deer Landing as recorded in Instrument # 2021082638.
Easements, covenants, reservations, conditions and restrictions of record.
Easements, liens or encumbrances, or claims thereof, not shown by the Public Records.
Any encroachment, encumbrance, violation, variation, or adverse circumstance affecting the Title that would be disclosed by an accurate and complete land survey of the Land and not shown by the Public Records.
Any portion of subject property conveyed to The City of Mobile.
Restrictive Covenants contained in instrument dated December 16, 2021 and recorded in Instrument # 2021082765; including the Amendment dated April 22, 2022 recorded in Instrument # 2022033369

and all amendments thereto, but deleting any covenant, condition or restriction indicating a preference, limitation or discrimination based on race, color, religion, sex, handicap, familial status, or nation origin to the extend such covenants, conditions, or restrictions violate 42 USC 3604(c).

Building setback line; drainage and utility line easements as shown on the recorded plat of said subdivision.
Easement granted to Alabama Power Company by instrument recorded in Deed Book 433, Page 1015; Deed Book 515, Page 352; and Real Property Book 5424, Page 1216 of the records in the Office of the Judge of Probate of Mobile Count, Alabama.
Right of way granted to Mobile County by instrument recorded in Deed Book 440, Page 298 of the records in the Office of the Judge of Probate of Mobile County, Alabama
10’ Public Right of Way running along West side of property.
50’ Minimum Building Setback Line.
25’ Easement for Ingress & Egress and Utilities.
Mortgage dated March 30, 2021 from Power Partnership LLC to Alabama AG Credit FLCA as recorded in Instrument # 2021021241 and UCC Financing Statement from Power Partnership LLC to Alabama AG Credit FLCA as recorded in Instrument # 2021021242 to be released upon payoff of Vendors Lien Deed.
Plat of Deer Landing by Byrd Surveying, Inc. dated August 9th, 2021 and recorded in Instrument No. 2021057066.
Amended Plat of Deer Landing by Byrd Surveying, Inc. dated August 9th, 2021 and recorded in Instrument No. 2021082638.
2023 Taxes are due and payable as of October 1, 2023.

Said sale will be made for the purpose of paying said indebtedness and the expenses incidental to said sale, including a reasonable attorney’s fee.

POWER PARTNERSHIP LLC, an Alabama Limited Liability Company as holder of said Vendors Lien Deed

William C. Poole, LLC

Attorneys at Law

William C. Poole

917 Western America Circle, Suite 210

Mobile, AL 36609

(251) 344-5015

THIS IS AN ATTEMPT TO COLLECT A DEBT ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.

Call News October 4, 11, 18, 2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Alyssa Gilman, an unmarried female, originally in favor of Mortgage Electronic Registration Systems, Inc., solely as nominee for Embrace Home Loans, Inc., on April 28, 2016, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book LR7374 Page 1735; the undersigned Freedom Mortgage Corporation, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 30, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 83, Hidden Pines, Unit Two, according to the Plat thereof recorded in Map Book 87, Page 60, of the recorded in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 6929 Gray Oaks Drive , Theodore, AL 36582. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Freedom Mortgage Corporation, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223

www.tblaw.com

TB File Number: 23-06799

Call News 10/04/2023, 10/11/2023, 10/18/2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by John S Logan and Alice Mabire-Logan, husband and wife, originally in favor of Mortgage Electronic Registration Systems, Inc., as nominee for Hometown Lenders Inc., on June 25, 2020, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Instrument Number 2020038092; the undersigned Wilmington Savings Fund Society, FSB, as trustee of Stanwich Mortgage Loan Trust F, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 1, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lots 9 and 10, Dykes Road Farmettes, according to the plat thereof recorded in Map Book 21, Page 38, in the Probate Office of Mobile County, Alabama.. Property street address for informational purposes: 501 Eliza Jordan Rd S , Mobile, AL 36608. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Wilmington Savings Fund Society, FSB, as trustee of Stanwich Mortgage Loan Trust F, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223

www.tblaw.com

TB File Number: 23-05526

Call News 10/04/2023, 10/11/2023, 10/18/2023

NOTICE OF SALE UNDER POWER

FORECLOSURE NOTICE

WHEREAS, default has occurred in the performance of the covenants, terms and conditions of a mortgage from HELEN J BROADNAX, A SINGLE WOMAN to MORTGAGE ELECTRONIC REGISTRATION SYSTEMS INC. AS MORTGAGEE, AS NOMINEE FOR CREVECOR MORTGAGE INC., on the 1st day of March, 2006, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, on March 3, 2006, in Deed/Mortgage Book 5928, Page 584, at Instrument Number 2006015486, Mobile County, Alabama Records, said Mortgage having subsequently been transferred and assigned to U.S. Bank Trust National Association, as Trustee for LB-Dwelling Series V Trust, by instrument recorded in the aforesaid Probate Office; notice is hereby given that the undersigned U.S. Bank Trust National Association, as Trustee for LB-Dwelling Series V Trust, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash in front of the main entrance of the Courthouse in Mobile, Mobile County, Alabama, on November 1, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:

LOT 17, BLOCK 1, OAK DRIVE COURT, ACCORDING TO PLAT THEREOF RECORDED IN MAP BOOK 4, PAGE 484 OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE MOBILE COUNTY, ALABAMA.

Said legal description being controlling, however the property is more commonly known as 565 OAK DRIVE COURT, MOBILE, AL 36617.

U.S. Bank Trust National Association, as Trustee for LB-Dwelling Series V Trust, Mortgagee/Transferee

THE BELOW LAW FIRM MAY BE HELD TO BE ACTING AS A DEBT COLLECTOR, UNDER FEDERAL LAW. IF SO, ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.

Rubin Lublin, LLC, Attorney for Mortgagee/Transferee

11 N. Water Street, Suite 10290, Mobile, AL 36602

Telephone Number: (877) 813-0992 Case No. SNS-23-03834-2

rlselaw.com/property-listing

Call News 10/04/2023, 10/11/2023, 10/18/2023

NOTICE OF

MORTGAGE FORECLOSURE SALE

STATE OF ALABAMA

COUNTY OF MOBILE

Default having been made of the terms of the loan documents secured by that certain mortgage executed by Lawrence Andrews A Single Man to Mortgage Electronic Registration Systems, Inc., as Mortgagee, a nominee for Green Tree Servicing, LLC, Its Successors and Assigns dated June 4, 2014; said mortgage being recorded on June 16, 2014, in Book LR7158, Page 1215 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to NewRez LLC d/b/a Shellpoint Mortgage Servicing in Instrument 2023056525 in the Office of the Judge of Probate of Mobile County, ALABAMA.

The undersigned, NewRez LLC d/b/a Shellpoint Mortgage Servicingunder and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 2nd day of November, 2023 the following property, situated in Mobile County, Alabama, to-wit:

LOTS 14 AND 15, BRESTOR SUBDIVISION, AS RECORDED IN DEED BOOK 156 N.S., PAGE 285, IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA.

Said property is commonly known as 1567 Eslava Street, Mobile, AL 36604.

Should a conflict arise between the property address and the legal description the legal description will control.

NEWREZ LLC D/B/A SHELLPOINT MORTGAGE SERVICING

as holder of said mortgage

McCalla Raymer Leibert Pierce, LLC

Two North Twentieth

2 20th Street North, Suite 1000

Birmingham, AL 35203

(205) 216-4238

FT21@mccalla.com

File No. 923817

www.foreclosurehotline.net

Call News 10/04/2023,10/11/2023,10/18/2023

NOTICE OF

MORTGAGE FORECLOSURE SALE

STATE OF ALABAMA

COUNTY OF MOBILE

Default having been made of the terms of the loan documents secured by that certain mortgage executed by Patrick I. Headley A Married Man And Betty Ann Bell A Married Woman to Mortgage Electronic Registration Systems, Inc., as mortgagee, as nominee for GMFS LLC, its successors and assigns dated August 22, 2014; said mortgage being recorded on August 26, 2014, in Book LR7181, Page 402 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to GMFS LLC by assignment recorded in Deed Book LR7657, Page 1222 in the Office of the Judge of Probate of Mobile County, ALABAMA.

The undersigned, GMFS LLCunder and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 16th day of November, 2023 the following property, situated in Mobile County, Alabama, to-wit:

Lot 6, Southern Oaks Estates, Unit One, according to plat thereof recorded in Map Book 78, page 12, of the records in the Office of the Judge of Probate of Mobile County, Alabama.

Said property is commonly known as 5097 Dawes Road, Grand Bay, AL 36541.

Should a conflict arise between the property address and the legal description the legal description will control.

GMFS LLC

as holder of said mortgage

McCalla Raymer Leibert Pierce, LLC

Two North Twentieth

2 20th Street North, Suite 1000

Birmingham, AL 35203

(205) 216-4238

FT21@mccalla.com

File No. 9258820

www.foreclosurehotline.net

Call News 10/04/2023,10/11/2023,10/18/2023

MORTGAGE FORECLOSURE SALE

Default having being made in the payment of the indebtedness secured by that certain mortgage dated September 24, 2021 executed by Arthur L. Greathouse, an unmarried person, in favor of Mortgage Electronic Registration Systems, Inc. solely as nominee for Trustmark National Bank, said Mortgage being recorded September 30, 2021, in Inst. #2021064749, in the Office of the Judge of Probate of Mobile County, Alabama; having later been assigned to Trustmark National Bank by instrument recorded in Inst. #2022066803, in the Office of the Judge of Probate of Mobile County, Alabama. Said default continues and notice is hereby given that the undersigned, Trustmark National Bank, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash at the main entrance to the County Courthouse, Mobile County, Alabama on 11/29/2023, during the legal hours of sale, the following described real estate situated in Mobile County, Alabama, to-wit:

Lot 5, Pinewood Estates Subdivision, as recorded in Map Book 13, Page 48 in the Office of the Judge of Probate, Mobile County, Alabama.

For informational purposes only, the property address is: 24 Frances St., Saraland, AL 36571. Any property address provided is not part of the legal description of the property sold herein and in the event of any discrepancy, the legal description referenced herein shall control.

THIS PROPERTY WILL BE SOLD ON AN “AS-IS, WHERE-IS” BASIS, SUBJECT TO ANY EASEMENTS, ENCUMBRANCES, AND EXCEPTIONS REFLECTED IN THE MORTGAGE AND THOSE CONTAINED IN THE RECORDS OF THE OFFICE OF THE JUDGE OF PROBATE OF THE COUNTY WHERE THE ABOVE-DESCRIBED PROPERTY IS SITUATED. THIS PROPERTY WILL BE SOLD WITHOUT WARRANTY OR RECOURSE, EXPRESS OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO.

This sale is made for the purpose of paying the indebtedness secured by mortgage as well as the expenses of foreclosure, including a reasonable attorney’s fees and other purposes set out in said mortgage.

Trustmark National Bank

Paul K. Lavelle, Esq.

Attorney for Mortgagee

Spina, & Lavelle, P.C.

One Perimeter Park South-Suite 400N

Birmingham, Alabama 35243

(205) 298-1800

40-FC-23-01236

Call News October 4, 2023, October 11, 2023 and October 18, 2023

NOTICE OF

MORTGAGE FORECLOSURE SALE

STATE OF ALABAMA

COUNTY OF MOBILE

Default having been made of the terms of the loan documents secured by that certain mortgage executed by Samantha Jane Duff And Jeffery Glenn Duff Wife And Husband to Mortgage Electronic Registration Systems, Inc., as mortgagee, as nominee for SWBC Mortgage Corporation, its successors and assigns dated February 15, 2018; said mortgage being recorded on February 16, 2018, in Book LR7604, Page 1135 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to SWBC Mortgage Corporation in Instrument 2020070531 in the Office of the Judge of Probate of Mobile County, ALABAMA.

The undersigned, SWBC Mortgage Corporation, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 2nd day of November, 2023 the following property, situated in Mobile County, Alabama, to-wit:

LOT 31, VIKING PLACE, PHASE I, ACCORDING TO THE PLAT THEREOF RECORDED IN MAP BOOK 109, PAGE 74, OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE OF MOBILE COUNTY, ALABAMA.

Said property is commonly known as 3650 Eric Drive, Semmes, AL 36575.

Should a conflict arise between the property address and the legal description the legal description will control.

SWBC MORTGAGE CORPORATION

as holder of said mortgage

McCalla Raymer Leibert Pierce, LLC

Two North Twentieth

2 20th Street North, Suite 1000

Birmingham, AL 35203

(205) 216-4238

FT21@mccalla.com

File No. 23-04311AL

www.foreclosurehotline.net

Call News 09/27/2023,10/04/2023,10/11/2023,10/18/2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed on January 31, 2018 by Sophia C. Robinson and Rodney M. Robinson, wife and husband, originally in favor of Mortgage Electronic Registration Systems,Inc. acting solely as nominee for DHI Mortgage Company, LTD, and recorded in LR7599 at 759 on January 31, 2018, and modified in and modified by agreement recorded September 16, 2021 at Instrument Number 2021061083, in the Office of the Judge of Probate of Mobile County, Alabama, and secured indebtedness having been transferred to Nationstar Mortgage LLC. LOGS Legal Group LLP, as counsel for Mortgagee or Transferee and under and by virtue of power of sale contained in the said mortgage will, on November 28, 2023, sell at public outcry to the highest bidder at the main entrance of the Mobile County, Alabama, Courthouse in the City of Mobile, during the legal hours of sale, the following real estate situated in Mobile County, Alabama, to wit:

Lot 43, Newman Pass Subdivision, according to plat thereof as recorded in Map Book 127, Page 91, in the office of the Judge of Probate of Mobile County Alabama

For informational purposes only, the property address is: 13016 Chelle Way, Mobile, AL 36695.

Any property address provided is not part of the legal description of the property sold herein and in the event of any discrepancy, the legal description referenced herein shall control.

Nationstar Mortgage LLC, and its successors and assigns

Mortgagee or Transferee

LOGS LEGAL GROUP LLP

10130 Perimeter Parkway, Suite 400

Charlotte, NC 28216

704-333-8107/ 23-023153

Attorneys for Mortgagee or Transferee

Call News October 4, 2023 and October 11, 2023 and October 18, 2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by James R. Spencer and Tonya V. Spencer, as husband and wife, originally in favor of Mortgage Electronic Registration Systems, Inc., as nominee for First Federal Bank, on September 25, 2009, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 6588 Page 29; with loan modification agreement recorded September 28, 2012 in Book 6939 Page 1099; the undersigned MidFirst Bank, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 30, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lots 9, 10, 11 and 12, Block 54, North Mobile, according to plat thereof recorded in Deed Book 145 N.S., page 252, et seq., of records in the Office of the Judge of Probate of Mobile County, Alabama.. Property street address for informational purposes: 256 Thompson Blvd , Chickasaw, AL 36611. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. MidFirst Bank, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223

www.tblaw.com

TB File Number: 23-06687

Call News 10/04/2023, 10/11/2023, 10/18/2023

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Deborah L. Koschalk, a married woman and Joel L. Bowling, her husband, originally in favor of Mortgage Electronic Registration Systems, Inc. solely as nominee for Countrywide Home Loans, Inc., on September 26, 2005, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 5855 Page 915; the undersigned Wilmington Savings Fund Society, FSB, not in its individual capacity but solely as trustee for BCAT 2020-3TT, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 2, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Parcel A: From the Northeast corner of Lot 30, Crestwood Estates, Second Unit, as per plat recorded in Map Book 25, Page 18, Probate Court Records, Mobile County, Alabama; run thence North 89 degrees 41 minutes 34 seconds West and along the North line of Lot 3 a distance of 69.94 feet to a point; thence North 00 degrees 23 minutes 57 seconds East 35.00 feet to the Point of Beginning of the property herein described; thence continue North 00 degrees 23 minutes 57 seconds East, 200.00 feet to a point; thence South 89 degrees 32 minutes 52 seconds East 150.00 feet to a point; thence South 00 degrees 23 minutes 57 seconds West 199.60 feet to a point; thence North 89 degrees 42 minutes 07 seconds West 150.00 feet to the Point of Beginning. Together with an easement for ingress and egress over and across the following described property to-wit: The South 15 feet of the West 377 feet of the East 740 feet of the Northwest Quarter of the Northeast Quarter of Section 25, Township 3 South, Range 3 West, Mobile County, Alabama. Parcel B: Commencing at the Northeast corner of Lot 30, Crestwood Estates, Second Unit, as per plat recorded in Map Book 25, Page 18, Probate Court Records, Mobile County, Alabama; thence run North 89 degrees 41 minutes 34 seconds West, 69.94 feet to a point; thence run North 00 degrees 23 minutes 57 seconds East, 235 feet to the Point of Beginning of the property herein described; thence continuing North 00 degrees 23 minutes 57 seconds East, 44.68 feet to a point; thence run South 89 degrees 42 minutes 07 seconds East, 150.0 feet to a point; thence run South 00 degrees 23 minutes 57 seconds West, 45.08 feet to a point; thence run North 89 degrees 32 minutes 52 seconds West, 150.00 feet to the Point of Beginning. Together with a 20 foot easement for ingress and egress and being described as follows: Beginning at the Southwest corner of said Parcel A run North 89 degrees 41 minutes 08 seconds East 149.88 feet to a point: thence run South 00 degrees 24 minutes 11 seconds West 20 feet, more or less to a point that is 15 feet North of the North line of the Southwest Quarter of the Northeast Quarter of Section 25, Township 3 South, Range 3 West, Mobile County, Alabama: thence run Westwardly to a point that is 20 feet South of said Point of Beginning; thence run Northwardly 20 feet to said Point of Beginning. Together with a strip of land 30 feet in width for road purposes extending from Southwest corner of the North half of the East half of the Southwest Quarter of the Northeast Quarter of Section 25, Township 3 South, Range 3 West, described property to Wards Lane and running along the West line of the South half of the East half of the Southwest Quarter of the Northeast Quarter of said Section 25, Township 3 South, Range 3 West. Together with a non-exclusive permanent easement for the purpose of ingress and egress on, over and across that strip of land 30 feet in width for road purposes extending from the Northwest corner of the North half of the East half of the Southwest quarter of the Northeast quarter of Section 25, Township 3 South, Range 3 West, to Wards Lane, and running along the West line of the South half of the East half of the Southwest quarter of the Northeast quarter of said Section 25, Township 3 South, Range 3 West.. Property street address for informational purposes: 8050C Wards Ln , Semmes, AL 36575. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Wilmington Savings Fund Society, FSB, not in its individual capacity but solely as trustee for BCAT 2020-3TT, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223.

www.tblaw.com

TB File Number: 23-06256

Call News 10/04/2023, 10/11/2023, 10/18/2023

MORTGAGE FORECLOSURE NOTICE

Default having been made in the terms of that certain Mortgage, executed on 07/31/2007, by Roger Tunstall, Sr., Husband and Wife and Gwendolyn Tunstall, as Mortgagors, to Mortgage Electronic Registration Systems, Inc. as nominee for MortgageAmerica, Inc., as Mortgagee, which said Mortgage is recorded in the Office of the Judge of Probate, Mobile County, Alabama, in Book 6233, Page 1104 on 08/02/2007, and Modified in Inst # 2021043080 recorded 7/6/2021 and again Modified in Inst # 2022037984 recorded 6/1/2022 and further Modified in Inst # 2023011669 recorded 3/3/2023 and Carrington Mortgage Services, LLC is currently the holder of the Mortgage, and underlying promissory note secured thereby, and Carrington Mortgage Services, LLC is authorized to enforce the terms of the Mortgage secured by said promissory note; and default having continued under the terms of said Mortgage, and by virtue of Alabama Code Section 35-10-3 and 35-10-2, the following described real property will be sold at public outcry, for cash, to the highest bidder, in front of the Courthouse door of said County, during the legal hours of sale, on 11/15/2023

That real property situated in the County of Mobile, State of Alabama, described as follows, to-wit:

Lot 32, Delmar Subdivision, according to plat thereof recorded in Map Book 9, Page 24, of the records in the Office of the Judge of Probate of Mobile, County, Alabama.

The property is being sold “as is, where is”. Said property is sold without warranty or recourse, expressed or implied as to title, use or enjoyment.

This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure.

This sale is subject to postponement or cancellation.

Kent D. McPhail

McPhail Sanchez, LLC

Attorney for Mortgagee/Transferee

126 Government Street

Mobile, AL 36602

251-438-2333

Call News 10/4/2023, 10/11/2023, 10/18/2023

NOTICE OF

MORTGAGE FORECLOSURE SALE

STATE OF ALABAMA

COUNTY OF MOBILE

Default having been made of the terms of the loan documents secured by that certain mortgage executed by Mamie Frowner Unmarried to First Family Financial Services, Inc. dated August 16, 2000; said mortgage being recorded on August 18, 2000, in Book 4870, Page 143 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to U.S. Bank National Association, not in its individual capacity but solely in its capacity as Indenture Trustee of CIM Trust 2020-R1 in Instrument 2023055960 in the Office of the Judge of Probate of Mobile County, ALABAMA.

The undersigned, U.S. Bank National Association, not in its individual capacity but solely in its capacity as Indenture Trustee of CIM Trust 2020-R1under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 25th day of October, 2023 the following property, situated in Mobile County, Alabama, to-wit:

LOT 11, BLOCK 1, SECOND ADDITION TO MEADOW GARDENS, ACCORDING TO THE PLAT THEREOF RECORDED IN MAP BOOK 8, PAGE 152, IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA.

Said property is commonly known as 2951 Bellmead Dr, Whistler, AL 36612.

Should a conflict arise between the property address and the legal description the legal description will control.

U.S. BANK NATIONAL ASSOCIATION, NOT IN ITS INDIVIDUAL CAPACITY BUT SOLELY IN ITS CAPACITY AS INDENTURE TRUSTEE OF CIM TRUST 2020-R1

as holder of said mortgage

McCalla Raymer Leibert Pierce, LLC

Two North Twentieth

2 20th Street North, Suite 1000

Birmingham, AL 35203

(205) 216-4238

FT21@mccalla.com

File No. 23-04528AL

www.foreclosurehotline.net

Call News 10/04/2023,10/11/2023,10/18/2023

NOTICE OF SALE UNDER POWER

FORECLOSURE NOTICE

WHEREAS, default has occurred in the performance of the covenants, terms and conditions of a mortgage from Jack Skinner, a married man with no claim of homestead to First Franklin a Division of Nat. City Bank of IN, on the 26th day of April, 2005, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, on April 29, 2005, in Deed/Mortgage Book 5767, Page 1292, Mobile County, Alabama Records, said Mortgage having subsequently been transferred and assigned to Nationstar Mortgage LLC, by instrument recorded in the aforesaid Probate Office; notice is hereby given that the undersigned Nationstar Mortgage LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash at the Main Entrance of the Mobile County Courthouse, 205 Government Street, Mobile, AL 36602 in Mobile, Mobile County, Alabama, on November 2, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:

BEGINNING AT THE NORTHEAST CORNER OF LOT 1 BLOCK 1 SHENANDOAH PARK AS RECORDED IN MAP BOOK 5, PAGE 420, IN THE RECORDS OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA, THENCE NORTH 88 DEGREES 12 MINUTES 19 SECONDS EAST ALONG SOUTH RIGHT OF WAY OF ROSEDALE ROAD A DISTANCE OF 100 FEET THENCE SOUTH 02 DEGREES 36 MINUTES 20 SECONDS WEST A DISTANCE OF 630.0 FEET; THENCE SOUTH 89 DEGREES 14 MINUTES 19 SECONDS WEST A DISTANCE OF 100.00 FEET; THENCE NORTH 02 DEGREES 37 MINUTES EAST ALONG THE EAST LINE OF THE AFOREMENTIONED SHENANDOAH PARK A DISTANCE OF 628.20 FEET TO THE POINT OF BEGINNING.

Said legal description being controlling, however the property is more commonly known as 1727 ROSEDALE RD, MOBILE, AL 36605.

Nationstar Mortgage LLC, Mortgagee/Transferee

THE BELOW LAW FIRM MAY BE HELD TO BE ACTING AS A DEBT COLLECTOR, UNDER FEDERAL LAW. IF SO, ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.

Rubin Lublin, LLC, Attorney for Mortgagee/Transferee

11 N. Water Street, Suite 10290, Mobile, AL 36602

Telephone Number: (877) 813-0992 Case No. NAT-23-04135-1

rlselaw.com/property-listing

Call News 10/04/2023, 10/11/2023, 10/18/2023

NOTICE OF FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Ashante Burrell, unmarried woman, to Mortgage Electronic Registration Systems, Inc., as Mortgagee, as nominee for Hamilton Mortgage Corporation, a Corporation, its successors and assigns, on August 13, 2015, said mortgage being recorded in the Office of the Judge of Probate of Mobile County, Alabama, on August 25, 2015 at Book LR7296, at Page 1085. Freedom Mortgage Corporation, the current holder, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Mobile County Courthouse, in Mobile, Alabama, on November 29, 2023, during the legal hours of sale, the following described real estate, situated in Mobile County, Alabama, to-wit:

Lot 13, Block 5, Forest Highlands, according to plat thereof recorded in Map Book 5, Pages 623-636, of the records in the Office of the Judge of Probate, Mobile County, Alabama.

More commonly known as: 5322 Forest Park Dr, Mobile, AL 36618

Freedom Mortgage Corporation (“Transferee”)

Halliday, Watkins & Mann, P.C.

244 Inverness Center Drive

Birmingham, AL 35242

Phone: (801) 355-2886

Call News October 4, 2023, October 11, 2023, October 18, 2023

NOTICE OF SALE UNDER POWER

FORECLOSURE NOTICE

WHEREAS, default has occurred in the performance of the covenants, terms and conditions of a mortgage from Melissa A. Woodruff, an unmarried woman to Mortgage Electronic Registration Systems Inc., as mortgagee, as nominee for America`s Wholesale Lender, on the 18th day of July, 2006, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, on July 21, 2006, in Deed/Mortgage Book 6010, Page 1012, Mobile County, Alabama Records, said Mortgage having subsequently been transferred and assigned to NewRez LLC d/b/a Shellpoint Mortgage Servicing, by instrument recorded in the aforesaid Probate Office; notice is hereby given that the undersigned NewRez LLC d/b/a Shellpoint Mortgage Servicing, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash at the Main Entrance of the Mobile County Courthouse, 205 Government Street, Mobile, AL 36602 in Mobile, Mobile County, Alabama, on October 26, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:

THAT REAL PROPERTY SITUATED IN THE COUNTY OF MOBILE, STATE OF ALABAMA, DESCRIBED AS FOLLOWS, TO-WIT:

LOTS 34 AND 35, WILLOW RUN PARK, ACCORDING TO PLAT THEREOF RECORDED IN MAP BOOK 5 PAGES 346-7 OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA

Said legal description being controlling, however the property is more commonly known as 2354 WILLOWDALE ST, MOBILE, AL 36605.

NewRez LLC d/b/a Shellpoint Mortgage Servicing, Mortgagee/Transferee

THE BELOW LAW FIRM MAY BE HELD TO BE ACTING AS A DEBT COLLECTOR, UNDER FEDERAL LAW. IF SO, ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.

Rubin Lublin, LLC, Attorney for Mortgagee/Transferee

11 N. Water Street, Suite 10290, Mobile, AL 36602

Telephone Number: (877) 813-0992 Case No. SHP-23-04078-1

rlselaw.com/property-listing

Call News 10/04/2023, 10/11/2023, 10/18/2023

NOTICE OF SALE UNDER POWER

FORECLOSURE NOTICE

WHEREAS, default has occurred in the performance of the covenants, terms and conditions of a mortgage from LYNN WORKMAN AKA LYNN K. WORKMAN, AN UNMARRIED WOMAN to Mortgage Electronic Registrations Systems, Inc., as Mortgagee, as Nominee for Hometown Lenders Inc. , on the 4th day of May, 2018, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, on May 25, 2018, in Deed/Mortgage Book LR7639, Page 1738, Mobile County, Alabama Records, said Mortgage having subsequently been transferred and assigned to Planet Home Lending, LLC, by instrument recorded in the aforesaid Probate Office; notice is hereby given that the undersigned Planet Home Lending, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash at the main entrance to the Mobile county courthouse located at 205 Government Street, Mobile, AL 36652 in Mobile, Mobile County, Alabama, on November 15, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:

BEGIN AT THE SOUTHWEST CORNER OF THE NORTH HALF OF THE SOUTH HALF OF THE NORTHWEST QUARTER OF THE SOUTHEAST QUARTER OF SECTION 26, TOWNSHIP 6 SOUTH; RANGE 3 WEST; RUN THENCE NORTH 138 FEET TO A POINT; RUN THENCE EAST 225 FEET TO A POINT; RUN THENCE SOUTH 138 FEET TO A POINT; RUN THENCE WEST 225 FEET TO THE POINT OF BEGINNING.

Said legal description being controlling, however the property is more commonly known as 9561 BEVERLY RD, IRVINGTON, AL 36544.

Planet Home Lending, LLC, Mortgagee/Transferee

THE BELOW LAW FIRM MAY BE HELD TO BE ACTING AS A DEBT COLLECTOR, UNDER FEDERAL LAW. IF SO, ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.

Rubin Lublin, LLC, Attorney for Mortgagee/Transferee

11 N. Water Street, Suite 10290, Mobile, AL 36602

Telephone Number: (877) 813-0992 Case No. PHL-23-04092-1

rlselaw.com/property-listing

Call News 10/18/2023, 10/25/2023, 11/01/2023

POSTPONEMENT

MORTGAGE FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Donald R Avis and Vivian J Avis, originally in favor of U. S. Bank National Association ND, on June 4, 2010, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 6721 Page 82; the undersigned US Bank National Association as successor by merger to US Bank National Association ND , as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on October 12, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Situate in the County of Mobile, State of Alabama: Lot 7, Roseland Heights, Unit Two, according to plat thereof recorded in Map Book 27, Page 125 of the records in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 2250 Laura Dr , Semmes, AL 36575. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. The above mortgage foreclosure sale has been postponed from October 12, 2023 until December 14, 2023, during the legal hours of sale in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama. US Bank National Association as successor by merger to US Bank National Association ND , (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223

www.tblaw.com

TB File Number: 23-06000

Call News September 20, 2023, September 27, 2023, October 4, 2023, October 18, 2023

CONTINUATION OF MORTGAGE

FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed to Mortgage Electronic Registration Systems, Inc. as nominee for Vandyk Mortgage Corporation on May 14, 2009, by Reginald L. Crear, a Married Man joined by his wife and Mary A. Crear, and recorded in Book 6535, Page 228 and secured indebtedness having been transferred Wells Fargo Bank, N.A.. LOGS Legal Group LLP, as counsel for the Mortgagee or Transferee, under and by virtue of the power of sale contained in the said mortgage will sell at public outcry to the highest bidder for cash in front of the main entrance of the Mobile County, Alabama, Courthouse in the City of Mobile, Mobile County, Alabama, on the August 31, 2023, during the legal hours of sale the following real estate situated in Mobile County, Alabama, to wit:

Lot 20, Lee Place, Muths Subdivision, as per plat recorded in Map Book 3, Pages 325-326 of the records in the office of the Judge of Probate of Mobile County, Alabama.

Notice of this foreclosure sale may also be provided to the following parties if applicable, who may have some interest in said property, in order that they might avail themselves of the opportunity to bid at said foreclosure sale: Internal Revenue Service.

For informational purposes only, the property address is: 1849 La Salle St, Mobile, AL 36606. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. Five Thousand Dollars and no/100 ($5,000.00) must be tendered in certified funds at the time and place of the sale by the purchaser as a non-refundable deposit. The balance of the purchase price must be paid in certified funds within 24 HOURS thereafter at the law offices of LOGS Legal Group LLP, 1878 Jeff Rd. NW, Suite “I”, Huntsville, AL 35806, 704-333-8107. LOGS Legal Group LLP reserves the right to award the bid to the next highest bidder, or to reschedule the sale, should the highest bidder fail to timely tender the total amount due.

Wells Fargo Bank, N.A., and its successors and assigns

Mortgagee or Transferee

LOGS LEGAL GROUP LLP

1878 Jeff Rd. NW, Suite “I”

Huntsville, AL 35806

704-333-8107/22-021903

Attorneys for Mortgagee or Transferee

Call News January 6, 2023 and January 13, 2023 and January 20, 2023.

The public sale provided for hereinabove was postponed on August 31, 2023, by public announcement being made at the main entrance of the Mobile County Courthouse, Mobile, Alabama, during the legal hours of sale. The foreclosure sale described hereinabove shall be held on the November 2, 2023, at the main entrance of the Mobile County Courthouse, Mobile, Alabama, during the legal hours of sale.

Call News 10/18/2023

NOTICE OF FORECLOSURE SALE

MOBILE COUNTY

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Brittany K. Richardson a/k/a Brittany Richardson, a married woman, originally in favor of Mortgage Electronic Registration Systems, Inc., as mortgagee, as nominee for First Federal Bank, A FSB, its successors and assigns on June 25, 2021, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, Instrument Number 2021042035; the undersigned NewRez LLC d/b/a Shellpoint Mortgage Servicing, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash or certified funds, in front of the main entrance of the Courthouse at Mobile County, Alabama, on June 15, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:

Lot 44, Maryknoll Place, Unit One, according to plat thereof recorded in Map Book 79, Page 56 of the records in the Office of the Judge of Probate of Mobile County, Alabama.

Property street address for informational purposes: 6565 Lubarrett Way Mobile, AL 36695

THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, SUBJECT TO ANY EASEMENTS, ENCUMBRANCES, AND EXCEPTIONS REFLECTED IN THE MORTGAGE AND THOSE CONTAINED IN THE RECORDS OF THE OFFICE OF THE JUDGE OF PROBATE OF THE COUNTY WHERE THE ABOVE-DESCRIBED PROPERTY IS SITUATED. THIS PROPERTY WILL BE SOLD WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO.

Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender cash or certified funds made payable to Aldridge Pite, LLP at the time and place of the sale. Aldridge Pite, LLP reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. NewRez LLC d/b/a Shellpoint Mortgage Servicing, Mortgagee/Transferee ALDRIDGE PITE, LLP Six Piedmont Center 3525 Piedmont Road, N.E., Suite 700 Atlanta, GA 30305. Attorney for Mortgagee/Transferee.

Newspaper: Call News

Publication Dates: 5/10/2023, 5/17/2023, 5/24/2023

AMENDMENT TO NOTICE OF MORTGAGE FORECLOSURE SALE

The sale date under the above mentioned Notice of Mortgage Foreclosure Sale has been postponed until August 31, 2023, and public notice thereof having been given, the above notice is hereby republished with this amendment.

Newspaper: Call News

Publication Dates: 6/14/2023

AMENDMENT TO NOTICE OF MORTGAGE FORECLOSURE SALE

The sale date under the above mentioned Notice of Mortgage Foreclosure Sale has been postponed until October 12, 2023, and public notice thereof having been given, the above notice is hereby republished with this amendment.

Newspaper: Call News

Publication Dates: 8/30/2023

AMENDMENT TO NOTICE OF MORTGAGE FORECLOSURE SALE

The sale date under the above mentioned Notice of Mortgage Foreclosure Sale has been postponed until December 14, 2023, and public notice thereof having been given, the above notice is hereby republished with this amendment.

THIS OFFICE IS ACTING AS A DEBT COLLECTOR AND IS ATTEMPTING TO COLLECT A DEBT. ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.

Call News 10/18/2023

POSTPONEMENT OF NOTICE OF FORECLOSURE SALE

Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Tracey R. Johnson Whatley and Bryan Lee Whatley, to Ameriquest Mortgage Company, on October 27, 2005, said mortgage being recorded in the Office of the Judge of Probate of Mobile County, Alabama, on December 16, 2005 at Book 5891, at Page 756. Deutsche Bank National Trust Company, as Trustee for Ameriquest Mortgage Securities Inc., Asset-Backed Pass-Through Certificates, Series 2005-R11, the current holder, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Mobile County Courthouse, in Mobile, Alabama, on October 5, 2023, during the legal hours of sale, the following described real estate, situated in Mobile County, Alabama, to-wit:

Lot 12, Hearthstone, Unit Two, according to the plat thereof recorded in Map Book 21, Page 50 of the records in the Office of the Judge of Probate, Mobile County, Alabama.

This Property will be sold on as “as is, where is” basis, without warranty or recourse, expressed or implied as to title, use and/or enjoyment and will be sold subject to the right of redemption of all parties entitled thereto. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expense of foreclosure. The successful bidder must tender certified funds by noon the next business day to Law Office of Halliday, Watkins & Mann, P.C.. Certified funds must be in the form of a wire transfer, bank or credit union’s cashier’s check, or bank official check payable to Halliday, Watkins & Mann, P.C.. Halliday, Watkins & Mann, P.C. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. If sale is voided, Mortgagee/Transferee shall return the bid amount to the successful purchaser and the Mortgagee/Transferee shall not be liable to the purchase for any damages. If the sale is set aside for any reason, the purchaser at the sale shall be only entitled to a return of the deposit and bid amount, if paid. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit is purchase price against the expenses of sale and indebtedness secured by the real estate. This sale is subject to postponement or cancellation.

THIS FORECLOSURE SALE HAS BEEN CONTINUED TO December 14, 2023 AT THE TIME AND PLACE SET FORTH ABOVE.

Deutsche Bank National Trust Company, as Trustee for Ameriquest Mortgage Securities Inc., Asset-Backed Pass-Through Certificates, Series 2005-R11 (“Transferee”)

Halliday, Watkins & Mann, P.C.

244 Inverness Center Drive

Birmingham, AL 35242

Phone: (801) 355-2886

Call News August 30, 2023, September 6, 2023, September 13, 2023, October 18, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of RONNIE EUGENE WILLIAMS

Case No. 2023-1865

Take notice that Letters of Administration have been granted to the below named party on the 13th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.

BOBBY DARNELL WILLIAMS as Administrator of the estate of RONNIE EUGENE WILLIAMS, deceased

Attorney of Record:

VAUGHN DRINKARD, JR, Esq.

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of NOREEN MCALLISTER VICKERS, Deceased

Case No. 2023-1970

Take notice that Letters Testamentary have been granted to the below named party on the 11th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.

MICHAEL PATRICK VICKERS as Executor under the last will and testament of NOREEN MCALLISTER VICKERS, Deceased

Attorney of Record:

GILBERT DUKES III

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of JOSEPH LOUIS TODD

Case No. 2023-1687

Take notice that Letters of Administration have been granted to the below named party on the 10th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.

ETHEL MAE TODD as Administratrix of the estate of JOSEPH LOUIS TODD, deceased

Attorney of Record:

JOHN A WENZEL, Esq.

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of JACQUELINE L THERRELL, Deceased

Case No. 2023-1969

JOHN W THERRELL JR as Executor under the last will and testament of JACQUELINE L THERRELL, Deceased

Attorney of Record:

NASH CAMPBELL

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of MARGARET MARIE SWEATT

Case No. 2023-1815

Take notice that Letters of Administration have been granted to the below named party on the 12th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.

STACY NEWELL MURPHY as Administratrix of the estate of MARGARET MARIE SWEATT, deceased

Attorney of Record:

STEPHEN E. CLEMENTS, Esq.

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of TERRY LYNN SUMERLIN, Deceased

Case No. 2023-1930

Take notice that Letters Testamentary have been granted to the below named party on the 4th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.

TERA COCHRAN as Executrix under the last will and testament of TERRY LYNN SUMERLIN, Deceased

Attorney of Record:

DANIEL G SAYERS

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of EMMA STANDRIDGE, Deceased

Case No. 2023-1864

BARBARA BRELAND as Executrix under the last will and testament of EMMA STANDRIDGE, Deceased

Attorney of Record:

RICK A. LA TRACE

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of JAMES REID SPIRES, Deceased

Case No. 2023-1873

Take notice that Letters Testamentary have been granted to the below named parties on the 4th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.

JAMES L SPIRES and JAMES R SPIRES JR as Co-Executors under the last will and testament of JAMES REID SPIRES, Deceased

Attorney of Record:

SHIRLEY M JUSTICE

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of CHARLES DALE SMITH, Deceased

Case No. 2023-1460

JAMIE JO SMITH as Executrix under the last will and testament of CHARLES DALE SMITH, Deceased

Attorney of Record:

PAGE STANLEY ELLIS

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of RONALD FRANKLIN SILVA, Deceased

Case No. 2023-1902

BARBARA L. COPELAND as Executrix under the last will and testament of RONALD FRANKLIN SILVA, Deceased

Attorney of Record:

NEIL CHUNN JOHNSTON JR.

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of DAVID L. ROBERTS

Case No. 2023-1691

Take notice that Letters of Administration have been granted to the below named party on the 3rd day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.

ANTHONY M. HOFFMAN, as Administrator of the estate of DAVID L. ROBERTS, Deceased

Attorney of Record:

ANTHONY M. HOFFMAN

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of ROBERT ORESTIES NEWELL

Case No. 2023-1621

Take notice that Letters of Administration have been granted to the below named party on the 2nd day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.

SHARON NEWELL WOODHAM as Administratrix of the estate of ROBERT ORESTIES NEWELL, deceased

Attorney of Record:

PAGE STANLEY ELLIS, Esq.

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of MARIETTA MURRAY, Deceased

Case No. 2023-1927

MARIETTA M. URQUHART and ANNE BLAKE M. BROOKS as Co-Executrices under the last will and testament of MARIETTA MURRAY, Deceased

Attorney of Record:

THOMAS E SHARP, Ill, Esq.

JAMES F. WATKINS

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of ANNIE MAGEE, Deceased

Case No. 2023-1926

RYAN ZOGHBY as Executor under the last will and testament of ANNIE MAGEE, Deceased

Attorney of Record:

RYAN ZOGHBY, PRO SE

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of RANDY DOUGLAS JONES

Case No. 2023-1546

ANTHONY M. HOFFMAN, as Administrator of the estate of RANDY DOUGLAS JONES, Deceased

Attorney of Record:

Anthony Hoffman, Esq.

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of EDWINA J. JOHNSON

Case No. 2023-1383

FAYE LORAINE CURTIS as Executrix of the estate of EDWINA J. JOHNSON, deceased

Attorney of Record:

DONELSON FOOSE

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of DENISE ANN JOHNSON

Case No. 2023-0858

ANTHONY M. HOFFMAN, as Administrator of the estate of DENISE ANN JOHNSON, Deceased

Attorney of Record:

ANTHONY M. HOFFMAN

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of CURTIS WAYNE HITT

Case No. 2023-1771

Take notice that Letters of Administration have been granted to the below named party on the 11th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.

MELISSA HITT-LATHAM as Administratrix of the estate of CURTIS WAYNE HITT, deceased

Attorney of Record:

WILLIAM T. MCGOWIN IV, Esq.

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of RICHARD NELSON HERRING

Case No. 2023-1608

PATRICE ANDERSON as Administratrix of the estate of RICHARD NELSON HERRING, deceased

Attorney of Record:

JOHN A WENZEL, Esq.

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of LATAWERENCE FINKLEY

Case No. 2023-1652

DELORES WELCH as Administratrix of the estate of LATAWERENCE FINKLEY, deceased

Attorney of Record:

LATONYA MINES, Esq.

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of DOUGLAS COOLEY SR

Case No. 2023-1543

DEZSJEUN Z COOLEY as Administrator of the estate of DOUGLAS COOLEY SR, deceased

Attorney of Record:

RICHARD E. SHIELDS, Esq.

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of RUTH ANN CLEMENT

Case No. 2023-1493

ANTHONY M. HOFFMAN, as Administrator of the estate of RUTH ANN CLEMENT, Deceased

Attorney of Record:

ANTHONY M. HOFFMAN

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of JAMES N. CHRISTIANSEN, Deceased

Case No. 2023-1932

JAMES N. CHRISTIANSEN JR. as Executor under the last will and testament of JAMES N. CHRISTIANSEN, Deceased

Attorney of Record:

DUANE A. GRAHAM

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of CAROL ALLENE GODBEE, Deceased

Case No. 2023-1931

DONALD WAYNE BARNETT as Executor under the last will and testament of CAROL ALLENE GODBEE, Deceased

Attorney of Record:

GILBERT DUKES III

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of ETTA DRISKELL BROWN Deceased

Case No. 2023-1799

ROBERT DON BROWN as Executor under the last will and testament of ETTA DRISKELL BROWN, Deceased

Attorney of Record:

WILLIAM M. LYON JR.

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of WILLIAM MOORE BAYLEY JR, Deceased

Case No. 2023-1659

MEISHA DIANE BAYLEY HANNAH as Executrix under the last will and testament of WILLIAM MOORE BAYLEY JR., Deceased

Attorney of Record:

DANIEL MIMS

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of RICHARD MICHAEL BARTON, Deceased

Case No. 2023-1802

MARTHA ELLEN BARTON as Executrix under the last will and testament of RICHARD MICHAEL BARTON, Deceased

Attorney of Record:

BRITTEN LESLIE BRITT

Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of FRANKLIN LOUIS SHUFORD JR., Deceased

Case No. 2023-1867

Take notice that Letters Testamentary have been granted to the below named party on the 27th day of September, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.

BARBARA GRISSETT SHUFORD as Executrix under the last will and testament of FRANKLIN LOUIS SHUFORD JR., Deceased

Attorney of Record:

VAUGHN DRINKARD, JR

Call News October 4, 11, 18, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of ANGELO WALTER SEMIFERO, Deceased

Case No. 2023-1462

RONALD JAMES MARCHLEWSKI JR. as Executor under the last will and testament of ANGELO WALTER SEMIFERO, Deceased

Attorney of Record:

KENNETH A. WATSON

Call News October 4, 11, 18, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of MATTHEW D. ROSIER, Deceased

Case No. 2023-1824

EMILY DIANE ROSIER as Executrix under the last will and testament of MATTHEW D. ROSIER, Deceased

Attorney of Record:

JOHN A WENZEL

Call News October 4, 11, 18, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of MICHAEL NIKKEL KERNARD REESE

Case No. 2023-1620

Take notice that Letters of Administration have been granted to the below named party on the 29th day of September, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.

LURETTA NICOLE COLEMAN as Administratrix of the estate of MICHAEL NIKKEL KERNARD REESE, deceased

Attorney of Record:

STEPHEN E. CLEMENTS, Esq.

Call News October 4, 11, 18, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of EDDIE DALE RATCLIFF

Case No. 2023-1058

Take notice that Letters of Administration on the Annexed Will have been granted to the below named party on the 27th day of September, 2023, by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.

AUSTIN DEAN RATCLIFF, as Administrator CTA under the last will and testament of EDDIE DALE RATCLIFF, Deceased

Attorney of Record:

JOHN T. BENDER

Call News October 4, 11, 18, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of MARTHA PARK

Case No. 2023-1503

Take notice that Letters Testamentary have been granted to the below named party on the 20th day of September, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.

LORNA ELIZABETH PARK HODGES as Executrix of the estate of MARTHA PARK, deceased

Attorney of Record:

BILLY C. BEDSOLE

Call News October 4, 11, 18, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of JAMES PACKER SR

Case No. 2023-1606

Take notice that Letters of Administration have been granted to the below named party on the 28th day of September, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.

ANTHONY M. HOFFMAN, as Administrator of the estate of JAMES PACKER SR, Deceased

Attorney of Record:

ANTHONY M. HOFFMAN

Call News October 4, 11, 18, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of MABLE S MOORER

Case No. 2023-1856

Take notice that Letters of Administration have been granted to the below named party on the 26th day of September, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.

HENRY J JACKSON as Administrator of the estate of MABLE S MOORER, deceased

Attorney of Record:

PAGE STANLEY ELLIS, Esq.

Call News October 4, 11, 18, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of WILMA JEAN LOTT, Deceased

Case No. 2023-1866

ROBERT JAMES SNYDER as Executor under the last will and testament of WILMA JEAN LOTT, Deceased

Attorney of Record:

ROBERT TURNIPSEED

Call News October 4, 11, 18, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of JAMES W. KIRKSEY JR., AKA JAMES WILLE KIRKSEY, Deceased

Case No. 2023-1868

GLORIA BURKS as Executrix under the last will and testament of JAMES W. KIRKSEY JR., AKA JAMES WILLE KIRKSEY, Deceased

Attorney of Record:

VAUGHN DRINKARD, JR

Call News October 4, 11, 18, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of PAUL ALLEN GARRETT

Case No. 2023-0425

BARRY TAYLOR GARRETT as Executor of the estate of PAUL ALLEN GARRETT, deceased

Attorney of Record:

RICHARD DAVID ALLEN

Call News October 4, 11, 18, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of HELEN M. CHARLTON, Deceased

Case No. 2023-0771

Take notice that Letters of Administration on the Annexed Will have been granted to the below named party on the 27th day of September, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.

ANTHONY M. HOFFMAN Administrator CTA under the last will and testament of HELEN M. CHARLTON, Deceased

Attorney of Record:

ANTHONY M. HOFFMAN

Call News October 4, 11, 18, 2023

NOTICE OF ESTATE ADMINISTRATION

PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of LENORA A CADDEN, Deceased

Case No. 2023-1729

Take notice that Letters Testamentary have been granted to the below named party on the 29th day of September, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.

E. ED CADDEN AKA WILLIAM EDWIN CADDEN as Executor under the last will and testament of LENORA A CADDEN, Deceased

Attorney of Record:

MICHAEL R HOLBERG

Call News October 4, 11, 18, 2023

NOTICE OF COURT PROCEEDINGS

November 13, 2023

Case No. 2023-1887

In Re: Charles Murdock Welch, an alleged incapacitated person

On to-wit, the 13th day of October, 2023, at 10:00 AM in Courtroom. 1, Third Floor, Mobile County Government Center Annex, 151 Government Street, Mobile, Alabama, 36602, the Court will proceed to consider the Petition for Letters of Conservatorship and Guardianship filed by Kim Hervet MacWilliam. Notice is hereby given to all parties in interest, specifically Christopher Charles Welch, who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

Don Davis

Judge of Probate

Attorney:

John R. Nix, Esq.

1325 Dauphin Street

Mobile, AL 36604

Call News October 18, 25 and November 1, 2023

NOTICE OF COURT PROCEEDING

October 12, 2023

Case No. 2022-0528

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of ELVIN LEO BLAIR, Deceased

On to-wit the 13th day of November, 2023 at 9:30 AM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the PROBATE OF WILL as filed by NEWELL WESLEY RALSTON JR. NOTICE is hereby given to all parties in interest, specifically AZSPEN ROHR, PEGGY PARMER GILCHRIST, who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

DON DAVIS, Judge of Probate

Attorney:

LUE E SULLIVAN SR

555 A IROQUOIS STREET

CHICKASAW, AL 36611

Call News October 18, 25, and November 1, 2023

NOTICE OF COURT PROCEEDING

October 13, 2023

Case No. 2023-0290-1

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of TREYH LASHAWN WEBSTER, Deceased

On to-wit the 4th day of December, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT BY SURETY as filed by RLI INSURANCE COMPANY. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

DON DAVIS, Judge of Probate

Attorney: JAMES J. DUFFY III

P.O. BOX 1109

MOBILE, AL 36633

Call News October 18, 25 and November 1, 2023

NOTICE OF COURT PROCEEDING

October 13, 2023

Case No. 2020-2299-6

IN THE PROBATE COURT OF

MOBILE COUNTY ALABAMA

Estate of BOBBY GENE RITTINGHOUSE, Deceased

On to-wit the 13th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Sale of Real Property as filed by ELIZABETH RITTINGHOUSE. NOTICE is hereby given to all parties in interest, specifically NICOLE MOTT, BRANDON RITTINGHOUSE, who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

DON DAVIS, Judge of Probate

Attorney: PAGE STANLEY ELLIS

169 DAUPHIN STREET, SUITE 304

MOBILE, AL 36602

Call News October 18,25, and November 1, 2023

NOTICE OF COURT PROCEEDING

October 12, 2023

Case No. 2021-1502-2

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of ERNEST HOLLINS, Deceased

On to-wit the 27th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Final Settlement as filed by TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

DON DAVIS, Judge of Probate

Attorney:

BRIAN A. DODD

3973 BIBURY LN

BIRMINGHAM, AL 35242

Call News October 18, 25 and November 1, 2023

NOTICE OF COURT PROCEEDING

September 22, 2023

Case No. 2014-1753-1

IN THE PROBATE COURT OF

MOBILE, COUNTY, ALABAMA

Estate of RUDOLPH PUGH, Deceased

On to-wit the 6th day of November, 2023 at 2:00 p.m. in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Final Settlement as filed by CARRIE RIVERS. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

Don Davis, Judge of Probate

Petitioner:

Carrie Rivers

6312 Spice Pond Rd.,

Mobile, AL 36613

Call News October 18, 25, and November 1, 2023

NOTICE OF COURT PROCEEDING

October 11, 2023

Case No. 2021-0561-1

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of BESSIE B WATT, Deceased

On to-wit the 27th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT BY SURETY as filed by WESTERN SURETY COMPANY. NOTICE is hereby given to all parties in interest, specifically JANICE FUNCHES, who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

DON DAVIS, Judge of Probate

Attorney:

JAMES J. DUFFY III

P.O. BOX 1109

MOBILE, AL 36633

Call News October 18, 25, and November 1, 2023

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

CASE NO. 2021-0424

IN THE MATTER OF THE ESTATE OF CHARLES WINSTON JOHNS, SR., DECEASED,

NOTICE OF ESTATE SALE

Anthony M. Hoffman, as Administrator for the above-referenced Estate, gives notice of his intent to conduct an Estate Sale selling coins and silver.

The sale shall be conducted by Anthony Hoffman. The terms of said sale shall be that said coins will be sold as one lot, to sell all items for a price not less than the price as marked or for the highest offer. The SALE shall be conducted during the hours of 1:00 p.m. to 3:00 p.m. Friday, November 10, 2023, at 5 Dauphin Street, Suite 301, Mobile, Alabama 36602. Security will be present.

Same-day payment required in a manner satisfactory to the Administrator, with delivery of items upon payment.

Attorney:

ANTHONY M. HOFFMAN

P.O. BOX 11

Mobile, AL 36601

Call News October 18, 25, and November 1, 2023

NOTICE OF COURT PROCEEDING

CASE NO. 2023-1901

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Notice of the filing of Petition for Summary Distribution in the estate of Dorothy M. Nelson, Deceased.

Notice is hereby given that a Petition for Summary Distribution has been filed by Fred Nelson, Jr. on September 29, 2023, and that 30 days after the notice of publication hereof and pursuant to law the Court shall be requested to enter an order directing summary distribution of the estate of said decedent.

Don Davis, Judge of Probate

Attorney:

Anna M. Williams, Esq.

P O Drawer 446

Grand Bay, AL 36541

Call News October 18, 2023

NOTICE OF COURT PROCEEDING

October 06, 2023

Case No. 2022-1314-2

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of RICHARD IVY, Deceased

On to-wit the 20th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Amended Petition for Sale of Real Property and Personal Property as filed by Anthony Hoffman, Esq. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

DON DAVIS, Judge of Probate

Attorney:

ANTHONY M. HOFFMAN

P.O. BOX 11

Mobile, AL 36601

Call News October 11, 18, 25, 2023

NOTICE OF COURT PROCEEDING

October 05, 2023

CASE NO. 2001-1755-4

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of BARBARA ANN DILLARD, Deceased

On to-wit the 20th day of November 2023 at 2:00 PM in COURTROOM #1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by CHRISTOPHER DILLARD. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they think proper.

Don Davis, Judge of Probate

Attorney:

CREOLA G. RUFFIN

Post Office Box 40404

Mobile, Alabama 36640-0404

Call News October 11,18, 25, 2023

NOTICE OF COURT PROCEEDING

October 06, 2023

Case No. 2019-1408-3

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of RAY FEE PERINE SR, Deceased

On to-wit the 20th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT BY SURETY as filed by WESTERN SURETY COMPANY. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

DON DAVIS, Judge of Probate

Attorney:

JAMES J. DUFFY III

P.O. BOX 1109

MOBILE, AL 36633

Call News October 11, 18, 25, 2023

NOTICE OF COURT PROCEEDING

October 06, 2023

Case No. 2022-0010-3

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of WALTER EARL JOHNSON JR, Deceased

On to-wit the 20th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT BY SURETY as filed by RLI INSURANCE COMPANY. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

DON DAVIS, Judge of Probate

Attorney:

JAMES J. DUFFY Ill

P.O. BOX 1109

MOBILE, AL 36633

Call News October 11, 18, 25, 2023

NOTICE OF COURT PROCEEDING

October 05, 2023

Case No. 2022-1217-2

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of CHRISTIE LOCKHART O’CAIN, Deceased

On to-wit the 13th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Sale of Real Property for the Payment of Debts as filed by Anthony Hoffman, Esq. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

DON DAVIS, Judge of Probate

Attorney:

ANTHONY M. HOFFMAN

P.O. BOX 11

Mobile, AL 36601

Call News October 11, 18, 25, 2023

NOTICE OF COURT PROCEEDING

September 22, 2023

Case No. 2021-2348-1

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of LLOYD WRAY BLACK, Deceased

On to-wit the 6th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by MARY ELIZABETH BLACK. NOTICE is hereby given to all parties in interest, specifically JIMMY WRIGHT, RILEY WRIGHT, who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

DON DAVIS, Judge of Probate

Attorney:

PATRICIA WINSTON HALL

4055 COTTAGE HILL RD #103-D

Mobile, AL 36609

Call News October 11, 18, 25, 2023

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

CASE NO: 2013-1603

IN THE MATTER OF THE ESTATE OF RUBY DANIELS RIDINGS, Deceased

NOTICE OF COURT PROCEEDING AND SALE OF PERSONAL PROPERTY

Take notice that on February 10, 2023 the Honorable Don Davis, Judge of Probate, granted a Petition to Sell Personal Property consisting of home goods, collectables, jewelry and other items. The sale of that personal property will occur online only at www.buddyray.com beginning on Monday October 23, 2023 and will continue from day to day until Monday October 30, 2023. The sale will be conducted by Buddy Ray Auction and Appraisal on behalf of the said Estate.

For further sale details, contact Buddy Ray Auction and Appraisal 251-544-9661.

Attorney:

Daniel Barlar, Jr.

Barlar Law, LLC

Post Office Box 3045

Mobile, Alabama 36652

Call News October 4, 11, 18, 2023

NOTICE OF COURT PROCEEDING

September 27, 2023

Case No. 2022-1936-2

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of ARMAND AUSTIN ROBINSON, Deceased

On to-wit the 13th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT AND REPORT OF INSOLVENCY as filed by ANTHONY M. HOFFMAN. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

DON DAVIS, Judge of Probate

Attorney:

ANTHONY M. HOFFMAN

P.O. BOX 11

Mobile, AL 36601

Call News October 4, 11, 18, 2023

NOTICE OF COURT PROCEEDING

September 27, 2023

Case No. 2023-0488-2

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of YONG WOON CHUNG, Deceased

On to-wit the 6th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Sale of Real Property for Debts as filed by Anthony Hoffman, Esq. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

DON DAVIS, Judge of Probate

Attorney:

ANTHONY M. HOFFMAN

P.O. BOX 11

Mobile, AL 36601

Call News October 4, 11, 18, 2023

NOTICE OF COURT PROCEEDING

September 29, 2023

Case No. 2021-1837-2

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of THOMAS FROWNER SR, Deceased

On to-wit the 13th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Final Settlement and Report of Insolvency as filed by TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

DON DAVIS, Judge of Probate

Attorney:

BRIAN A. DODD

3973 BIBURY LN

BIRMINGHAM, AL 35242

Call News October 4, 11, 18, 2023

NOTICE OF COURT PROCEEDING

September 27, 2023

Case No. 2021-0745-2

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of TERRY GLEN BRUNSON, Deceased

On to-wit the 13th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by BRENDA STOKLEY BRUNSON. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

DON DAVIS, Judge of Probate

Attorney:

MICHAEL JACK HARBIN

PO BOX 851372

MOBILE, ALABAMA 36685

Call News October 4, 11, 18, 2023

NOTICE OF COURT PROCEEDING

September 28, 2023

Case No. 2022-0815-3

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of EMMA LUCRETIA BEDFORD, Deceased

On to-wit the 6th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Sale of Real Property as filed by DAVID J BEDFORD. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto If they then think proper,

BON DAVIS, Judge of Probate

Attorney

NOEL J, NELSON

P.O. BOX 2573

Mobile, AL 36652

Call News October 4, 11, 18, 2023

NOTICE OF COURT PROCEEDING

September 27, 2023

Case No. 2022-1143-1

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of BETTY ANN BROGLEN, Deceased

On to-wit the 13th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by BOBBY BROGLEN. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

DON DAVIS, Judge of Probate

Attorney:

WILLIAM C. POOLE

917 WESTERN AMERICA CIR STE 210

Mobile, AL 36609

Call News October 4, 11, 18, 2023

NOTICE OF COURT PROCEEDING

September 27, 2023

Case No. 2017-0490-3

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of CORINE C JACKSON, Deceased

On to-wit the 13th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT AND REPORT OF INSOLVENCY as filed by WESTERN SURETY COMPANY. NOTICE is hereby given to all parties in interest, specifically MARQUES A JACKSON, ANTONIO L JACKSON, who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

DON DAVIS, Judge of Probate

Attorney:

JAMES J. DUFFY III

P.O. BOX 1109

MOBILE, AL 36633

Call News October 4, 11, 18, 2023

NOTICE OF COURT PROCEEDING

September 25, 2023

Case No. 2014-1317-2

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of GERALD HARDER, Deceased

On to-wit the 6th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT AND REPORT OF INSOLVENCY as filed by MICHAEL EUGENE HARDER. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

DON DAVIS, Judge of Probate

Attorney:

PAGE STANLEY ELLIS

169 DAUPHIN STREET, SUITE 304

MOBILE, AL 36602

Call News October 4, 11, 18, 2023

NOTICE OF COURT PROCEEDING

September 26, 2023

Case No. 2021-0497-2

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of JULIA (JUDY) I. NICHOLAS, Deceased

On to-wit the 30th day of October, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT BY FORMER PERSONAL REPRESENTATIVE as filed by JOE SMITH. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

DON DAVIS, Judge of Probate

Attorney:

ANTHONY M. HOFFMAN

P.O. BOX 11

Mobile, AL 36601

Call News October 4, 11, 18, 2023

NOTICE OF COURT PROCEEDING

September 22, 2023

Case No. 2017-1361-3

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of BARBARA ANDRY ROGERS, Deceased

On to-wit the 6th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Sale of Real Property as filed by ANTHONY M. HOFFMAN. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

DON DAVIS, Judge of Probate

Attorney:

ANTHONY HOFFMAN, ESQ.

P.O. BOX 11

MOBILE, ALABAMA 36601

Call News October 4, 11, 18, 2023

NOTICE OF COURT PROCEEDING

September 26, 2023

Case No. 2020-2299-6

IN THE PROBATE COURT OF

MOBILE COUNTY, ALABAMA

Estate of BOBBY GENE RITTINGHOUSE, Deceased

On to-wit the 13th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Sale of Real Property as filed by ELIZABETH RITTINGHOUSE. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.

DON DAVIS, Judge of Probate

Attorney:

PAGE STANLEY ELLIS

169 DAUPHIN STREET, SUITE 304

MOBILE, AL 36602

Call News October 4, 11, 18, 2023

Completion Notice

NOTICE OF COMPLETION

In accordance with Chapter 1, Title 39, Code of Alabama, 1975, notice is hereby given that

Bay Area Contracting, Inc. (Contractor), has completed the Contract for (Construction), (Renovation), (Alteration), (Equipment), (Improvement) of Brooks Park Landing Public Access Enhancements For the State of Alabama and the (Mobile) (Chickasaw), Alabama, Owners, and have made request for final settlement of said Contract. All persons having any claim for labor, materials, and otherwise in connection with this project should immediately notify Kimley-Horn and Associates, Inc. 11 North Water Street, Suite 9290 Mobile, AL 36602

Bay Area Contracting, Inc., Contractor

P.O. Box 8312 Mobile, AL 36689

Call News October 18, 25 and November 1, 8, 2023

LEGAL NOTICE

H.O. WEAVER & SONS, INC. hereby gives notice of completion of contract with the MOBILE COUNTY COMMISSION for construction of Project No. MCR-2022-104 in MOBILE COUNTY. This notice will appear for four consecutive weeks beginning on 10/18/2023 and ending on 11/1/2023 All claims should be filed at H.O. Weaver & Sons, Inc P.O. Box 8039 Mobile, AL 36689 during this period.

P.O. WEAVER & SONS, INC.

Call News October 18, 25, and November 1, 2023

NOTICE OF COMPLETION

WATER DISTRIBUTION SYSTEM IMPROVEMENTS

CONTRACT A

LeMoyne Water System, Inc.

Nordan Contracting Co., Inc. has completed the contract requirements for the above project. ANY PERSONS HAVING A CLAIM AGAINST THE PROJECT SHOULD NOTIFY William G. Luker, Speaks & Associates, Consulting Engineers, Inc., 732 Oak Circle Drive West, Mobile, Alabama 36609 (telephone 251-666-4646). All claims should be filed within 30 days of publication of this notice.

Nordan Contracting Company, Inc.

PO Box 336

Saraland, AL 36571-0336

Call News October 11, 18,25, and November 1, 2023

Notice is hereby given that Underground, Inc., has completed the contract with Mobile County Water, Sewer, and Fire Protection Authority for GOMESA Bellingrath SS Force Main Ext. – Phase B (Contract No. 448923B). Any claims held against same shall be itemized, notarized and presented

to Mobile County Water, Sewer, and Fire Protection Authority at its offices or same will be barred.

Call News October 11, 18, 25 and November 1, 2023

STATE OF ALABAMA

COUNTY OF MOBILE

NOTICE OF COMPLETION

In accordance with chapter 1, Title 39, Code of Alabama, 1975, notice is hereby given that AEIKER CONSTRUCTION CORPORATION, Contractor, has completed the Contract for MCV-PF-20-001 for the Mobile County Commission, Mobile, Alabama, Owner(s), and have made a request for final settlement of the said contract. All persons having any claim for labor, materials, or otherwise in conjunction with this project should immediately notify Mobile County Facilities Design and Construction, Mobile, Alabama

Call News September 27, and October 4, 11, 18, 2023

Notice of Completion

Southern Land Development, LLC gives notice of completion of Contract with County Commission of Mobile County Project: MCR-2016-307 Hilltop Road/Walther Road GDBP All claims should be filed at: Southern Land Development, LLC, 10351 Tanner Williams Rd., Mobile, AL 36608.

Call News September 27, and October 4, 11, 18, 2023

STATE OF ALABAMA

COUNTY OF MOBILE

NOTICE OF COMPLETION

In accordance with Chapter I, Title 39, Code of Alabama, 1975, NOTICE IS HEREBY given

that S. C. Stagner Contracting, Inc., has completed the contract for the City of Citronelle LeBaron Avenue-Sixth Street Drainage Improvements project. All persons having any claim for labor, material or otherwise in connection with this project should immediately contact Speaks & Associates Consulting Engineers, Inc. 732 Oak Circle Drive West Mobile, AL 36609

Call News September 27 and October 4, 11, 18, 2023

STORAGE SALE

Life Storage will hold a public auction to sell personal property described below belonging to those individuals listed below at the location indicated:

3259: 8781 Airport Blvd, Mobile, AL 36608

Auction Date: 11/15/2023 at 11:30 PM

Units: A10, C136, C165, C200, D229, G397, G414, G451, H475, I521, I525, J537, J553, K690, K729, K810

Call News November 1, 2023

STORAGE SALE

Old Pas Storage LLC will hold a public auction to sell personal property described below belonging to those individuals listed below at the location indicated:

8601 Old Pascagoula Rd., Theodore, AL 36582

Auction Date: 10/27/2023 at 12:00 PM

Unit: A5 Christy L Tew 8816 Hunters Pointe Dr. S, Theodore, AL 36582

Unit A8, A14, A7 David E. Boles 8020 Oak Bend Dr., Theodore, AL 36582

Unit 3 Debra Foster 7121 Kenny Lundy Rd., Theodore, AL 36582

Auction will be listed and advertised on www.storagetreasures.com. Purchases must be made with cash only and paid at the above referenced facility in order to complete the transaction. Extra Space Storage may refuse any bid and may rescind any purchase up until the winning bidder takes possession of the personal property.

Call News October 11, 18, 2023

Extra Space Storage will hold a public auction to sell personal property described below belonging to those individuals listed below at the location indicated:

7403: 429 Bel Air Blvd, Mobile, AL 36606

Auction Date: 11/01/2023 at 12:00 PM

Unit: 1004, 1282

7926: 3679 Airport Blvd, Mobile, AL 36608

Auction Date: 11/01/2023 at 12:30 PM

Unit: 2064, 2132, 2136

Call News October 18, 2023

BILL

STATE OF ALABAMA

COUNTY OF MOBILE

Notice is hereby given that a bill as described in the synopsis below will be introduced in the 2024 Regular Session of the Legislature of Alabama and application for its passage and enactment will be made:

A BILL

TO BE ENTITLED

AN ACT

SYNOPSIS: To authorize any Class 2 municipality to establish a delegation agreement with the Department of Environmental Management for the local enforcement of the Scrap Tire Environmental Quality Act; and provide for jurisdiction for violations within a Class 2 municipality.

Call News October 18, 25, and November 1, 8, 2023

STATE OF ALABAMA

COUNTY OF MOBILE

A BILL

TO BE ENTITLED

AN ACT

SYNOPSIS: Relating to Class 2 municipalities; to amend sections 11-44C-7 and 11-44C-9, Code of Alabama 1975 relating to the deadline to qualify as a candidate for city council and mayor prior to the election; to extend the qualifying deadline from 60 days prior to the election to 90 days.

Call News September 27, 2023 and October 4, 11, 25, 2023

SHERIFF’S SALE

CASE NO. CD-12762

STATE OF ALABAMA

COUNTY OF MOBILE

Alabama Department of Revenue

Leonard V Stiell and Linda R. Stiell aka Leonard Vincent Stiell and Linda Ray Stiell

Under and by virtue of a Writ of Fieri Facias issued out of the Department of Revenue Court of Montgomery County in the above styled case, I will proceed to sell to the highest and best bidder, for cash, on October 30, 2023 at the hour of 12:00 NOON, at the courthouse, Government Street Entrance to the North Tower of Government Plaza, all the right, title and interest of Leonard V Stiell and Linda R Stiell aka Leonard Vincent Stiell and Linda Ray Stiell, in and to the following described Real property, to-wit:

Lots 3 & 4 BLK 9 West Mobile S/D DBK 93 P 157 #SEC 7 T4S R1W #MP29 03 07 4 003 Sold subject to existing liens, if any.

PAUL BURCH JR SHERIFF,

MOBILE COUNTY

Call News October 4, 11, 18, 2023

PUBLIC HEARING

NOTICE OF PUBLIC HEARING

CITY OF SATSUMA, ALABAMA

Notice is hereby given that the City of Satsuma will hold a Public Participation Meeting on Monday, November 13, 2023 at 5:30 PM (CST). The meeting location will be in the City of Satsuma Water and Sewer Board’s Office at 5502 Old Highway 43, Satsuma, AL. The purpose of the meeting is to share an overview of three projects that have been submitted to the Alabama Department of Environmental Management, ADEM, for approval. All individuals, who may be adversely affected by these projects are encouraged to attend and make your comments known. Reports and data relevant to the discussion are available for the public’s review at the office of the Satsuma Water and Sewer Board.

Call News October 4, 11, 18, 25, 2023

NOTICE

MOBILE COUNTY HOUSING

AUTHORITY

PUBLIC HEARING

The purpose of the public hearing is to obtain input from residents and members of the community relative to the Annual Plan for 2024 and the Five Year Action Plan to be submitted to the U. S. Department of Housing and Urban Development.

The Public Hearing will be held Monday, November 13, 2023, 5:00 p.m. at our office located at 16545 U. S. Hwy 45, Citronelle, AL 36522.

All residents are encouraged to attend this hearing. The hearing is open to all residents and citizens in the community. Any citizen needing a reasonable accommodation may contact the Housing Authority. The Public Housing Agency Plan will be available for public review at the public housing office between the hours of 9:00 a.m. and 4:00 p.m. Persons may also submit written comments prior to the public hearing.

For further information, please contact Tyronnda Turner Bethune, Executive Director at (251) 866-9696.

MOBILE COUNTY HOUSING AUTHORITY

PUBLIC HEARING

Call News September 27 and October 4, 11, 18, 25, November 2, 8, 2023

PUBLIC MEETING

TECHNICAL COORDINATING COMMITTEE (TCC)/CITIZEN ADVISORY COMMITTEE (CAC)

of the MOBILE METROPOLITAN PLANNING ORGANIZATION (MPO) MEETING

The Mobile MPO Technical Coordinating Committee/Citizen Advisory Committee (TCC/CAC) will meet on Wednesday, October 25th, 2023 at 10:00 am at the GM&O Building at 110 Beauregard St, Mobile, AL 36602.

The committee will review and recommend for approval to the MPO the following amendments to the FY 2024-2027 Transportation Improvement Program:

100070136; PE; Causeway Access Management Plan and Signalization on SR-16 (US-90/98) from west of the Bankhead Tunnels to the US-98 Bypass; 11/1/2023; $367,853.51
100070137; CN; Causeway Access Management Plan and Signalization on SR-16 (US-90/98) from west of the Bankhead Tunnels to the US-98 Bypass; 9/24/2027; $2,707,141.76.00
CN; Resurfacing, Restoration, and Rehabilitation of Snow Road South from Jeff Hamilton Road to Airport Blvd; 11/1/2023; $2,449,000.00
CN; Resurfacing, Restoration, and Rehabilitation of Snow Road North from Tanner Williams Road to U.S. Highway 98; 11/1/2023; $5,892,000.00
100077358; SP; Traffic Impact Study for SR-158 at I-65; 10/1/2023; $124,195.00

Also on the agenda is an amendment to the FY2024 Unified Planning Work Program to include a task for a Traffic Impact/Feasibility Study for McCrary Road from US-98 to Spice Pond Road Extension and Spice Pond Road Extension from McCrary Road to Lott Road for $57,225.00

The Mobile Metropolitan Planning Organization Policy Board will vote on the recommendations by the TCC/CAC at a meeting on Wednesday, November 8th, 2023 at 10:00 AM at the GM&O Building located at 110 Beauregard Street, Mobile, AL 36602.

Physically challenged persons who need special accommodations should contact SARPC in advance so arrangements can be made to meet their needs. Additional information may be obtained from the Transportation Planning Coordinator at the South Alabama Regional Planning Commission, (251)433-6541 or transporation@sarpc.org.

Call News October 18, 25, 2023

ALABAMA DEPARTMENT OF

ENVIRONMENTAL MANAGEMENT

NOTICE OF APPLICATION FOR

UNDERGROUND INJECTION CONTROL (UIC) PERMIT

AND REQUEST FOR COMMENTS

PUBLIC NOTICE – 212

Clarke County

Coffeeville Utilities Board c/o Mr. Bill Taylor, P.O. Box 88 Coffeeville, AL 36524, UIC Permit Number ALSI9913002 has applied for the reissuance of a permit for Class V Injection Wells at Coffeeville WWTP, West Bend Road, Coffeeville, AL 36524 for discharge resulting from the injection of treated sanitary effluent from a wastewater treatment facility.

The draft permit contains requirements and limitations which are protective of groundwater quality.

Copies of the draft permit, conditions, limitations and a fact sheet as applicable describing the methodology for setting the limitations and conditions and other related documents are available for public inspection electronically via http://adem.alabama.gov/newsEvents/publicNotices.cnt, and at the following location Monday – Friday (except legal holidays), 8:00 am to 5:00 pm. A nominal fee for copying and/or mailing may be charged. Arrangements for copying should be made in advance.

Jeffery W. Kitchens, Chief

ADEM-Water Division

1400 Coliseum Blvd.

[Mailing address: PO Box 301463; Zip 36130-1463]

Montgomery, Alabama 36110-2400

(334) 271-7823

water-permits@adem.alabama.gov

Persons wishing to comment may do so, in writing, to the Department’s named contact above within 30 days following the publication date of this notice. COMMENTERS SHOULD IDENTIFY THE APPROPRIATE UIC PERMIT NUMBER ON THE FIRST PAGE OF THEIR COMMENTS. In order to affect final decisions, comments must offer technically substantial information that is applicable to the draft permit.

A written request for a public hearing may also be filed within that 30-day period and must state the nature of the issues proposed to be raised in the hearing. The Director shall hold a public hearing whenever it is found, on the basis of hearing requests, that there exists a significant degree of public interest in the permit application or draft permit. The Director may also hold a hearing if he determines that it would clarify one or more issues involved in the permit decision.

After consideration of all written comments, review of any public hearing record, and consideration of the requirements of the Alabama Water Pollution Control Act, the Federal Water Pollution Control Act and applicable regulations, the Department will make a final determination. The Department will develop a response to comments, which will become part of the public record. The Department will post responses to comments as well as the final permit determinations to the Department’s website at http://app.adem.alabama.gov/eFile/. To find the response to comments and final permit determination, you may search by the permit number listed in this notice.

The Department maintains a list of interested individuals who are emailed legal notices regarding proposed permits. If you wish to receive such notices, please sign up at http://adem.alabama.gov by entering your email address on the left side of the page and clicking the submit button.

Notice is hereby given this 18th day of October, 2023, by authorization of the Alabama Department of Environmental Management.

Lance R. LeFleur, Director

Nondiscrimination Statement: The Department does not discriminate on the basis of race, color, national origin, sex, religion, age or disability in the administration of its programs.

Call News October 18, 2023

Alabama Department of Environmental Management

P.O. Box 301463 (Zip 36130-1463)

1400 Coliseum Boulevard (Zip 36110-2400)

Montgomery, Alabama

(334) 271-7700

CATEGORICAL EXCLUSION FROM ENVIRONMENTAL REVIEW

ADEM Fund Code 245

Utilities Board of the Town of Grove Hill

Clarke County

SRF Project No. FS010197-02

The Alabama Department of Environmental Management has made $1,550,000 in financial assistance available to the Utilities Board of the Town of Grove Hill using funds from the FY2022 Drinking Water State Revolving Bipartisan Infrastructure Legislation Fund (DWSRF BIL) loan program. In accordance with State and Federal regulations that govern the program, the Alabama Department of Environmental Management has conducted a review to assess the potential impacts upon the environment that may result from implementation of this project.

The Utilities Board of the Town of Grove Hill proposes a project to improve the reliability of drinking water for the community by installing a new well and a short section of water main to allow supply of water from the well from two (2) different directions. The completion of this project will ensure the citizens served by the Utilities Board of the Town of Grove Hill have a reliable source of drinking water.

The Alabama Department of Environmental Management has determined that the project qualifies for a Categorical Exclusion (CE) from further environmental study under the guidelines specified by the State Environmental Review Process (SERP) which specifically include actions which are solely directed toward minor rehabilitation of existing facilities, functional replacement of equipment, or towards the construction of new ancillary facilities adjacent or appurtenant to existing facilities. However, this decision may be reconsidered if significant adverse information concerning the potential environmental impacts of the project is discovered.

Comments relative to this project should be submitted in writing to Mr. John Laney, SRF Section, Permits & Services Division, Alabama Department of Environmental Management, P.O. Box 301463, Montgomery, Alabama 36130, no later than 30 days after the date of this notice. The Alabama Department of Environmental Management will not take formal action to proceed with the project without carefully evaluating any public comments opposing the project.

Notice is hereby given this 18th day of October, 2023, by authorization of the Alabama Department of Environmental Management.

Lance R. LeFleur, Director

Nondiscrimination Statement: The Department does not discriminate on the basis of race, color, national origin, sex, religion, age or disability in the administration of its programs.

Call News October 18, 2023

ALABAMA DEPARTMENT OF ENVIRONMENTAL MANAGEMENT

NOTICE OF PROPOSED MODIFICATION OF THE POST-CLOSURE PERMIT UNDER THE ALABAMA HAZARDOUS WASTES MANAGEMENT AND MINIMIZATION ACT (AHWMMA) AND REQUEST FOR COMMENTS

PUBLIC NOTICE – 421

Mobile County

Rentokil Initial Environmental Services, LLC of Creola, Alabama submitted to ADEM an application for modification of its post-closure permit for its closed surface impoundments which were used to manage hazardous waste at its facility (EPA I.D. Number ALD 021 257 951) located at 10565 Highway 43 Creola, Alabama. The Department has determined the facility’s modification application to be complete and has prepared a draft permit in accordance with State regulations.

A predecessor company of Rentokil Initial Environmental Services, LLC previously operated a tank truck terminal. Rentokil Initial Environmental Services, LLC is the owner of the facility. The Post-Closure Permit modification addresses the revised Corrective Action Plan, which includes the use of monitored natural attenuation. It also addresses the updated Groundwater Monitoring, Sampling and Analysis Plan to reflect the revised Corrective Action Plan.

Copies of the fact sheet, permit modification application and draft AHWMMA permit are available for public inspection electronically via http://adem.alabama.gov/newsEvents/publicNotices.cnt and at the following location Monday – Friday (except legal holidays) during the hours of 8:00 a.m. to 5:00 p.m. A nominal fee for copying and/or mailing may be charged. Arrangements for copying should be made in advance.

Russell A. Kelly, Chief

Permits and Services Division

Alabama Department of Environmental Management

1400 Coliseum Blvd., Montgomery, Alabama 36110-2400

[Mailing address: P.O. Box 301463; Zip 36130-1463]

(334) 271-7714

permitsmail@adem.alabama.gov

Persons wishing to comment may do so, in writing or by email, to the Department’s named contact above no later than 5:00 p.m. on December 4, 2023. In order to affect final decisions, comments must offer technically substantial information that is applicable to the proposed permit.

A written request for a public hearing may also be filed no later than 5:00 p.m. on December 4, 2023, and must state the nature of the issues proposed to be raised in the hearing. The Director shall hold a public hearing upon receipt of a significant number of technical requests.

After consideration of all written comments, review of any public hearing record, and consideration of the requirements of the AHWMMA, the Federal Resource, Conservation and Recovery Act (RCRA) and applicable regulations, the Department will make a final determination. The Department will develop a response to comments, which will become part of the public record and will be available to persons upon request. Notice will be sent to any person requesting notice of the final action.

The Department maintains a list of interested individuals who are mailed legal notices regarding proposed permits. If you wish to receive such notices, contact the Permits & Services Division via telephone (334-271-7714), e-mail (permitsmail@adem.alabama.gov), or postal service (P.O. Box 301463, Montgomery, AL 36130-1463).

Notice is hereby given this 18th day of October, 2023, by authorization of the Alabama Department of Environmental Management.

Lance R. LeFleur

Director

Nondiscrimination Statement: The Department does not discriminate on the basis of race, color, national origin, sex, religion, age or disability in the administration of its programs.

Call News October 18, 2023

Abandoned Vehicle Auction

The following vehicles have been abandoned at 701 S Royal St. Mobile, AL 36603 and will be auctioned off on November 29, 2023 at 8:00 a.m. at 701 S Royal St. Mobile, AL 36603.

2012 CHEVROLET MALIBU

1G1ZB5E02CF296799

1996 BUICK LESABRE

1G4HR52K1TH426348

2008 FORD EXPEDITION

1FMFU17568LA02122

2011 DODGE CHARGER

2B3CL1CT7BH550716

2006 CHEVROLET MALIBU

1G1ZT51F46F196084

2014 TOYOTA COROLLA

2T1BURHE1EC125541

2016 NISSAN VERSA

3N1CN7AP5GL868076

2015 DODGE CHALLENGER

2C3CDZAG4FH783592

Call News October 18, 25, 2023

The following abandoned vehicle(s) will be sold at public auction on 11/22/2023 at 9:00 A.M. at 5663 Nevius Rd Mobile, AL 36619.

2010 Chevrolet Camaro

VIN#2G1FB1EV0A9180076

Call News October 18, 25, 2023

The following abandoned vehicle(s) will be sold at public auction on 11/22/2023 at 9:00 A.M. at 9955 Strickland Rd Lot A Grand Bay, AL 36541.

2008 Dodge Sprinter

VIN#WD0PF145685239180

Call News October 18, 25, 2023

Notice of Sale

In accordance with Section 32-13-1, Code of Alabama 1975, notice is hereby given to the owners, lien holders and other interested parties that the following described abandoned vehicle will be sold at public auction for cash to the highest bidder on 12/18/2023 at 12pm. Location Copart Auto Auctions 4763 Lott Rd Eight Mile, AL 36613.

2014 JEEP CHEROKEE GRAY

1C4PJMCS3EW232404

2002 FORD F150 BLACK

1FTRX172X2NB69609

2005 OTHER YUKON BLACK

1GKEC13T65J155294

2012 FORD FOCUS SILVER

1FAHP3F26CL456134

2016 TOYOTA COROLLA SILVER

2T1BURHE2GC687063

2010 VOLVO VN VNL WHITE

4V4NC9TG0AN291411

2012 NISSAN ALTIMA MAROON

1N4AL2AP1CC159458

2014 TOYOTA 4RUNNER BLUE

JTEZU5JR1E5081442

2009 CHEVROLET TAHOE WHITE

1GNFC13C99R170953

2007 DODGE RAM 1500 BLACK

1D7HA18207S200795

Call News October 18, 25, 2023

F&S Towing and Recovery 801 Schillinger’s Rd. N. Mobile, AL 36608 will auction off the following vehicles on 11/8/2023 at 9 a.m.

2005 Scion TC Black

JTKDE177750047294

2009 Lincoln MKS Black

1LNHM93R69G621670

2014 Ford Focus

1FADP3K22EL283476

2003 Chevrolet Silverado 2500HD Gold

1GCHK29UX3E236564

1996 Mercury Cougar Red

1MELM62W0TH636816

2005 Dodge Caravan White

1D4GP45R15B174165

2006 Infiniti G35 White

JNKCV51EX6M508708

2001 GMC Yukon

1GKEC13T61J165690

2005 Toyota Camry Gray

4T1BF32K05U599761

2014 Kia Forte

KNAFK4A67E5245044

2001 Dodge Ram Pickup 1500

1B7HC16Y51S312401

Call News Oct. 18, 2023 and Nov. 1, 2023

The following abandoned vehicles will be held for public auction on 11-17-23 at 10:00 a.m. at 7970 Zeigler Blvd. Mobile, AL 36608.

2017 Toyota Corolla

VIN: 5YFBURHE1HP729918

2014 Dodge Journey

VIN: 3C4PDCBG4ET142523

2010 Cadillac SRX

VIN: 3GYFNKE49AS650730

Call News October 11, 18, 2023

These abandoned vehicles will be sold on 11-15-23 at 5781 Three Notch Rd Mobile, AL 36619 at 9am if not redeemed before then.

NISS 1N6AA06A64N543649

CHEV 1G1ZB5ST0HF293258

Call News October 11, 18, 2023

Posted in Legals

Leave a Comment

Related Posts

MOBILE COUNTY PUBLIC NOTICES 12-06-2023 CLICK HERE

MOBILE COUNTY PUBLIC NOTICES 11-29-2023 CLICK HERE

MOBILE COUNTY PUBLIC NOTICES 11-22-2023 CLICK HERE

MOBILE COUNTY PUBLIC NOTICES 11-15-2023 CLICK HERE

MOBILE COUNTY PUBLIC NOTICES 11-08-2023 CLICK HERE