MOBILE COUNTY PUBLIC NOTICES 11-01-2023 CLICK HERE

BID NOTICES
THE WATER WORKS BOARD OF THE CITY OF BIRMINGHAM
Pressure Washing of the Gardendale and Higdon Hill Potable Water Tanks
Project Number:
NOTICE TO BIDDERS
Sealed Bids for the Pressure Washing of Gardendale and Higdon Hill Potable Water Tanks will be received by The Water Works Board of the City of Birmingham, Engineering Department, Attention: Ms. Hattye D. McCarroll, P.E. Chief Engineer, until 10:00 a.m. local time on Thursday, November 16, 2023, in the Engineering Department Conference Room on the Second Floor of the Main Campus Building located at 3600 First Avenue, North in Birmingham, Alabama, at which time they will be opened and read. Bids received after said time will be rejected and returned unopened.
The Work consists of pressure washing both tanks and providing ground containment. However, any coating that is damaged during the Work must be repainted by the Contractor, at the Contractor’s expense, and per all applicable specifications listed in the Contract Documents. In the event of any repainting, the Contractor is fully responsible for providing, at his expense, full containment of exterior painting operations to prevent the exit and drift of paint residue onto adjacent property, streets, or structures. No welding can be performed on either of these tanks in order to provide full containment.
Bidding Documents may be examined at the Birmingham Construction Industry Authority (BCIA), 601 – 37th Street, South, Birmingham, AL 35222; or at the office of the BWWB Project Manager – Engineering Department – Mr. Tony Free, Project Engineer, The Water Works Board of the City of Birmingham, 3600 First Avenue, North, Birmingham, AL 35222.
Prime Contractor bidders may obtain one complete set of Bidding Documents from the office of the Chief Engineer of The Water Works Board of the City of Birmingham upon payment of $150.00 deposit by company check or by certified check and signing a nondisclosure statement. No personal checks or any other form of payment except as noted will be accepted. This deposit shall be refunded in full to each prime contractor bidder upon the return of the Bidding Documents and drawings in a reusable condition within 10 days after the bid opening. Additional sets of Bidding Documents for prime contractor bidders, subcontractors, vendors, or dealers may be obtained upon payment of said $150.00 deposit and signing a nondisclosure statement. This deposit shall be refunded less the costs of printing, reproduction, handling, and distribution, upon return of the documents in reusable condition within 10 days after the bid opening. Company check or Certified check for documents shall be made payable to The Water Works Board of the City of Birmingham, 3600 First Avenue North, Birmingham, Alabama, 35222 and mailed to the Attn: Ms. Hattye McCarroll. P.E.; Chief Engineer. No additional charge will be made for delivery via UPS ground. Those requesting shipment of documents via carriers other than UPS ground will be made at the requesting firm’s expense. Partial sets of Bidding Documents will not be available to any Bidder. Neither the OWNER nor the ENGINEER will be responsible for full or partial sets of Bidding Documents, including any addenda, obtained from other sources. No Bidder may withdraw or alter his bid within sixty (60) calendar days after the actual date of the Bid Opening.
A Mandatory Pre-Bid Conference and Site Visit will be held at 10:00 a.m. local time on Tuesday, November 7, 2023 in the Engineering Department Conference Room located as shown above. After a short pre-bid meeting, a site visit will follow at the Gardendale Tank, 319 Day Street, Gardendale, Alabama 35071 followed by a site visit to the Higdon Hill Tank, 7004 6th Avenue South, Birmingham, Alabama 35212 All Prospective Bidders are required to attend the Pre-Bid Conference and site visit. The purpose of the Pre-Bid Conference is to raise questions pertaining to the Bidding Documents and Contract Documents and for the OWNER or its representatives to clarify any points. Bids will NOT BE ACCEPTED from any Prospective Bidder who does not attend the Pre-Bid Conference and site visit. All Prospective Bidders shall complete and submit the HUB Bid Solicitation Notice (HUB Form 3) no later than one (1) day after the scheduled date of the pre-bid conference (NO EXCEPTIONS). HUB Program Acknowledgement (HUB Form 1), HUB Compliance Form (HUB Form 2), HUB Subcontractor Performance Form (HUB Form 5) and HUB Subcontractor Utilization Form (HUB Form 6) of Section 00451 HUB Program must be submitted at the Bid Opening as shown above.
Each bid shall be accompanied by a cashier’s check, drawn on an Alabama Bank, or Bid Bond in the amount of five percent (5%) of the bid not to exceed $10,000.00 in the form and subject to conditions provided for in the Specifications.
The Successful Bidder will be required to furnish a Performance Bond and a Labor & Material Payment Bond each in an amount equal to one hundred percent (100%) of the Contract Award.
Bidders shall comply with all statutory requirements in accordance with the Instruction to Bidders. Bids will only be received from Contractors who are licensed by the State of Alabama.
Contract time of commencement and completion will be in accordance with the Agreement.
The Water Works Board of the City of Birmingham (“BWWB”) has adopted a voluntary Historically Underutilized Business (“HUB”) Program designed to encourage the participation of HUB firms in construction projects. To that end, the BWWB will never exclude any firm from participation in, deny any person benefits of, or otherwise discriminate in connection with the award and performance of BWWB contracts based on racial, gender, social, or economic status.
It is the intent of the BWWB to foster competition among contractors, suppliers and vendors that will result in better quality and more economical services for the BWWB. Under this program, the BWWB has established a goal of 30% participation of HUB firms for services required for BWWB construction projects. The BWWB’s stated goal will not be the determining factor in construction contract awards; rather bidders must demonstrate compliance with the Good Faith Efforts, more particularly outlined in the HUB Program, toward meeting said goal.
Failure on the part of a bidder to fully submit the information required herein may be considered by the BWWB in evaluating whether the bidder is responsive to bid requirements.
Alabama Code §31-13-9 (1975) provides that as a condition for the award of any contract by The Water Works Board of the City of Birmingham, a business entity or employer that employs one or more employees within the state of Alabama shall provide documentation of enrollment in the E-Verify program.
Each Prospective Bidder must complete, as a condition for the award of any Contract by The Water Works Board of the City of Birmingham, the Certification Regarding Debarment in Section 00201. The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).
Legislature of Alabama Act 2013-205 grants the Alabama Department of Revenue (ADOR) the authority to issue certificates of exemption from sales and use taxes for construction projects for certain governmental agencies. Pursuant to Act 2013-205, Section 1(g) the Contractor accounts for the sales tax not included in the Bid Form by submitting an Accounting of Sales Tax-Attachment to BWWB Bid Form. Failure to provide an accounting of sales tax shall render the bid non-responsive. Other than determining responsiveness, sales tax accounting shall not affect the bid pricing nor be considered in the determination of the lowest responsible and responsive bidder. After Notice of Award, Contractor and Subcontractor licensed by the State Licensing Board for General Contractors must comply with ADOR requirements for making application for qualification of the exemption and are responsible for ADOR reporting requirements for the duration of the project.
If a Contract is to be awarded, it will be awarded to the lowest responsive and responsible Bidder, who has neither been disqualified nor rejected pursuant to these Contract Documents, and whose Bid based on an evaluation by the OWNER indicates that the award will be in the best interest of the Project and will result in the lowest overall cost to the OWNER for completion of the project. If a Contract is to be awarded, it will be awarded within 30 calendar days after the day of the opening of bids.
The OWNER reserves the right to reject any and all proposals, the right to waive irregularities or to accept any proposal deemed to be in the best interest of the OWNER.
Owner:
The Water Works Board of the City of Birmingham (BWWB)
3600 First Avenue North
Birmingham, Alabama 35222
Hattye D. McCarroll, P.E., Chief Engineer
Telephone: (205) 244-4182
Owner’s Contact for Plans and Specifications
Engineering Department Administrative Assistant
Telephone: (205) 244-4180
Facsimile: (205) 244-4680
Owner’s Project Manager:
Primary Contact:
Mr. Tony Free
Project Engineer
Telephone: (205) 244-4288
E-mail: Tony.Free@bwwb.org
Call News November 1, 8, 2023

Sealed bid packages for Bid 23-05-39 Traveling Screens for Cahaba Pumping Station will be received in the Purchasing Department of the Birmingham Water Works Board, located at 3600 First Avenue North, Birmingham, Alabama 35222, until 10:00 a.m. (CST), November 21, 2023, at which time and place they will be publicly opened and read. All potential suppliers must receive an executed copy of the applicable Receipt of Bid Package from the BWW Purchasing Department before their bid package may be considered responsive, pending evaluation of appropriate staff. All bid packages must be hand-delivered to the BWW Purchasing Department, which is located at 3600 First Avenue North, Birmingham, Alabama 35222. The bid packages must be directed to the attention of the Purchasing Manager, and marked in the lower left-hand corner of the envelope as follows: “Bids for “Traveling Screens for Cahaba Pumping Station due on November 21, 2023, at 10:00 a.m. (CST)” at which time and place they will be publicly opened and read. Bid packages may be obtained through our website at www.bwwb.org, by emailing Matthew Shiver at matthew.shiver@bwwb.org, or by calling 205-244-4302.
Call News November 1, 8, 15, 2023

ADVERTISEMENT FOR BIDS
The Evergreen Conecuh Capital Improvement Cooperative District (ECCICD) is requesting competitive sealed bids for an earthwork, grading, and drainage project described as Liberty Hill Drainage Improvements. Project consists of the construction of a stormwater detention facility, and generally consists of the excavation and grading of on-site materials.
Sealed bids will be received by the Evergreen Conecuh Capital Improvement
Cooperative District (ECCICD), 100 Depot Square, Evergreen, AL, until 9 A.M. on 8 November, 2023, and then publicly opened for furnishing all labor and materials, and performing all work required by Evergreen-Conecuh Development Cooperative and described as follows:
Project: Liberty Hill Drainage Improvements
Project No.: 017826000
150 calendar days are allowed for the construction of the project.
All bids must be on blank forms provided in the specifications and submitted in its entirety. A cashier’s check drawn Conecuh County, on an Alabama bank or a bidder’s bond, payable to the ECCICD for an amount not less than five percent (5%) of the amount bid, but in no event more than ten thousand dollars ($10,000.00), shall be filed with the bid, as a bid guaranty. The bidder’s bond shall be prepared on the form specified and issued by a surety company authorized to do business in the State of Alabama.
A performance bond in the form and terms approved by the ECCICD in an amount not less than the contract price will be required at the signing of the contract. A labor and materials bond in the form and terms approved by the ECCICD in an amount not less than the contract price, insuring payment for all labor and materials, shall also be required at the signing of the contract. In addition, the contractor must furnish to the
ECCICD at the time of the signing of the contract a certificate of insurance coverage as provided in the specifications. The right is reserved to reject any and/or all bids and to waive informalities and to furnish any item of material or work to change the amount of said contract.
Liquidated damages for non‑completion of the work within the time limit agreed upon will be assessed in accordance with the terms of the contract.
Specifications are on file and may be viewed in the ECCICD, 100 Depot Square, Evergreen, AL and in the office of Kimley- Horn and Associates, 11 North Water Street, Suite 9290, Mobile, Alabama. Specifications may be obtained by prime contractor bidders by depositing $100.00 with the Project Engineer for each set. This deposit shall be refunded in full upon return of the documents in reusable condition within ten (10) days after bid opening. The cost of and return of additional sets of specifications shall be in accord with Section 39-2-3(b), Code of Alabama (1975). No Specifications will be issued later than twenty‑four (24) hours prior to the time indicated above for receiving bids.
A pre-bid conference will be held on 1 November, 2023 at 2:00 PM Central Time, at the ECCICD at 100 Depot Square, Evergreen, AL. All prospective bidders should have a representative present at the pre-bid conference. No bids will be considered unless the bidder, whether resident or non‑resident of Alabama, is properly licensed and qualified to perform the work described herein in accordance with all applicable laws of the State of Alabama. This shall include evidence of holding a current certificate to engage in general contracting in the State of Alabama, issued by the State of Alabama Licensing Board for General Contractors, Montgomery, Alabama, as required by Section 34-8-2, Code of Alabama (1975). Any contractor that desires to bid as a prime contractor must have at least one of the following major classifications of license per Section 230-X-1-.27 of the State of Alabama Licensing Board for General Contractors Administrative Code:
1.c.) Highways and Streets
1.d) Municipal and Utility
1.e) Heavy and Railroad Construction
Out of state corporations shall furnish a certificate of authority to transact business in Alabama. Out of state limited liability companies shall provide proof of registration to transact business in this state.
Prior to the award of a competitively bid contract to a contractor having one or more employees in the State of Alabama, Alabama law requires that the contractor provide the County proof of enrollment in E-Verify (see www.uscis.gov/everify).
No bid shall be withdrawn for a period of thirty (30) days subsequent to the opening of bids without the consent of the ECCICD. A tabulation of the bids will be available for public viewing within two (2) weeks of the award of the bid by request.
Call News October 18, 25, and November 1, 2023

LEGAL NOTICE – INVITATION TO BID
A MANDATORY pre-bid conference is REQUIRED
for ALL Prospective bidders. Pre-bid conference
will be held Thursday, November 2, 2023 at approximately 9:00 A.M.
Dodge Elementary School
2615 Longleaf Drive
Mobile, AL 36693
BID ON: DODGE ELEMENTARY SCHOOL
PLAYGROUND EQUIPMENT AND INSTALLATION
BSC #23-23
BID OPENING DATE: Thursday, November 16, 2023 @ 2:00 P.M.
Call News October 18, 25 and November 1, 2023

Notice to Contractors Federal Aid
Project No. NH-HSIP-0013(621)
MOBILE COUNTY, ALABAMA
Sealed bids will be received by the Director of Transportation at the office of the Alabama Department of Transportation, Montgomery, Alabama until 10:00 AM on November 03, 2023 and at that time publicly opened for constructing the Planing, Resurfacing, Guardrail Upgrades (Steel Blockout Replacement), Traffic Signal Upgrades (Signal Backplates), and Traffic Stripe on SR-13 (US-43) from the junction of SR-158 in Saraland to the intersection of Plateau Avenue in Satsuma. Length 4.377 mi.
The total amount of uncompleted work under contract to a contractor must not exceed the amount of his or her qualification certificate.
The Entire Project Shall Be Completed By December 31, 2024. A 2.00% DBE Contract Obligation Is Required.
A Bidding Proposal may be purchased for $5.00. Plans may be purchased for $15.00 per set. Plans and Proposals are available at the Alabama Department of Transportation, 1409 Coliseum Boulevard, Room E-108, Montgomery, AL 36110. Checks should be made payable to the Alabama Department of Transportation. Plans and Proposals will be mailed only upon receipt of remittance. No refunds will be made.
Minimum wage rates for this project have been pre-determined by the Secretary of Labor and are set forth in the advertised specifications. This project is subject to the contract work hours and Safety Standards Act and its implementing regulations.
Cashier’s check or bid bond for 5% of bid (maximum – $50,000.00) made payable to the Alabama Department of Transportation must accompany each bid as evidence of good faith.
The bracket range is shown only to provide general financial information to contractors and bonding companies concerning the project’s complexity and size. This Bracket should not be used in preparing a bid, nor will this bracket have any bearing on the decision to award this contract.
The Bracket Estimate On This Project Is From $3,475,925 To $4,248,353 .
The proposed work shall be performed in conformity with the rules and regulations for carrying out the Federal Highway Act.
Plans and Specifications are on file in Room E-108 of the Alabama Department of Transportation at Montgomery, Alabama 36110.
In accordance with the rules and regulations of The Alabama Department of Transportation, proposals will be issued only to prequalified contractors or their authorized representatives, upon requests that are received before 10 AM., on the day previous to the day of opening of bids.
The bidder’s proposal must be submitted on the complete original proposal furnished him or her by the Alabama Department of Transportation.
The Alabama Department of Transportation, in accordance with Title VI of the Civil Rights Act of 1964, 78 Stat. 252, 42
U.S.C. 2000D TO 2000D-4 and Title 49 code of Federal Regulations, Department of Transportation, Subtitle A, Office of The Secretary, Part 21, nondiscrimination in federally-assisted programs of the Department of Transportation issued pursuant to such act, hereby notifies all bidders that it will affirmatively insure that in any contract entered into pursuant to this advertisement, minority business enterprises will be afforded full opportunity to submit bids in response to this invitation and will not be discriminated against on the grounds of race, color, religion, sex, or national origin in consideration for an award.
The right to reject any or all bids is reserved.
JOHN R. COOPER
Transportation Director
Call News October 18, 25 & November 1, 2023

Notice to Contractors
State Project No.
ATRP2-49-2022-346
MOBILE COUNTY, ALABAMA
Sealed bids will be received by the Director of Transportation at the office of the Alabama Department of Transportation, Montgomery, Alabama until 10:00 AM on November 03, 2023 and at that time publicly opened for constructing the Intersection Improvements (Traffic Signal Upgrades) on SR-16 (US-90), SR-42 (US-98), and on SR-17 (US-45) at various locations in the Southwest Region (Mobile Area) as indicated in the plans.
The total amount of uncompleted work under contract to a contractor must not exceed the amount of his or her qualification certificate.
The Entire Project Shall Be Completed In One Hundred Eighty (180) Working Days.
A Bidding Proposal may be purchased for $5.00. Plans may be purchased for $21.00 per set. Plans and Proposals are available at the Alabama Department of Transportation, 1409 Coliseum Boulevard, Room E-108, Montgomery, AL 36110. Checks should be made payable to the Alabama Department of Transportation. Plans and Proposals will be mailed only upon receipt of remittance. No refunds will be made.
Cashier’s check or bid bond for 5% of bid (maximum – $50,000.00) made payable to the Alabama Department of Transportation must accompany each bid as evidence of good faith.
The bracket range is shown only to provide general financial information to contractors and bonding companies concerning the project’s complexity and size. This Bracket should not be used in preparing a bid, nor will this bracket have any bearing on the decision to award this contract.
The Bracket Estimate On This Project Is From $1,731,362 To $2,116,109 .
Plans and Specifications are on file in Room E-108 of the Alabama Department of Transportation at Montgomery, Alabama 36110.
In accordance with the rules and regulations of The Alabama Department of Transportation, proposals will be issued only to prequalified contractors or their authorized representatives, upon requests that are received before 10 AM., on the day previous to the day of opening of bids.
The bidder’s proposal must be submitted on the complete original proposal furnished him or her by the Alabama Department of Transportation.
Section 34-8-8. Code of Alabama 1975 as amended states in part as follows: ‘… it will be necessary for him or her to show evidence of license before his or her bid is considered,’ Further, Section 34-8-8, Code of Alabama 1975 as amended also states in part as follows: ‘All Owners, Architects, and engineers receiving bids pursuant to this chapter shall require the person, firm, or corporation to include his or her current license number on the bid.’
The right to reject any or all bids is reserved.
JOHN R. COOPER
Transportation Director
Call News October 18, 25 & November 1, 2023

ADVERTISEMENT FOR BIDS
Sealed proposals will be received by Board of School Commissioners of Mobile County at the office of Facilities Department, Bldg. F, 1 Magnum Pass, Mobile, AL 36618 until 1:00pm CST, Tuesday, November 7, 2023 for the Alma Bryant High School New Tennis Courts for the Mobile County Public School System, at which time and place they will be publicly opened and read.
A mandatory pre-bid conference will be held Tuesday, October 31, 2023 at 2:00 pm CST at MCPSS Alma Bryant High School job site.
A cashier’s check or bid bond payable to Board of School Commissioners of Mobile County in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder’s proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract.
Drawings and specifications may be examined at the office of Clark Geer Latham & Associates, Inc., 3901 Springhill Ave. Mobile, AL 36608, (251)344-7073 and F.W. Dodge Plan Rooms.
Bid Documents may be obtained from the Architect upon deposit of $75.00 per hard copy set, which will be refunded in full on the first (2) sets issued to each general contract bidder submitting a bonafide bid, upon return of documents in good condition within ten days of bid opening. There shall be no charge for electronic plans.
Bids must be submitted on proposal forms furnished by the Board of School Commissioners of Mobile County or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner’s judgement, the best interests of the Owner will thereby be promoted.
Board of School Commissioners of Mobile County- Louis Anderson, Mobile County Public School System, Facilities- Clark Geer Latham & Associates, Inc.
Call News October 18, 25 and November 1, 2023

Divorce
IN THE CIRCUIT COURT OF
MOBILE COUNTY, ALABAMA
DOMESTIC RELATIONS DIVISION
NOTICE OF DIVORCE ACTION
CASE NO. DR 2023-901163.00 WHH
DOROTHY L. OKLEY MIMS, Plaintiff
vs.
RUSTY MIMS, Defendant
RUSTY MIMS, (Defendant), whose whereabouts is unknown, must answer the plaintiff’s Petition for Divorce and other relief by December 26, 2023 or, thereafter, a Judgment by Default may be rendered against him/her in the above styled case. The Defendant’s written answer must be filed with the Court and a copy mailed to the Plaintiff’s attorney of record at the address provided below.
Done this 13th day of October, 2023.
Sharla Knox, Circuit Clerk
Attorney for plaintiff:
Jon A. Green
711 Dauphin Street
Mobile, AL 36602
Jonallengreenlaw@gmail.com
Call News November 1, 8, 15, 22, 2023

IN THE CIRCUIT COURT OF
MOBILE COUNTY, ALABAMA
DOMESTIC RELATIONS DIVISION
NOTICE OF DIVORCE ACTION
CASE NO. DR 2023-901139.00 WHH
ALICE G. CHAPMAN, Plaintiff
vs.
JOSEPH L. WAITE, Defendant
JOSEPH L. WAITE, (Defendant), whose whereabouts is unknown, must answer the plaintiff’s Petition for Divorce and other relief by December 18, 2023 or, thereafter, a Judgment by Default may be rendered against him/her in the above styled case. The Defendant’s written answer must be filed with the Court and a copy mailed to the Plaintiff’s attorney of record at the address provided below.
Done this 6th day of October, 2023.
Sharla Knox, Circuit Clerk
Attorney for plaintiff:
William J. Casey
3208 Cottage Hill Road
Mobile, AL 36606
251-478-5713
Wcasey438@cs.com
Call News October 25 and November 1, 8, 15, 2023

IN THE CIRCUIT COURT OF
MOBILE COUNTY, ALABAMA
DOMESTIC RELATIONS DIVISION
NOTICE OF DIVORCE ACTION
CASE NO. DR 2023-90113.00 WHH
LINDSEY MICHELLE SEITZ, Plaintiff
vs.
JOSEPH BERNARD SEITZ, Defendant
JOSEPH BERNARD SEITZ, (Defendant), whose whereabouts is unknown, must answer the plaintiff’s Petition for Divorce and other relief by December 11, 2023 or, thereafter, a Judgment by Default may be rendered against him/her in the above styled case. The Defendant’s written answer must be filed with the Court and a copy mailed to the Plaintiff’s attorney of record at the address provided below.
Done this 28th day of September, 2023.
Sharla Knox, Circuit Clerk
Attorney for plaintiff:
Thomas F. Monk
1111 Easts I-65 Service Rd. S Suite 112
Mobile, AL 36606
monk@mobileattorney.net
Call News October 18, 25 and November 1, 8, 2023

Complaint
LEGAL NOTICE
NOTICE TO DEFENDANT OF COMPLAINT ISSUED OUT OF THE CIRCUIT COURT OF MOBILE COUNTY, ALABAMA, IN THE CASE ENTITLED NO. CV-2022-901602, SALLY BOSARGE and CHELSEA BOSARGE, Plaintiffs -VERSUS- HAYLEY MORGAN ROBINSON, et al., Defendants.
NOTICE is hereby given that in the above entitled cause on the 12th day of September, 2022, the above named Plaintiffs filed in said Circuit Court of Mobile County, Alabama, a cause of action against the above named Defendant for damages for personal injuries sustained in an automobile accident.
THAT on the 23rd day of October 2023, Mr. William T. Eiland Attorney for Plaintiffs, filed in the above entitled cause an affidavit that the said Hayley Morgan Robinson is absent from the State of Alabama or is concealing herself so that process cannot be served upon her.
NOW, THEREFORE, the said Hayley Morgan Robinson is hereby commanded to answer or plead by December 22, 2023, to the Complaint heretofore filed in the above entitled cause.
Witness my hand and seal on this the 27th day of October, 2023.
ATTEST:
/s Sharla Knox
Clerk, Circuit Court, Mobile County, AL
Attorney for Plaintiffs:
William T. Eiland
Eiland and Ritchie, LLC
P O Box 190609
Mobile, AL 36609
Phone: 251-666-1212
E-mail: mhardage@erlawfirm.com
Call News Nov. 1, Nov. 8, Nov. 15 & Nov. 22, 2023

LEGAL NOTICE
NOTICE TO DEFENDANT, DANNY H. RODGERS, OF COMPLAINT ISSUED OUT OF THE CIRCUIT COURT OF MOBILE COUNTY, AL—CASE NO.
CV-2023-902049.
NOTICE is hereby given in the above-entitled cause that on the 29th day of September, 2023, KIMBERLY R. MAYO and SUE R. COLBERT, Plaintiffs, filed in said Circuit Court, a cause of action against the above named Defendant seeking a sale for division of Lot 11, Hillcrest Crossing, 1st Addition, Phase Two (Map Bk 73 p. 22) in Mobile County, AL commonly known as 1103 Hillcrest Crossing, Mobile, AL.
NOW THEREFORE, Defendant is hereby commanded to answer or plead by December 22, 2023, to the Complaint filed in the above entitled case.
WITNESS my hand on this the 26th day of October, 2023.
ATTEST
/s Sharla Knox
CLERK OF THE CIRCUIT COURT OF MOBILE COUNTY, AL
CLIFFORD C. (KIP) SHARPE
Attorney for Plaintiff
307 Morgan Ave.
Mobile, AL 36606
(251) 343-6700 (251) 423-1157
E-mail: ksharpe@kiplaw.net
Call News NOV. 1, NOV. 8, NOV. 15 & NOV. 22, 2023

IN THE CIRCUIT COURT OF
MOBILE COUNTY, ALABAMA
Heartland Capital Investments, LLC, Plaintiff
v.
Emmanuel David Strickland, Defendant.
Notice to Defendant:
You must answer Plaintiff’s Complaint by December, 2023, or, thereafter, a judgment by default may be rendered against you in Case No. CV-2023-901409.00 Circuit Court of Mobile County, Alabama. The original of said answer is to be filed with the Clerk of this Court and a copy must be mailed or hand delivered to the attorney for Plaintiff.
Given under my hand this 26th day of October 2023.
/s Sharla Knox
Clerk of Circuit Court
Mobile County, Alabama
Attorney for Plaintiff:
Morgan P. Hoggle
P.O. Box 2147
Dothan, Al 36302
Phone: 334-671-0555, ext. 226
E-mail: becky@pm-firm.com
Call News Nov. 1, Nov. 8, Nov. 15 & Nov. 22, 2023

NOTICE OF PUBLICATION
In the Circuit Court of
Mobile County, Alabama
Case No. 02-CV-2023-901004.00
DAVID JONES, Plaintiff
YOSHA POPULUS, Defendant.
NOTICE OF PUBLICATION
YOSHA POPULUS Notice is hereby given that a Complaint against the Defendant YOSHA POPULUS, was filed in the above-styled action on May 22, 2023 in the Circuit Court of Mobile County, Alabama, and that by reason of an Order for Service by Publication hereinbefore entered by the Court, you are hereby commanded and required to file with the Clerk of the Court, and to serve upon the Plaintiff’s Attorney, Alan Colvin with the law firm of Long & Long, PC, 3600 Springhill Memorial Drive N, Mobile, Alabama 36608, an answer to the Complaint within thirty (30) days after the last publication of this notice, or a default judgment will be entered against you.
GIVEN under my hand this 26th day of October, 2023
/s Sharla Knox
Circuit Court Clerk of Mobile County, Alabama:
Plaintiff’s Attorney:
Alan Colvin
Long & Long, PC
3600 Springhill Memorial Drive N
Mobile, Alabama 36608
Phone:(251) 445-6000.
E-mail: Shorei@longandlong.com
Call News Nov. 1, Nov. 8, Nov. 15 & Nov. 22, 2023

IN THE CIRCUIT COURT OF
MOBILE COUNTY
STATE OF ALABAMA
Case No. CV-2022-901328.00
RUBIN LUBLIN, LLC, Plaintiff,
v.
BOBBY GENE VICKERY, JR., JENNY L. VICKERY AKA JENNY L. MASON, AND ALL UNKNOWN HEIRS OF MARSHALL B. VICKERY, Defendants.
To: ALL UNKNOWN HEIRS OF MARSHALL B. VICKERY
NOTICE OF PUBLICATION
By Order for Service by Publication, dated the 19th day of October, 2023, you are hereby notified that on August 1, 2022, RUBIN LUBLIN, LLC (“Plaintiff’) filed its Complaint for Interpleader of Excess Funds Collected from Foreclosure, amended on August 31, 2023 (hereinafter, the “Complaint”), pertaining to real property at 9950 Whip Poor Will Dr., Semmes, AL 36575 (the “Property”). Plaintiff seeks to interplead the excess funds from the foreclosure sale of the Property. To prevent a default judgment being entered against you, you must file an Answer in writing with the Clerk of the Circuit Court and serve a copy upon Plaintiff’s attorneys, Amanda M. Beckett and Hannah Davenport of Rubin Lublin, LLC at 3145 Avalon Ridge Place, Suite 100, Peachtree Corners, Georgia 30071, within thirty (30) days from the date of the last publication of this notice, which shall be published at least once per week for four consecutive weeks in a newspaper of general circulation in Mobile County, Alabama
Given under my hand this 20th day of October, 2023.
/s Sharla Knox
CLERK OF THE CIRCUIT COURT OF MOBILE COUNTY, ALABAMA
Plaintiff’s Attorneys:
Douglas Baymiller;
Hannah Davenport
Rubin Lublin, LLC
11 N Water St, Suite 10290
Mobile, AL 36602
Phone: (770) 246-3345
E-mail: dpiper@rlselaw.com
Call News Oct. 25, Nov. 1, Nov. 8 & Nov. 15, 2023

IN THE CIRCUIT COURT OF
MOBILE COUNTY, ALABAMA
HISTORIC MOBILE, LLC, Plaintiff
v.
PARCEL OF REAL PROPERTY SITUATED IN MOBILE COUNTY, ALABAMA, HAVING PARCEL IDENTIFICATION OF Parcel No. R022906400003148.01, and legally described as: The East half of that property described as follows: Beginning 100.6 feet Southwardly of the Southwest corner of Congress and Dearborn Streets running Westwardly 110 feet, thence Southwardly 48.7 feet, thence nearly 50.3 feet to beginning of #Sec 40 T4S R1W #MP29 06 40 0 004 in the Office of the Judge of the Probate of Mobile County, Alabama,
AND
ETTA REE PENDLETON, NINA JACKSON ROBINSON, and LINDA JACKSON, Defendants.
CIVIL ACTION NO.:
CV-2023-901717
NOTICE OF PUBLICATION
The Defendants or any party having any right, lien, encumbrance of interest in the described land in the above-styled action, must answer Plaintiff’s Bill to Quiet Title by the 8th day of December, 2023 or, thereafter a judgment by default may be entered against them.
GIVEN under my hand this 12th day of October, 2023.
Sharla Knox, CIRCUIT CLERK, MOBILE COUNTY
Plaintiff’s Attorney:
Keri Coumanis
Helmsing, Leach, Herlong, Newman & Rouse, PC
P O Box 2767
Mobile, AL 36652
Phone: 251-432-5521
E-mail: ktm@helmsinglaw.com
Call News October 18, 25, November 1, 8, 2023

LIS PENDENS
IN THE CIRCUIT COURT OF
MOBILE COUNTY, ALABAMA
Case Action No.: CV-2023-901329
BCB ENTERPRISES, LLC, Plaintiff
vs.
HERMAN L. SMITH AND CELESTE SMITH, Defendants, and against the Lands Described: Lot 35 addition to Brierwood, Map Book 10 Page 122 in the records of the Office of the Judge of Probate, Mobile County, Alabama.
Key No. 1184550; commonly known as: 475 Kirkwell Drive Mobile, Alabama, 36619
NOTICE OF LIS PENDENS
Notice is hereby given that, BCB Enterprises, LLC has commenced a civil action against the above described Real Property in which Plaintiff claims a right title, interest, or claim in and to the following described real property.
Lot 35 addition to Brierwood, Map Book 10 Page 122 in the records of the Office of the Office of the Judge of Probate, Mobile County, Alabama.
Mobile County Revenue Commission Key No.: 1184550
Address: 475 Kirkwell Drive, Mobile, Alabama, 36619
Any party having any interest, lien, right or encumbrance on said lands, must file an Answer or plead to the complaint on or before 30 days after the last date of publication.
Given under my hand this 20th day of October, 2023.
/s Sharla Knox
Circuit Clerk, Mobile County, Alabama
/s/ Noel J. Nelson
Attorney for Plaintiff
Post Office Box 2573
Mobile, Alabama 36652
(251) 433-7272
E-mail: njnelson@bellsouth.net
Call News Oct. 25, Nov. 1, Nov. 8 and Nov. 15, 2023

IN THE CIRCUIT COURT OF
MOBILE COUNTY, ALABAMA
Case Action No.:CV-2023-901330
BCB ENTERPRISES, LLC, Plaintiff
Vs
Lands Described: Lot 27 of a Subdivision of Lots 4 and 5 Rosedale Subdivison as per plat thereof recorded in Deed Book 156 N.S. Page 120-121 as shown in Map Book 4 Page 73 in the Office of the Judge of Probate, Mobile County, Alabama.
commonly known as: 2126 Johns Lane Mobile, Alabama, 36605
NOTICE OF LIS PENDENS
Notice is hereby given that, BCB Enterprises, LLC has commenced a civil action against the above described Real Property in which Plaintiff claims a right title, interest, or claim in and to the following described real property:
Lot 27 A Subdivision of Lots 4 & 5 Rosedale according to plat thereof recorded in Deed Book 156 New Series, Page 120-121, Map Book 4, Page 73, in the Office of the Judge of Probate, Mobile County, Alabama.
Mobile County Revenue Commission Key No. 1007984
Any party having any interest, lien, right or encumbrance on said lands, must file an answer or plead to the complaint on or before 30 days after the last date of publication.
Given under my hand the 20th day of October, 2023.
/s Sharla Knox
Circuit Clerk, Mobile County, Alabama
/s/ Noel J. Nelson
Attorney for Plaintiff
Post Office Box 257
Mobile, Alabama 36652
(251) 433-7272
E-mail: njnelson@bellsouth.net
Call News Oct. 25, Nov. 1, Nov. 8 and Nov. 15, 2023

Breach of Contract/Ejectment
IN THE CIRCUIT COURT OF
MOBILE COUNTY, ALABAMA
CASE NO. CV-2023-901795
FEDERAL HOME LOAN MORTGAGE CORPORATION, Plaintiff
vs.
JASON GAINEY And any Unknown Occupants in Possession, Defendants
PUBLICATION NOTICE
To: JASON GAINEY
For: Breach of Contract/Ejectment
You are hereby notified that FEDERAL HOME LOAN MORTGAGE CORPORATION, filed its Complaint on August 29, 2023, in the MOBILE County Circuit Court against the Defendant, JASON GAINEY. Affidavit having been filed herein that service of process cannot be made because either the residence of defendants are unknown and cannot with reasonable diligence be ascertained, or, the identity of defendant is unknown, or, the resident defendant has been absent for more than thirty days since the filing of this suit, or that defendant avoids service and avers facts showing such avoidance.
JASON GAINEY is commanded to answer or plead to the Complaint within 30 days of the last date of publication or suffer the entry of a Default Judgment against him.
GIVEN under my hand this 26th day of October, 2023
/s Sharla Knox
Clerk of the Mobile County Circuit Court Plaintiff’s Attorney:
Kent D. McPhail
McPhail Sanchez, LLC
Eslava Bldg
126 Government Street
Mobile, AL 36602
Phone: 251-438-2333, Ext 131
E-mail: JulieG@mslawyers.law
Call News NOV. 1, NOV. 8, NOV. 15 & NOV. 22, 2023

CIVIL ACTION
ORDER OF NOTICE BY PUBLICATION
DOCKET NUMBER: 2377CV00359
Trial Court of Massachusetts,
The Superior Court
CASE NAME: Bank of New York Mellon Trust Company, N.A. Trustee for Mortgage Assets Management Series I Trust
vs.
Aimee Sanford et al
RE: Kane, Steven James
WHEREAS a civil action has been begun against you in our Superior Court by Bank of New York Mellon Trust Company, N.A. Trustee for Mortgage Assets Management Series I Trust wherein it is seeking to; Bank of New York Mellon Trust Company, N.A., as Trustee for Mortgage Assets Management Series I Trust (hereinafter “BONY Mellon”), the foreclosing mortgagee is currently holding surplus funds that it wishes to pay into the Court so that the Court can determine who is entitled to the surplus funds. BONY Mellon further request that it be discharged from any further obligation involving this matter. We COMMAND YOU if you intend to make any defense, that on 11/16/2023 or within such further time as the law allows you do cause your written pleading to be filed in the office of the Clerk of Court named above, in said Commonwealth, and further that you defend against said suit according to law if you intend any defense, and that you do and receive what the Court shall order and adjudge therein. Hereof fail not, at your peril, or as otherwise said suit may be adjudged and orders entered in your absence. It appearing to this Court that no personal service of the Complaint has been made on the defendant a deputy sheriff having made a return on the summons that after diligent search he can find no one upon whom he can lawfully make service, a copy of which is hereto attached and made part of this notice, it is ORDERED that notice of this suit be given to them by publishing, once a week for three successive weeks, the last publication to be at least 20-days before said return day in the:
Newspaper: Citronelle Call News &Birmingham News
City/ Town: City of Lawrence
DATE ISSUED: 10/05/2023
Thomas H. Driscoll, Jr., Clerk of Courts, Essex County
CLERK OF COURTS/ ASST. CLERK
COURT NAME & ADDRESS: Essex County Superior Court – Lawrence, 43 Appleton Way Lawrence, MA 01841
Call News October 18, 25 and November 1, 2023

ORDER OF NOTICE BY PUBLICATION
DOCKET NUMBER: 2377CV00359
Trial Court of Massachusetts,
The Superior Court
CASE NAME: Bank of New York Mellon Trust Company, N.A. Trustee for Mortgage Assets Management Series I Trust
vs.
Aimee Sanford et al
RE: Sanford, Joseph
WHEREAS a civil action has been begun against you in our Superior Court by Bank of New York Mellon Trust Company, N.A. Trustee for Mortgage Assets Management Series I Trust wherein it is seeking to; Bank of New York Mellon Trust Company, N.A., as Trustee for Mortgage Assets Management Series I Trust (hereinafter “BONY Mellon”), the foreclosing mortgagee is currently holding surplus funds that it wishes to pay into the Court so that the Court can determine who is entitled to the surplus funds. BONY Mellon further request that it be discharged from any further obligation involving this matter. We COMMAND YOU if you intend to make any defense, that on 11/16/2023 or within such further time as the law allows you do cause your written pleading to be filed in the office of the Clerk of Court named above, in said Commonwealth, and further that you defend against said suit according to law if you intend any defense, and that you do and receive what the Court shall order and adjudge therein. Hereof fail not, at your peril, or as otherwise said suit may be adjudged and orders entered in your absence. It appearing to this Court that no personal service of the Complaint has been made on the defendant a deputy sheriff having made a return on the summons that after diligent search he can find no one upon whom he can lawfully make service, a copy of which is hereto attached and made part of this notice, it is ORDERED that notice of this suit be given to them by publishing, once a week for three successive weeks, the last publication to be at least 20-days before said return day in the:
Newspaper: Citronelle Call News &Birmingham News
City/ Town: City of Lawrence
DATE ISSUED: 10/05/2023
Thomas H. Driscoll, Jr., Clerk of Courts, Essex County
CLERK OF COURTS/ ASST. CLERK
COURT NAME & ADDRESS: Essex County Superior Court – Lawrence, 43 Appleton Way Lawrence, MA 01841
Call News October 18, 25 and November 1, 2023

Complaint to Quiet Title
LEGAL NOTICE
NOTICE TO DEFENDANTS OF COMPLAINT ISSUED OUT OF THE CIRCUIT COURT OF MOBILE COUNTY, ALABAMA—CASE NO. CV-2023-901288.00, JAMES KYLE WEAVER AND MARY ANN WEAVER, Plaintiffs, v. LANDS DESCRIBED AS FOLLOWS: COMMENCE AT THE NORTHWEST CORNER OF SECTION 19, TOWNSHIP 1 NORTH, RANGE 2 WEST, MOBILE COUNTY, ALABAMA; THENCE NORTH 89°27’13” EAST 1320.00’ TO A POINT, THENCE SOUTH 264.00’ TO THE POINT OF BEGINNING OF PROPERTY HEREIN DESCRIBED, THENCE EAST 40.25’ TO A POINT, THENCE SOUTH 00°06’04” EAST 254.04’ TO A POINT, THENCE SOUTH 89°46’00” WEST 260.38’ TO A POINT, THENCE NORTH 00°32’47” WEST 34.10’ TO A POINT, THENCE EAST 220.00’ TO A POINT, THENCE NORTH 221.00’ BACK TO THE POINT OF BEGINNING; AND THOSE FICTICIOUS PARTIES A-Z, WHOSE IDENTITIES ARE CURRENTLY UNKNOWN AND WHO WILL BE ADDED TO THIS COMPLAINT BY AMENDMENT WHEN ASCERTAINED, INCLUDING ANY PERSONS CLAIMING ANY PRESENT INTERESTTHEREIN AND INCLUDING ANY PERSONS CLAIMING ANY FUTURE, CONTINGENT, REVERSIONARY, REMAINDER, OR OTHER INTEREST THEREIN, WHO MAY CLAIM ANY INTEREST IN THE ABOVE DESCRIBED PROPERTY, Defendants.
NOTICE is hereby given in the above-entitled cause on the 23rd day of June, 2023, the above-named Plaintiff filed in said Circuit Court, a cause of action against the above named Defendants to quiet the title to the above described real property in favor of the Plaintiff, extinguishing any rights of the Defendants in and to the real property.
NOW THEREFORE, any person claiming an interest in and to the above-described real property is hereby commanded to answer or plead by December 14, 2023, to the complaint filed in the above-entitled case.
WITNESS my hand on this the 20th day of October, 2023.
ATTEST
/s Sharla Knox
CLERK OF THE CIRCUIT COURT OF MOBILE COUNTY, ALABAMA
/s/ Jason D. Smith
ANDERS, BOYETT, BRADY & SMITH, P.C.
3800 Airport Boulevard
Suite 203
Mobile, Alabama 36608
(251) 344-0880
CALL NEWS OCT. 25, NOV. 1, NOV. 8 & NOV. 15, 2023

SERVICE BY PUBLICATION
LEGAL NOTICE
IN THE CIRCUIT COURT OF
MOBILE COUNTY, ALABAMA
CASE NO. CV-2022-900765
BEFORE THE AMERICAN ARBITRATION ASSOCIATION CASE NO 01-22-0002-7098
Roy Benton and Aurelia Hooks Benton, Plaintiffs/Claimants v. Terminix International Co, LP,
Trevor Butler
Roy Benton and Aurelia Hooks Benton, Plaintiffs/Claimants v. Terminix International Co, LP,
Michael Johnson
Claim Amounts:
In excess of the jurisdictional minimum of the Court, including compensatory, mental anguish, and punitive damages for asserted claims of fraud, fraudulent suppression and concealment, breach of warranty, negligence, wantonness/willfulness, breach of contract,
Negligent training and supervision.
Affidavit having been filed herein that service of process cannot be made because either the residence of the Defendants are unknown and cannot with reasonable diligence be ascertained, or, the identity of the Defendant is unknown, or the resident Defendant has been absent for more than thirty (30) days since the filing of this suit, or that Defendant avoids service and averring fact showing such avoidance.
On September 1, 2023 the Circuit Court of Mobile County, Alabama entered an Order for serving Defendants, Trevor Butler and Michael Johnson by publication as service both for the pending case in Mobile County Circuit Court and the Arbitration pending before the American Arbitration Association. The Court’s Order for service by Publication was amended on September 29, 2023.
Now, therefore, said Defendants, Trevor Butler and Michael Johnson are hereby commanded to within thirty (30) days of the last date of publication hereof plead or answer to said Complaint or Demand in Arbitration, or suffer the entry of a Default Judgment against them.
Given under my hand this 12th day of October, 2023.
/s Sharla Knox
Circuit Clerk of Mobile County, Alabama
Plaintiff’s Attorney
L. Daniel Mims
The Mims Firm P C
952 Government St
Mobile, AL 36604
Phone: 252-433-0161
E-mail: Corrine Busby corrinebusby@mimsfirm.com
Call News Oct. 18, Oct. 25, Nov. 1 & Nov. 8, 2023

FORECLOSURE NOTICE
Default having been made in the payment of the indebtedness described in and secured by that certain Mortgage executed by DIANA THOMAS SYLVESTER dated July 15, 2019 and recorded as Instrument No. 2019043884, Probate Records of Mobile County, Alabama to THAMES, JACKSON, HARRIS CO., INC.; said Mortgage was thereafter transferred and assigned to James D. Tallent Family Trust by instrument dated August 8, 2019 and recorded in as Instrument No. 2019046337 of the aforesaid probate court records; and which Mortgage was thereafter transferred and assigned unto LINDA TALLENT BROWN by instrument dated December 3, 2022 and recorded as Instrument No. 2022075845 of the aforesaid Probate Court Records; and the undersigned holder of said Mortgage having declared the entire indebtedness due and payable notice is hereby given that the undersigned, under and by virtue of the powers contained in said Mortgage, will sell at public outcry for cash to the highest bidder during the legal hours of sale on the 21st day of November, 2023 at the front or main door of the Government Street entrance of Government Plaza, the Courthouse of Mobile County Alabama, , the following described real property lying and being situated in the County of Mobile, State of Alabama, to-wit:
Lot 1, Dogwood Ridge, according to plat thereof recorded in Map Book 44, Page 106 of the records in the Office of the Judge of Probate of Mobile County, Alabama.
Said sale is made for the purpose of paying the indebtedness secured by said mortgage and all charges as provided therein and the expense incident thereto, including a reasonable attorney’s fee.
Said property will be sold on an “as is, where is” basis subject to any easements, encumbrances, and exceptions contained in said Mortgage and those contained in the records of the Office of the Judge of Probate where the above-described property is situated. Said property will be sold without warranty or recourse, expressed or implied as to title, use and/or enjoyment, and will be sold subject to the right of redemption of all parties entitled thereto.
ALABAMA LAW GIVES SOME PERSONS WHO HAVE AN INTEREST IN PROPERTY THE RIGHT TO REDEEM THE PROPERTY UNDER CERTAIN CIRCUMSTANCES. PROGRAMS MAY ALSO EXIST THAT HELP PERSONS AVOID OR DELAY THE FORECLOSURE PROCESS. AN ATTORNEY SHOULD BE CONSULTED TO HELP YOU UNDERSTAND THESE RIGHTS AND PROGRAMS AS A PART OF THE FORECLOSURE PROCESS.
LINDA TALLENT BROWN
Holders of said Mortgage
JIM H. FERNANDEZ
FERNANDEZ, CRANE & COMBS, L.L.C.
Attorneys for Holders of said Mortgage
Post Office Box 162
Mobile, Alabama 36601 / (251) 433-0738
Call News November 1, November 8 and November 15, 2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed on November 29, 2007 by Gertrude Jackson, originally in favor of Mortgage Electronic Registration Systems, Inc., as nominee for First Choice Funding Inc., and recorded in LR Book 6336 at Page 493 on February 21, 2008, in the Office of the Judge of Probate of Mobile County, Alabama, and secured indebtedness having been transferred to MidFirst Bank. LOGS Legal Group LLP, as counsel for Mortgagee or Transferee and under and by virtue of power of sale contained in the said mortgage will, on January 4, 2024, sell at public outcry to the highest bidder at the main entrance of the Mobile County, Alabama, Courthouse in the City of Mobile, during the legal hours of sale, the following real estate situated in Mobile County, Alabama, to wit:
Lot 8A, Block 26, Bon Air Estates, according to plat thereof recorded in Deed Book 156, Pages 374-377 of the records in the office of the Judge of Probate for Mobile County, Alabama.
For informational purposes only, the property address is: 559 Williams Street, Mobile, AL 36606.
Any property address provided is not part of the legal description of the property sold herein and in the event of any discrepancy, the legal description referenced herein shall control.
This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. Furthermore, the property to be offered pursuant to this notice of sale is being offered for sale, transfer and conveyance AS IS, WHERE IS. Neither the mortgagee, nor the officers, directors, attorneys, employees, agents or authorized representative of the mortgagee make any representation or warranty relating to the title or any physical, environmental, health or safety conditions existing in, on, at or relating to the property offered for sale. Any and all responsibilities or liabilities arising out of or in any way relating to any such condition, including those suggested by Code of Ala. (1975) § 35-4-271, expressly are disclaimed. This sale is subject to all prior liens and encumbrances and unpaid taxes and assessments including any transfer tax associated with the foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars and no/100 ($5,000.00) in certified or cash funds at the time and place of the sale. The balance of the purchase price must be paid in certified funds by close of business on the next business day thereafter at the Law Office of LOGS Legal Group LLP at the address indicated below. LOGS Legal Group LLP reserves the right to award the bid to the next highest bidder, or to reschedule the sale, should the highest bidder fail to timely tender the total amount due.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
MidFirst Bank, and its successors and assigns
Mortgagee or Transferee
LOGS LEGAL GROUP LLP
10130 Perimeter Parkway, Suite 400
Charlotte, NC 28216
(704) 333-8107/ 23-023278
Attorneys for Mortgagee or Transferee
Call News November 1, 2023 and November 8, 2023 and November 15, 2023

MORTGAGE FORECLOSURE SALE
Default having being made in the payment of the indebtedness secured by that certain mortgage dated August 28, 2017 executed by Richard Bookout and Anita Bookout, Husband and Wife, in favor of Mortgage Electronic Registration Systems, Inc., solely as nominee for American Financial Network, Inc., said Mortgage being recorded September 1, 2017, in Book 7564, Page 1857 and re-recorded in Book 7551, Page 327 , in the Office of the Judge of Probate of Mobile County, Alabama; having later been assigned to NewRez LLC d/b/a Shellpoint Mortgage Servicing by instrument recorded in Inst. No. 2021050549, in the Office of the Judge of Probate of Mobile County, Alabama. Said default continues and notice is hereby given that the undersigned, NewRez LLC d/b/a Shellpoint Mortgage Servicing, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash at the main entrance to the County Courthouse, Mobile County, Alabama on 01/03/2024, during the legal hours of sale, the following described real estate situated in Mobile County, Alabama, to-wit:
Lot 9, Phase two, Glenwood Farms, according to the plat thereof recorded in Map Book 74, Page 107 in the Office of the Judge of Probate Court of Mobile County, Alabama. Together with that certain mobile home 2017 Live Oak mobile home serial # LOHGA21732373AB
For informational purposes only, the property address is: 6115 Glenwood Farms Lane W, Wilmer, AL 36587. Any property address provided is not part of the legal description of the property sold herein and in the event of any discrepancy, the legal description referenced herein shall control.
THIS PROPERTY WILL BE SOLD ON AN “AS-IS, WHERE-IS” BASIS, SUBJECT TO ANY EASEMENTS, ENCUMBRANCES, AND EXCEPTIONS REFLECTED IN THE MORTGAGE AND THOSE CONTAINED IN THE RECORDS OF THE OFFICE OF THE JUDGE OF PROBATE OF THE COUNTY WHERE THE ABOVE-DESCRIBED PROPERTY IS SITUATED. THIS PROPERTY WILL BE SOLD WITHOUT WARRANTY OR RECOURSE, EXPRESS OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
This sale is made for the purpose of paying the indebtedness secured by mortgage as well as the expenses of foreclosure, including a reasonable attorney’s fees and other purposes set out in said mortgage.
NewRez LLC d/b/a Shellpoint Mortgage Servicing
Paul K. Lavelle, Esq.
Attorney for Mortgagee
Spina, & Lavelle, P.C.
One Perimeter Park South-Suite 400N
Birmingham, Alabama 35243
(205) 298-1800
30-FC-23-01274
Call News November 1, 2023, November 8, 2023 and November 15, 2023

NOTICE OF FORECLOSURE SALE
MOBILE COUNTY
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Jackson C. Weldon, an unmarried man, originally in favor of Coats & Co., Inc. on February 18, 1999, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, at Book 4680, Page 219; the undersigned Wilmington Savings Fund Society, FSB, as trustee of Stanwich Mortgage Loan Trust I, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash or certified funds, in front of the main entrance of the Courthouse at Mobile County, Alabama, on December 13, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:
LOT 17, BLOCK Q, RESIBDIVISION OF WESTLAWN AS RECORDED IN MAP BOOK 4 PAGES 516-520 IN THE OFFICE OF JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA
Property street address for informational purposes: 157 Potter Drive, Mobile, AL 36606
THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, SUBJECT TO ANY EASEMENTS, ENCUMBRANCES, AND EXCEPTIONS REFLECTED IN THE MORTGAGE AND THOSE CONTAINED IN THE RECORDS OF THE OFFICE OF THE JUDGE OF PROBATE OF THE COUNTY WHERE THE ABOVE-DESCRIBED PROPERTY IS SITUATED. THIS PROPERTY WILL BE SOLD WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender cash or certified funds made payable to Aldridge Pite, LLP at the time and place of the sale. Aldridge Pite, LLP reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Wilmington Savings Fund Society, FSB, as trustee of Stanwich Mortgage Loan Trust I, Mortgagee/Transferee ALDRIDGE PITE, LLP Six Piedmont Center 3525 Piedmont Road, N.E., Suite 700 Atlanta, GA 30305. Attorney for Mortgagee/Transferee.
THIS OFFICE IS ACTING AS A DEBT COLLECTOR AND IS ATTEMPTING TO COLLECT A DEBT. ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
Call News 11/1/2023, 11/8/2023, 11/15/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by William Dickens, an unmarried man and Bailey Felps, an unmarried woman, originally in favor of Mortgage Electronic Registration Systems, Inc., acting solely as nominee for GMFS, LLC, on December 28, 2017, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book LR7591 Page 1816 and modified in Instrument No. 2022058964; the undersigned MidFirst Bank, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on December 28, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot Number 24, Rayjul Estates, First Unit, as recorded in Map Book 10, Page 288 of the records in the Office of the Judge of Probate Court of Mobile County, Alabama.. Property street address for informational purposes: 6900 Red Lane Circle , Theodore, AL 36582. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. MidFirst Bank, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-07917
Call News 11/01/2023, 11/08/2023, 11/15/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Stanley B Dees, an unmarried man, originally in favor of Mortgage Electronic Registration Systems, Inc., as nominee for Pacific Union Financial, LLC dba Clearvision Funding, on December 4, 2014, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book LR7214 Page 456; the undersigned MidFirst Bank, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on December 21, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot G, Lipscomb Jones Subdivision, Unit 2, according to plat thereof recorded in Map Book 103 Page 9 of the records in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 4025 Lloyd Station Rd , Mobile, AL 36693. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. MidFirst Bank, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-07665
Call News 11/01/2023, 11/08/2023, 11/15/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Patsy M Reinhart aka Patsy Reinhart, an unmarried person and George Henry Smith II, an unmarried person and Rhonda Kay Ganey and Thomas Ganey, a married couple, originally in favor of Compass Bank, on August 1, 2017, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in BK: LR7542 Page 610; the undersigned PNC Bank, National Association, successor by merger to BBVA, USA, successor by merger to Compass Bank, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 30, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: All of that certain parcel of real property situated in the Mobile City, State of Alabama, County of Mobile and more particularly described as follows, Viz Lot 26, McMurray Place, Phase Two, according to the plat thereof recorded in Map Book 122, Page 102 of the records in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 1115 McMurray Pl E , Mobile, AL 36609. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. PNC Bank, National Association, successor by merger to BBVA, USA, successor by merger to Compass Bank, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-07923
Call News 11/01/2023, 11/08/2023, 11/15/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Robert B. Ricker, Jr., a single person and Dana F. Housch, a single person, originally in favor of Coats & Co., Inc., on December 12, 2002, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 5277 Page 0638; the undersigned LoanCare, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on December 7, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 33, and the West 46.00 feet of Lot 32 and the East 17.00 feet of Lot 34, Revised Oakland Heights, according to the plat thereof recorded in Map Book 4, Pages 612-613 of the records in the Office of the Judge of Probate Court, Mobile County, Alabama.. Property street address for informational purposes: 1024 Oakland Dr , Mobile, AL 36609. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. LoanCare, LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-07727
Call News 11/01/2023, 11/08/2023, 11/15/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Donald Jones and Denisha Jones, husband and wife, originally in favor of AmSouth Bank, on February 4, 2005, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 5726 Page 470 and modified in Book 7414 Page 241; the undersigned Lakeview Loan Servicing LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on December 28, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 47, Malibar Heights, 5th Unit, according to the plat thereof recorded in Map Book 12, Page 40 in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 4303 Via Alta Dr , Mobile, AL 36609. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Lakeview Loan Servicing LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-07810
Call News 11/01/2023, 11/08/2023, 11/15/2023

NOTICE OF
MORTGAGE FORECLOSURE SALE
STATE OF ALABAMA
COUNTY OF MOBILE
Default having been made of the terms of the loan documents secured by that certain mortgage executed by Noel J Nelson to RBC Centura Bank dated February 8, 2008; said mortgage being recorded on March 3, 2008, in Book 6341, Page 1659 in the Office of the Judge of Probate of Mobile County, Alabama.
The undersigned, PNC Bank, National Association, successor by merger to RBC Bank (USA), formerly known as RBC Centura Bankunder and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 30th day of November, 2023 the following property, situated in Mobile County, Alabama, to-wit:
BEGINNING AT A POINT ON THE NORTH LINE OF MONTEREY PLACE SEVENTY-FIVE (75) FEET EASTWARDLY FROM THE NORTHEAST CORNER OF MONTEREY PLACE AND MONTEREY STREET AND RUNNING THENCE EASTWARDLY ALONG THE NORTH LINE OF MONTEREY PLACE FIFTY (50) FEET FOR THE FRONT, AND EXTENDING BACK BETWEEN LINES PARALLEL WITH MONTEREY STREET ONE HUNDRED AND FIFTY-TWO (152) FEET TO THE SOUTH LINE OF AN ALLEYWAY, BEING A PART OF MONTEREY PLACE, ACCORDING TO THE MAP RECORDED IN DEED BOOK 142 PAGE 236, PROBATE RECORDS OF MOBILE COUNTY, ALABAMA.
Said property is commonly known as 1606 Monterey Pl, Mobile, AL 36604.
Should a conflict arise between the property address and the legal description the legal description will control.
Said property will be sold subject to any outstanding ad valorem taxes (including taxes which are a lien, but not yet due and payable), the right of redemption of any taxing authority, all outstanding liens for public utilities which constitute liens upon the property, any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, easements, rights-of-way, zoning ordinances, restrictions, special assessments, covenants, the statutory right of redemption pursuant to Alabama law, and any matters of record including, but not limited to, those superior to said Mortgage first set out above. Said property will be sold on an “as-is” basis without any representation, warranty or recourse against the above-named or the undersigned. The successful bidder must present certified funds in the amount of the winning bid at the time and place of sale.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The sale will be conducted subject (1) to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and (2) to final confirmation and audit of the status of the loan with the holder of the Mortgage.
PNC BANK, NATIONAL ASSOCIATION, SUCCESSOR BY MERGER TO RBC BANK (USA), FORMERLY KNOWN AS RBC CENTURA BANK
as holder of said mortgage
McCalla Raymer Leibert Pierce, LLC
Two North Twentieth
2 20th Street North, Suite 1000
Birmingham, AL 35203
(205) 216-4238
FT21@mccalla.com
File No. 23-05270AL
www.foreclosurehotline.net
Call News 11/01/2023,11/08/2023,11/15/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Maish Smaw, unmarried woman, originally in favor of Mortgage Electronic Registration Systems, Inc. as nominee Mortgage Research Center, LLC dba Veterans United Home Loans, on May 9, 2022, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Instrument Number 2022033291; the undersigned PennyMac Loan Services, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 29, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 3, Hamilton Creek Estates, according to plat thereof recorded in Map Book 34, Page 63, of the records in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 2791 Cottage Glenn Dr W , Mobile, AL 36695. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. PennyMac Loan Services, LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-07768
Call News 11/01/2023, 11/08/2023, 11/15/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Dollie Berryhill, a unmarried woman, originally in favor of Mortgage Corporation Systems, Inc., solely as nominee for Mortgageamerica, Inc., Corporation, on April 27, 2007, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 6180 Page 1798 and modified in Book LR7608 Page 1359; the undersigned MidFirst Bank, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on December 21, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lots 11 and 12 in Block “G” of Nealy Place according to the plat of survey thereof, as recorded in Deed Book 141, N.S. Pages 188-189 of the records in the Office of the Judge of Probate Court of Mobile County, Alabama.. Property street address for informational purposes: 1237 Rich Avenue, Prichard, AL 36610. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. MidFirst Bank, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-07666
Call News 11/01/2023, 11/08/2023, 11/15/2023

STATE OF ALABAMA
COUNTY OF MOBILE
VENDOR’S LIEN FORECLOSURE NOTICE
Default having been made in the payment of the indebtedness secured by that certain vendor’s lien retained in deed from VICTORIA N. FORTNER to GOLSON MORTGAGE COMPANY, LLC, dated October 26, 2016, said vendor’s lien being recorded in the Office of the Judge of Probate of Mobile County, Alabama at Instrument No. 2016065517, the undersigned, GOLSON MORTGAGE COMPANY, LLC, under and by virtue of the power of sale contained in said vendor’s lien will sell at public outcry to the highest bidder for cash in front of the Courthouse (main entrance) of the Mobile County Courthouse in Mobile, Alabama, on December 18, 2023, during the legal hours of sale, the following described real estate situated in Mobile County, Alabama, to-wit:
Lot 3 Rainbow Downs, according to the plat thereof recorded in Map Book 67, page 25, in the Office of the Judge of Probate, Mobile County, Alabama.
Together with one (1) 1999 Palm Harbor mobile home—-16×76, Serial No. PH232449.
This sale is made for the purpose of paying the indebtedness secured by said vendor’s lien, as well as the charges as provided therein and expenses of foreclosure, including a reasonable attorney’s fee. The conveyance to the purchaser shall be by statutory warranty deed, subject to all statutory rights of redemption and further subject to any and all easements, encumbrances, exceptions, and mortgages of record in the Office of the Judge of Probate, Mobile County, Alabama.
GOLSON MORTGAGE COMPANY, LLC
Lien Holder
JULIE T. CURRY
Attorney for Lien Holder
TAYLOR & TAYLOR, LLC
Attorneys at Law
18350 Michigan Street
Robertsdale, Alabama 36567
Call News November 1, 8, 15, 2023

NOTICE OF
MORTGAGE FORECLOSURE SALE
STATE OF ALABAMA
COUNTY OF MOBILE
Default having been made of the terms of the loan documents secured by that certain mortgage executed by Steve Styburski A Married Man Timothy S King, Jr A Single Man Sandra L Styburski to JPMorgan Chase Bank, N.A. dated September 17, 2015; said mortgage being recorded on September 23, 2015, in Book LR7306, Page 33 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to NewRez LLC F/K/A New Penn Financial, LLC d/b/a Shellpoint Mortgage Servicing in Instrument 2023044307 in the Office of the Judge of Probate of Mobile County, ALABAMA.
The undersigned, NewRez LLC d/b/a Shellpoint Mortgage Servicingunder and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 30th day of November, 2023 the following property, situated in Mobile County, Alabama, to-wit:
LOT 4, BLOCK C, SKYLAND PARK, FIRST UNIT, A SUBDIVISION, ACCORDING TO A MAP OR PLAT THEREOF WHICH IS ON FILE OF RECORD IN THE OFFICE OF THE JUDGE OF PROBATE OF MOBILE COUNTY, ALABAMA, IN MAP BOOK 5, PAGES 643-646.
Said property is commonly known as 4164 Vega Dr, Mobile, AL 36693.
Should a conflict arise between the property address and the legal description the legal description will control.
Said property will be sold subject to any outstanding ad valorem taxes (including taxes which are a lien, but not yet due and payable), the right of redemption of any taxing authority, all outstanding liens for public utilities which constitute liens upon the property, any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, easements, rights-of-way, zoning ordinances, restrictions, special assessments, covenants, the statutory right of redemption pursuant to Alabama law, and any matters of record including, but not limited to, those superior to said Mortgage first set out above. Said property will be sold on an “as-is” basis without any representation, warranty or recourse against the above-named or the undersigned. The successful bidder must present certified funds in the amount of the winning bid at the time and place of sale.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The sale will be conducted subject (1) to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and (2) to final confirmation and audit of the status of the loan with the holder of the Mortgage.
NEWREZ LLC D/B/A SHELLPOINT MORTGAGE SERVICING
as holder of said mortgage
McCalla Raymer Leibert Pierce, LLC
Two North Twentieth
2 20th Street North, Suite 1000
Birmingham, AL 35203
(205) 216-4238
FT21@mccalla.com
File No. 23-05307AL
www.foreclosurehotline.net
Call News 11/01/2023,11/08/2023,11/15/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by James Cameron Yarbrough and Lauren Leeann Yarbrough, husband and wife, originally in favor of Mortgage Electronic Registration Systems, Inc. solely as nominee for Hamilton Mortgage Corporation, on March 6, 2015, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book LR7239 Page 1555 and modified in Instrument No. 2019005263; the undersigned Lakeview Loan Servicing, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 30, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 16, Shenandoah, Phase III, according to plat thereof recorded in Map Book 77, Page 63, of records in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 3455 Shenandoah Trail , Semmes, AL 36575. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Lakeview Loan Servicing, LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-07463
Call News 11/01/2023, 11/08/2023, 11/15/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by David M. Petway and spouse, Annease L. Petway, originally in favor of Compass Bank, on March 23, 2007, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 6161 Page 1207; the undersigned PNC Bank, National Association, successor by merger to BBVA USA, formerly known as Compass Bank, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on December 7, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot(s) 18, Wynnfield, Unit 1 according to the map or plat thereof recorded in Map Book 73 page 75, in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 3208 Wynnfield Dr E , Mobile, AL 36695. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. PNC Bank, National Association, successor by merger to BBVA USA, formerly known as Compass Bank, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-07399
Call News 11/01/2023, 11/08/2023, 11/15/2023

NOTICE OF FORECLOSURE SALE
MOBILE COUNTY
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Frederick D. Morton, an unmarried man, originally in favor of Wells Fargo Bank N.A. on January 20, 2012, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, at Book 6855, Page 783; the undersigned Nationstar Mortgage LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash or certified funds, in front of the main entrance of the Courthouse at Mobile County, Alabama, on December 1, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:
LOT 2, MORNINGSIDE MANOR, SIXTH UNIT, ACCORDING TO THE PLAT RECORDED IN MAP BOOK 10 PAGE 117 OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE OF MOBILE COUNTY, ALABAMA.
PROPERTY ADDRESS: 1605 EAST GREENBRIAR DRIVE
MOBILE, AL 36605
Property street address for informational purposes: 1605 E Greenbriar Drive Mobile, AL 36605
THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, SUBJECT TO ANY EASEMENTS, ENCUMBRANCES, AND EXCEPTIONS REFLECTED IN THE MORTGAGE AND THOSE CONTAINED IN THE RECORDS OF THE OFFICE OF THE JUDGE OF PROBATE OF THE COUNTY WHERE THE ABOVE-DESCRIBED PROPERTY IS SITUATED. THIS PROPERTY WILL BE SOLD WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender cash or certified funds made payable to Aldridge Pite, LLP at the time and place of the sale. Aldridge Pite, LLP reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Nationstar Mortgage LLC , Mortgagee/Transferee ALDRIDGE PITE, LLP Six Piedmont Center 3525 Piedmont Road, N.E., Suite 700 Atlanta, GA 30305. Attorney for Mortgagee/Transferee.
THIS OFFICE IS ACTING AS A DEBT COLLECTOR AND IS ATTEMPTING TO COLLECT A DEBT. ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
Call News 11/1/2023, 11/8/2023, 11/15/2023

NOTICE OF SALE UNDER POWER
FORECLOSURE NOTICE
WHEREAS, default has occurred in the performance of the covenants, terms and conditions of a mortgage from VIOLA SNEED, A WIDOW to WELLS FARGO HOME MORTGAGE, INC., on the 23rd day of February, 2002, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, on March 21, 2002, in Deed/Mortgage Book 5133, Page 0104, Mobile County, Alabama Records, said Mortgage having subsequently been transferred and assigned to SAFEGUARD HOMES II LLC, by instrument recorded in the aforesaid Probate Office; notice is hereby given that the undersigned SAFEGUARD HOMES II LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash in front of the main entrance of the Courthouse in Mobile, Mobile County, Alabama, on November 29, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:
LOT 4, SUBDIVISION OF THE ESTATE OF FINCH, ACCORDING TO THE PLAT THEREOF RECORDED IN MAP BOOK 22, PAGE 79 OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA.
Said legal description being controlling, however the property is more commonly known as 570 DONALD ST, MOBILE, AL 36617.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
This property will be sold on an “as is, where is” basis, subject to any easements, encumbrances, and exceptions reflected in the mortgage and those contained in the records of the Office of the Judge of Probate in the county where the above-described property is situated. This property will be sold subject to the right of redemption of all parties entitled thereto and subject to any outstanding ad valorem taxes (including taxes which are a lien, whether or not now due and payable). This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation.
SAFEGUARD HOMES II LLC, Mortgagee/Transferee
THE BELOW LAW FIRM MAY BE HELD TO BE ACTING AS A DEBT COLLECTOR, UNDER FEDERAL LAW. IF SO, ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
Rubin Lublin, LLC, Attorney for Mortgagee/Transferee
11 N. Water Street, Suite 10290, Mobile, AL 36602
Telephone Number: (877) 813-0992 Case No. BSI-23-04335-1
rlselaw.com/property-listing
Call News 11/01/2023, 11/08/2023, 11/15/2023

NOTICE OF
MORTGAGE FORECLOSURE SALE
STATE OF ALABAMA
COUNTY OF MOBILE
Default having been made of the terms of the loan documents secured by that certain mortgage executed by Kenneth Tartt And Gloria Tartt to Mortgage Electronic Registration Systems, Inc., as mortgagee, as nominee for Lehman Brothers Bank, FSB, A Federal Savings Bank, its successors and assigns dated October 26, 2006; said mortgage being recorded on November 15, 2006, in Book 6080, Page 535 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to Nationstar Mortgage LLC in Instrument 2023062393 in the Office of the Judge of Probate of Mobile County, ALABAMA.
The undersigned, Nationstar Mortgage LLCunder and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 30th day of November, 2023 the following property, situated in Mobile County, Alabama, to-wit:
Lot 9, Block “A” Neese’s Addition to Crichton, according to the Plat thereof as recorded in Map Book 4, Pages 168-169 in the Office of the Judge of Probate, Mobile County, Alabama.
Said property is commonly known as 2800 Josephine Street, Mobile, AL 36607.
Should a conflict arise between the property address and the legal description the legal description will control.
Said property will be sold subject to any outstanding ad valorem taxes (including taxes which are a lien, but not yet due and payable), the right of redemption of any taxing authority, all outstanding liens for public utilities which constitute liens upon the property, any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, easements, rights-of-way, zoning ordinances, restrictions, special assessments, covenants, the statutory right of redemption pursuant to Alabama law, and any matters of record including, but not limited to, those superior to said Mortgage first set out above. Said property will be sold on an “as-is” basis without any representation, warranty or recourse against the above-named or the undersigned. The successful bidder must present certified funds in the amount of the winning bid at the time and place of sale.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The sale will be conducted subject (1) to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and (2) to final confirmation and audit of the status of the loan with the holder of the Mortgage.
NATIONSTAR MORTGAGE LLC
as holder of said mortgage
McCalla Raymer Leibert Pierce, LLC
Two North Twentieth
2 20th Street North, Suite 1000
Birmingham, AL 35203
(205) 216-4238
FT21@mccalla.com
File No. 23-05283AL
www.foreclosurehotline.net
Call News 11/01/2023,11/08/2023,11/15/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Deborah Keller, single woman, originally in favor of Mortgage Electronic Registration Systems, Inc., as nominee for Keller Mortgage, LLC dba Keller Mortgage, on October 13, 2021, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Instrument Number 2021068417; the undersigned Wells Fargo Bank, N.A., as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on January 3, 2024, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 23, Heritage Woods, Unit Six, according to plat thereof recorded in Map Book 40, Page 110 of the records in the Office of the Judge of Probate of Mobile County, Alabama.. Property street address for informational purposes: 3266 Austin Dr , Mobile, AL 36695. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Wells Fargo Bank, N.A., (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-40529
Call News 11/01/2023, 11/08/2023, 11/15/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Dorothy Ellison and Frank Moore to Mortgage Electronic Registration Systems, Inc., as nominee for Quicken Loans Inc., dated February 8, 2007 said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 6143, Page 589 . Said mortgage was subsequently sold, assigned and transferred to BANK OF AMERICA, N.A.. Under and by virtue of the power of sale contained in said mortgage, the undersigned, BANK OF AMERICA, N.A., will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse in Mobile County, Alabama on November 22, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following describe real estate situated in Mobile County, Alabama, to-wit: SITUATED IN THE COUNTY OF MOBILE AND STATE OF ALABAMA: COMMENCING AT THE NORTHEAST CORNER OF SECTION 15, TOWNSHIP 3 SOUTH, RANGE 3 WEST, THENCE WESTWARDLY, ALONG THE NORTH LINE OF THE SAID SECTION 15, A DISTANCE OF 750 FEET TO A POINT, THENCE SOUTH 30 FEET TO THE SOUTH LINE OF VICKERS ROAD AND THE POINT OF BEGINNING OF THE PROPERTY HEREIN DESCRIBED; THENCE CONTINUE SOUTH 180 FEET, THENCE EAST 100.2 FEET, THENCE SOUTH 00 DEGREES 27 MINUTES WEST, A DISTANCE OF 452.6 FEET, THENCE WEST 330.75 FEET, THENCE NORTH 00 DEGREES 26 MINUTES EAST A DISTANCE OF 632.2 FEET TO THE SOUTH LINE OF VICKERS ROAD, THENCE EAST, ALONG THE SOUTH LINE OF THE SAID VICKERS ROAD, 230.8 FEET TO THE POINT OF BEGINNING. SUBJECT HOWEVER TO THE ROADWAY EASEMENT 10 FEET IN WIDTH ACROSS AND CONTIGUOUS TO, THE ENTIRE SOUTH LINE OF THE HEREIN DESCRIBED PROPERTY. TOGETHER WITH THE RIGHT OF INGRESS AND EGRESS OVER A STRIP OF LAND, THE CENTER-LINE OF WHICH IS THE EASTWARD PROJECTION OF THE SOUTH LINE OF THE HEREIN DESCRIBED PROPERTY; SAID STRIP OF LAND BEING 20 FEET WIDE AND EXTENDING EASTWARDLY TO THE WEST LINE OF MCCRARY ROAD. SUBJECT HOWEVER, TO ONE HALF INTEREST IN OIL, GAS AND MINERALS HERETOFORE RESERVED BY DAVID A. FEARS, ET UX BY INSTRUMENT RECORDED IN DEED BOOK 438 N.S. PAGES 515-518 OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE COURT OF MOBILE COUNTY, ALABAMA. Property Street Address for Informational Purposes: 9325 Vickers Rd Semmes AL 36575 Said property will be sold “AS IS”. NO REPRESENTATION OR WARRANTY, EXPRESSED OR IMPLIED, IS MADE AS TO THE TITLE OF SAID PROPERTY. Said property is subject to any title deficiencies including but not limited to: any outstanding ad valorem taxes – including taxes which are a lien but not yet due and payable, federal tax liens any matters which might be disclosed by an accurate survey and inspection of the property, any assessments liens, encumbrances, zoning ordinances, restrictions, covenants, and matters of record superior to the Mortgage first set out above. Said property will be sold subject to the right of redemption of all parties entitled thereto. The highest bidder must tender the total amount of the winning bid in certified funds at the time and place of sale. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand the rights and programs as a part of the foreclosure process. This sale will be made for the purpose of paying the same and all expenses of this sale, as provided in said Mortgage and by Alabama law. This sale is subject to postponement or cancellation. **This is an attempt to collect a debt and any information obtained may be used for that purpose.** BANK OF AMERICA, N.A., Mortgagee or Transferee Jonathan Smothers, Esq ALAW One Independence Plaza, Suite 416 Birmingham, AL 35209 Attorney for Mortgagee/Transferee 23-010308 A-4799103
Call News 11/01/2023, 11/08/2023, 11/15/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Ann Marie Orso to Mortgage Electronic Registration Systems, Inc., as nominee for Quicken Loans Inc, dated April 24, 2006 said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 5962, Page 137 . Said mortgage was subsequently sold, assigned and transferred to LoanCare, LLC. Under and by virtue of the power of sale contained in said mortgage, the undersigned, LoanCare, LLC, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse in Mobile County, Alabama on November 20, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following describe real estate situated in Mobile County, Alabama, to-wit: LOT B, WOODIE LANE SUBDIVISION AS RECORDED IN MAP BOOK 49, PAGE 92 IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA. Property Street Address for Informational Purposes: 9945 Woodie Ln Irvington AL 36544 Said property will be sold “AS IS”. NO REPRESENTATION OR WARRANTY, EXPRESSED OR IMPLIED, IS MADE AS TO THE TITLE OF SAID PROPERTY. Said property is subject to any title deficiencies including but not limited to: any outstanding ad valorem taxes – including taxes which are a lien but not yet due and payable, federal tax liens any matters which might be disclosed by an accurate survey and inspection of the property, any assessments liens, encumbrances, zoning ordinances, restrictions, covenants, and matters of record superior to the Mortgage first set out above. Said property will be sold subject to the right of redemption of all parties entitled thereto. The highest bidder must tender the total amount of the winning bid in certified funds at the time and place of sale. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand the rights and programs as a part of the foreclosure process. This sale will be made for the purpose of paying the same and all expenses of this sale, as provided in said Mortgage and by Alabama law. This sale is subject to postponement or cancellation. **This is an attempt to collect a debt and any information obtained may be used for that purpose.** LoanCare, LLC, Mortgagee or Transferee Jonathan Smothers, Esq ALAW One Independence Plaza, Suite 416 Birmingham, AL 35209 Attorney for Mortgagee/Transferee 23-010292 A-4799100
Call News 11/01/2023, 11/08/2023, 11/15/2023

MORTGAGE FORECLOSURE NOTICE
Default having been made in the terms of that certain Mortgage, executed on 11/26/2014, by Joseph Elliott and Amber Elliott, husband and wife, as Mortgagors, to Mortgage Electronic Registration Systems, Inc. as nominee for American Home Free Mortgage, LLC as Mortgagee, which said Mortgage is recorded in the Office of the Judge of Probate, Mobile County, Alabama, in Book LR7211, Page 1801 and recorded on 12/03/2014, and subsequently assigned to Carrington Mortgage Services, LLC and recorded in the Office of the Judge of Probate, Mobile County, Alabama on 6/9/2023 in Instrument # 2023035479 and default having continued under the terms of said Mortgage, and by virtue of Alabama Code Section 35-10-3 and 35-10-2, the following described real property will be sold at public outcry, for cash, to the highest bidder, in front of the Courthouse door of said County, during the legal hours of sale, on 12/13/2023.
LOT 12, EDGEWOOD PLACE, UNIT SIX, ACCORDING TO PLAT THEREOF RECORDED IN MAP BOOK 43, PAGE 113 OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA.
Subject to all easements, restrictions and reservations appearing of record. Said sale will also be made subject to any Federal Tax Liens and/or Special Assessments of any nature, if any, which might adversely affect the title to the property.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The property is being sold “as is, where is”. Said property is sold without warranty or recourse, expressed or implied as to title, use or enjoyment.
This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure.
This sale is subject to postponement or cancellation.
Kent D. McPhail
McPhail Sanchez, LLC
Counsel for Mortgagee/Transferee
126 Government Street
Mobile, AL 36602
251-438-2333
Call News 11/01/2023, 11/08/2023, and 11/15/2023

NOTICE OF
MORTGAGE FORECLOSURE SALE
STATE OF ALABAMA
COUNTY OF MOBILE
Default having been made of the terms of the loan documents secured by that certain mortgage executed by Harry M Widener An Unmarried Person to Mortgage Electronic Registration Systems, Inc., as mortgagee, as nominee for Freedom Mortgage Corporation, its successors and assigns dated April 30, 2016; said mortgage being recorded on May 9, 2016, in Book 7377, Page 347 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to Nationstar Mortgage LLC by assignment recorded in Deed Book 7534, Page 643 in the Office of the Judge of Probate of Mobile County, ALABAMA.
The undersigned, Nationstar Mortgage LLCunder and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 29th day of November, 2023 the following property, situated in Mobile County, Alabama, to-wit:
Lot 34, Hamilton Creek Estates as recorded in Map Book 34, Page 63 of the records in the Office of the Judge of Probate, Mobile County, Alabama.
Said property is commonly known as 9636 Hamilton Creek Dr, Mobile, AL 36695.
Should a conflict arise between the property address and the legal description the legal description will control.
Said property will be sold subject to any outstanding ad valorem taxes (including taxes which are a lien, but not yet due and payable), the right of redemption of any taxing authority, all outstanding liens for public utilities which constitute liens upon the property, any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, easements, rights-of-way, zoning ordinances, restrictions, special assessments, covenants, the statutory right of redemption pursuant to Alabama law, and any matters of record including, but not limited to, those superior to said Mortgage first set out above. Said property will be sold on an “as-is” basis without any representation, warranty or recourse against the above-named or the undersigned. The successful bidder must present certified funds in the amount of the winning bid at the time and place of sale.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The sale will be conducted subject (1) to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and (2) to final confirmation and audit of the status of the loan with the holder of the Mortgage.
NATIONSTAR MORTGAGE LLC
as holder of said mortgage
McCalla Raymer Leibert Pierce, LLC
Two North Twentieth
2 20th Street North, Suite 1000
Birmingham, AL 35203
(205) 216-4238
FT21@mccalla.com
File No. 23-05282AL
www.foreclosurehotline.net
Call News 11/01/2023,11/08/2023,11/15/2023

NOTICE OF
MORTGAGE FORECLOSURE SALE
STATE OF ALABAMA
COUNTY OF MOBILE
Default having been made of the terms of the loan documents secured by that certain mortgage executed by Carla H Krause A Single Person to Wells Fargo Bank, N.A. dated July 13, 2009; said mortgage being recorded on July 27, 2009, in Book 6560, Page 476 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to U.S. BANK TRUST NATIONAL ASSOCIATION, NOT IN ITS INDIVIDUAL CAPACITY BUT SOLELY AS OWNER TRUSTEE FOR VRMTG ASSET TRUST in Instrument 2023051944 in the Office of the Judge of Probate of Mobile County, ALABAMA.
The undersigned, U.S. BANK TRUST NATIONAL ASSOCIATION, NOT IN ITS INDIVIDUAL CAPACITY BUT SOLELY AS OWNER TRUSTEE FOR VRMTG ASSET TRUSTunder and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 30th day of November, 2023 the following property, situated in Mobile County, Alabama, to-wit:
LOT 3, BLOCK 87, PINEHURST DELANY’S ADDITION TO SPRINGHILL AS RECORDED IN DEED BOOK 138 N.S., PAGES 118-122 IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY ALABAMA.
Said property is commonly known as 1054 Wesley Ave, Mobile, AL 36609.
Should a conflict arise between the property address and the legal description the legal description will control.
Said property will be sold subject to any outstanding ad valorem taxes (including taxes which are a lien, but not yet due and payable), the right of redemption of any taxing authority, all outstanding liens for public utilities which constitute liens upon the property, any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, easements, rights-of-way, zoning ordinances, restrictions, special assessments, covenants, the statutory right of redemption pursuant to Alabama law, and any matters of record including, but not limited to, those superior to said Mortgage first set out above. Said property will be sold on an “as-is” basis without any representation, warranty or recourse against the above-named or the undersigned. The successful bidder must present certified funds in the amount of the winning bid at the time and place of sale.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The sale will be conducted subject (1) to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and (2) to final confirmation and audit of the status of the loan with the holder of the Mortgage.
U.S. BANK TRUST NATIONAL ASSOCIATION, NOT IN ITS INDIVIDUAL CAPACITY BUT SOLELY AS OWNER TRUSTEE FOR VRMTG ASSET TRUST
as holder of said mortgage
McCalla Raymer Leibert Pierce, LLC
Two North Twentieth
2 20th Street North, Suite 1000
Birmingham, AL 35203
(205) 216-4238
FT21@mccalla.com
File No. 23-05070AL
www.foreclosurehotline.net
Call News 11/01/2023,11/08/2023,11/15/2023

NOTICE OF FORECLOSURE SALE
MOBILE COUNTY
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Marietta V. Demming, an unmarried female, originally in favor of Mortgage Electronic Registration Systems, Inc., as mortgagee, as nominee for Embrace Home Loans, Inc., its successors and assigns, on November 7, 2016, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, at Book LR7448, Page 1797; the undersigned Lakeview Loan Servicing, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash or certified funds, in front of the main entrance of the Courthouse at Mobile County, Alabama, on December 13, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:
Lot 9, Franklin Estates, according to plat thereof recorded in Map Book 104, Page 82 of the records in the Office of the Judge of Probate, Mobile County, Alabama.
Property street address for informational purposes: 3272 Franklin Ct Mobile, AL 36618
THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, SUBJECT TO ANY EASEMENTS, ENCUMBRANCES, AND EXCEPTIONS REFLECTED IN THE MORTGAGE AND THOSE CONTAINED IN THE RECORDS OF THE OFFICE OF THE JUDGE OF PROBATE OF THE COUNTY WHERE THE ABOVE-DESCRIBED PROPERTY IS SITUATED. THIS PROPERTY WILL BE SOLD WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender cash or certified funds made payable to Aldridge Pite, LLP at the time and place of the sale. Aldridge Pite, LLP reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Lakeview Loan Servicing, LLC, Mortgagee/Transferee ALDRIDGE PITE, LLP Six Piedmont Center 3525 Piedmont Road, N.E., Suite 700 Atlanta, GA 30305. Attorney for Mortgagee/Transferee.
THIS OFFICE IS ACTING AS A DEBT COLLECTOR AND IS ATTEMPTING TO COLLECT A DEBT. ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
Call News 10/25/2023, 11/1/2023, 11/8/2023

NOTICE OF SALE UNDER POWER
FORECLOSURE NOTICE
WHEREAS, default has occurred in the performance of the covenants, terms and conditions of a mortgage from TAMMY ABNER, MARRIED to MORTGAGE ELECTRONIC REGISTRATION SYSTEMS INC. AS MORTGAGEE, AS NOMINEE FOR PENNYMAC LOAN SERVICES, LLC, on the 24th day of June, 2021, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, on June 30, 2021, at Instrument Number 2021042212, Mobile County, Alabama Records, said Mortgage having subsequently been transferred and assigned to PennyMac Loan Services, LLC, by instrument recorded in the aforesaid Probate Office; notice is hereby given that the undersigned PennyMac Loan Services, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash at the Main Entrance of the Mobile County Courthouse, 205 Government Street, Mobile, AL 36602 in Mobile, Mobile County, Alabama, on November 30, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:
ALL THAT CERTAIN PARCEL OF LAND SITUATE IN THE COUNTY OF MOBILE, STATE OF ALABAMA, MORE PARTICULARLY DESCRIBED AS FOLLOWS:
LOT 49, CORRECTION PLAT, WAKEFIELD PLACE, UNIT 2, ACCORDING TO PLAT THEREOF RECORDED IN MAP BOOK 99 PAGE 40 OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA. EXCEPTING THEREFROM SUCH OIL, GAS AND OTHER MINERALS IN, ON AND UNDER SAID REAL PROPERTY, TOGETHER WITH ALL RIGHTS IN CONNECTION THEREWITH, AS HAVE PREVIOUSLY BEEN RESERVED BY OR CONVEYED TO OTHERS, IT BEING THE INTENTION OF THE GRANTOR TO CONVEY TO THE GRANTEES ONLY THE INTEREST GRANTOR OWNS THEREIN, IF ANY.
PARCEL ID: 2708280000081099
Said legal description being controlling, however the property is more commonly known as 1240 REEVES CT, MOBILE, AL 36695.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
This property will be sold on an “as is, where is” basis, subject to any easements, encumbrances, and exceptions reflected in the mortgage and those contained in the records of the Office of the Judge of Probate in the county where the above-described property is situated. This property will be sold subject to the right of redemption of all parties entitled thereto and subject to any outstanding ad valorem taxes (including taxes which are a lien, whether or not now due and payable). This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation.
PennyMac Loan Services, LLC, Mortgagee/Transferee
THE BELOW LAW FIRM MAY BE HELD TO BE ACTING AS A DEBT COLLECTOR, UNDER FEDERAL LAW. IF SO, ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
Rubin Lublin, LLC, Attorney for Mortgagee/Transferee
11 N. Water Street, Suite 10290, Mobile, AL 36602
Telephone Number: (877) 813-0992 Case No. PNY-22-06233-5
rlselaw.com/property-listing
Call News 11/01/2023, 11/08/2023, 11/15/2023

NOTICE OF SALE UNDER POWER
FORECLOSURE NOTICE
WHEREAS, default has occurred in the performance of the covenants, terms and conditions of a mortgage from Christopher Bryan and Melissa S Bryan, husband and wife to MORTGAGE ELECTRONIC REGISTRATION SYSTEMS INC AS NOMINEE FOR SOUTHWEST FUNDING. L.P., on the 6th day of October, 2016, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, on October 18, 2016, in Deed/Mortgage Book LR7438, Page 346, Mobile County, Alabama Records, said Mortgage having subsequently been transferred and assigned to PennyMac Loan Services, LLC, by instrument recorded in the aforesaid Probate Office; notice is hereby given that the undersigned PennyMac Loan Services, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash in front of the main entrance of the Courthouse in Mobile, Mobile County, Alabama, on November 29, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:
COMMENCING AT THE SOUTHWEST CORNER OF THE WEST HALF OF THE EAST HALF OF THE NORTHWEST QUARTER OF THE NORTHWEST QUARTER, SECTION 2, TOWNSHIP 3 SOUTH, RANGE 3 WEST; THENCE NORTH 01 DEGREES 10 MINUTES EAST ALONG THE WEST LINE OF THE WEST HALF OF THE EAST HALF OF THE NORTHWEST QUARTER OF THE NORTHWEST QUARTER OF SAID SECTION 2, A DISTANCE OF 1297.29 FEET TO THE SOUTH LINE OF THE BROADUS LOOP ROAD; THENCE SOUTH 01 DEGREES 10 MINUTES WEST, ALONG THE EAST LINE OF A PRIVATE ROAD, 425.43 FEET; THENCE SOUTH 03 DEGREES 22 MINUTES EAST ALONG SAID PRIVATE ROAD, 219.32 FEET; THENCE SOUTH 07 DEGREES 56 MINUTES EAST ALONG THE EAST LINE OF SAID PRIVATE ROAD, 81.87 FEET, TO THE POINT OF BEGINNING; THENCE SOUTH 88 DEGREES 50 MINUTES EAST, 299.73 FEET TO AN OLD FENCE LINE; THENCE SOUTH 01 DEGREES 10 MINUTES WEST ALONG SAID OLD FENCE LINE, 100 FEET; THENCE NORTH 88 DEGREES 50 MINUTES WEST, 290.0 FEET. TO THE EAST LINE OF SAID PRIVATE ROAD; THENCE NORTH 01 DEGREES 16 MINUTES EAST ALONG SAID PRIVATE ROAD, 36.67 FEET; THENCE NORTH 07 DEGREES 56 MINUTES WEST ALONG SAID PRIVATE ROAD, 64.44 TO THE POINT OF BEGINNING.
TOGETHER WITH:
COMMENCING AT THE SOUTHWEST CORNER OF THE WEST HALF OF THE EAST HALF OF THE NORTHWEST QUARTER OF THE NORTHWEST QUARTER OF SECTION 2, TOWNSHIP 3 SOUTH, RANGE 3 WEST; THENCE SOUTH 89 DEGREES 06 MINUTES EAST ALONG AN OLD FENCE, 40.0 FEET TO THE EAST LINE OF A PRIVATE ROAD; THENCE NORTH 01 DEGREES 16 MINUTES EAST ALONG THE EAST LINE OF A SAID PRIVATE ROAD, 370.86 FEET, TO THE POINT OF BEGINNING; THENCE CONTINUE NORTH 01 DEGREES 16 MINUTES EAST ALONG THE EAST LINE OF SAID PRIVATE ROAD, 100.0 FEET; THENCE SOUTH 88 DEGREES 50 MINUTES EAST, 290 FEET TO AN OLD FENCE LINE, THENCE SOUTH 01 DEGREES 10 MINUTES WEST ALONG THE OLD FENCE LINE, 100.0 FEET; THENCE NORTH 88 DEGREES 50 MINUTES WEST, 290 FEET TO THE POINT OF BEGINNING.
TOGETHER WITH THE RIGHT OF INGRESS AND EGRESS OVER A 40 FOOT WIDE PRIVATE ROADWAY, THE EAST LINE OF WHICH IS DESCRIBED AS BEGINNING AT THE SOUTHWEST CORNER OF THE ABOVE DESCRIBED PROPERTY; THENCE NORTH 01 DEGREES 16 MINUTES EAST 136.37 FEET; THENCE NORTH 07 DEGREES 56 MINUTES WEST, 146.31 FEET; THENCE NORTH 03 DEGREES 22 MINUTES WEST, 219.32 FEET; THENCE NORTH 01 DEGREES 10 MINUTES EAST, 425.43 FEET TO THE SOUTH LINE OF THE BROADUS LOOP ROAD.
Said legal description being controlling, however the property is more commonly known as 6211 VIVIAN BROADUS RD, EIGHT MILE, AL 36613.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
This property will be sold on an “as is, where is” basis, subject to any easements, encumbrances, and exceptions reflected in the mortgage and those contained in the records of the Office of the Judge of Probate in the county where the above-described property is situated. This property will be sold subject to the right of redemption of all parties entitled thereto and subject to any outstanding ad valorem taxes (including taxes which are a lien, whether or not now due and payable). This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation.
PennyMac Loan Services, LLC, Mortgagee/Transferee
THE BELOW LAW FIRM MAY BE HELD TO BE ACTING AS A DEBT COLLECTOR, UNDER FEDERAL LAW. IF SO, ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
Rubin Lublin, LLC, Attorney for Mortgagee/Transferee
11 N. Water Street, Suite 10290, Mobile, AL 36602
Telephone Number: (877) 813-0992 Case No. PNY-18-05209-4
rlselaw.com/property-listing
Call News 11/01/2023, 11/08/2023, 11/15/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed on August 15, 2013 by Derrick O Pettaway, A Single Person, originally in favor of Wells Fargo Bank, N.A., and recorded in LR7074 at 816 on September 12, 2013, in the Office of the Judge of Probate of Mobile County, Alabama. LOGS Legal Group LLP, as counsel for Mortgagee or Transferee and under and by virtue of power of sale contained in the said mortgage will, on December 7, 2023, sell at public outcry to the highest bidder at the main entrance of the Mobile County, Alabama, Courthouse in the City of Mobile, during the legal hours of sale, the following real estate situated in Mobile County, Alabama, to wit:
THE FOLLOWING DESCRIBED REAL ESTATE, SITUATED IN THEODORE, IN THE COUNTY OF MOBILE, STATE OF ALABAMA. LOT 2, J C SULLIVAN SUBDIVISION, ACCORDING TO THE PLAT THEREOF RECORDED IN MAP BOOK 42, AT PAGE 99, OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE COURT OF MOBILE COUNTY, ALABAMA BEING THE SAME PREMISES CONVEYED TO DERRICK 0 PETTAWAY, A SINGLE PERSON FROM GWENDOLYN M WILLIAMS, A SINGLE PERSON AND DERRICK 0. PETTAWAY, A SINGLE PERSON BY QUIT CLAIM DEED DATED 6/3/2013, AND RECORDED ON 6/5/2013, AT BOOK 7034, PAGE 119, IN MOBILE COUNTY, AL
For informational purposes only, the property address is: 7035 Smith Aly, Theodore, AL 36582.
Any property address provided is not part of the legal description of the property sold herein and in the event of any discrepancy, the legal description referenced herein shall control.
This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. Furthermore, the property to be offered pursuant to this notice of sale is being offered for sale, transfer and conveyance AS IS, WHERE IS. Neither the mortgagee, nor the officers, directors, attorneys, employees, agents or authorized representative of the mortgagee make any representation or warranty relating to the title or any physical, environmental, health or safety conditions existing in, on, at or relating to the property offered for sale. Any and all responsibilities or liabilities arising out of or in any way relating to any such condition, including those suggested by Code of Ala. (1975) § 35-4-271, expressly are disclaimed. This sale is subject to all prior liens and encumbrances and unpaid taxes and assessments including any transfer tax associated with the foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars and no/100 ($5,000.00) in certified or cash funds at the time and place of the sale. The balance of the purchase price must be paid in certified funds by close of business on the next business day thereafter at the Law Office of LOGS Legal Group LLP at the address indicated below. LOGS Legal Group LLP reserves the right to award the bid to the next highest bidder, or to reschedule the sale, should the highest bidder fail to timely tender the total amount due.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
Wells Fargo Bank, N.A., and its successors and assigns
Mortgagee or Transferee
LOGS LEGAL GROUP LLP
1878 Jeff Rd. NW, Suite “I”
Huntsville, AL 35806
(704) 333-8107/ 23-023213
Attorneys for Mortgagee or Transferee
Call News October 25, 2023 and November 1, 2023 and November 8, 2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed on June 4, 2004 by Thomas Keith Tinnel, a married man, originally in favor of Mortgage Electronic Registration Systems, Inc., as nominee for CTZ Mortgage Company, LLC, and recorded in 5604 at 1588 on June 9, 2004, in the Office of the Judge of Probate of Mobile County, Alabama. LOGS Legal Group LLP, as counsel for Mortgagee or Transferee and under and by virtue of power of sale contained in the said mortgage will, on November 30, 2023, sell at public outcry to the highest bidder at the main entrance of the Mobile County, Alabama, Courthouse in the City of Mobile, during the legal hours of sale, the following real estate situated in Mobile County, Alabama, to wit:
LOT 10, BLOCK M, BERKSHIRE HILLS, PART A, ACCORDING TO PLAT THEREOF RECORDED IN MAP BOOK 6, PAGES 595-598 OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA
For informational purposes only, the property address is: 4014 Cresthaven Rd, Mobile, AL 36609.
Any property address provided is not part of the legal description of the property sold herein and in the event of any discrepancy, the legal description referenced herein shall control.
This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. Furthermore, the property to be offered pursuant to this notice of sale is being offered for sale, transfer and conveyance AS IS, WHERE IS. Neither the mortgagee, nor the officers, directors, attorneys, employees, agents or authorized representative of the mortgagee make any representation or warranty relating to the title or any physical, environmental, health or safety conditions existing in, on, at or relating to the property offered for sale. Any and all responsibilities or liabilities arising out of or in any way relating to any such condition, including those suggested by Code of Ala. (1975) § 35-4-271, expressly are disclaimed. This sale is subject to all prior liens and encumbrances and unpaid taxes and assessments including any transfer tax associated with the foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars and no/100 ($5,000.00) in certified or cash funds at the time and place of the sale. The balance of the purchase price must be paid in certified funds by close of business on the next business day thereafter at the Law Office of LOGS Legal Group LLP at the address indicated below. LOGS Legal Group LLP reserves the right to award the bid to the next highest bidder, or to reschedule the sale, should the highest bidder fail to timely tender the total amount due.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
CSMC 2021-RPL7 Trust, and its successors and assigns
Mortgagee or Transferee
LOGS LEGAL GROUP LLP
1878 Jeff Rd. NW, Suite “I”
Huntsville, AL 35806
(704) 333-8107/ 23-023104
Attorneys for Mortgagee or Transferee
Call News October 25, 2023 and November 1, 2023 and November 8, 2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Jeremy T. Farmer, single, originally in favor of Mortgage Electronic Registration Systems, Inc., as nominee for USAA Federal Savings Bank, on October 25, 2013, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Bk: LR7091 Pg 624; the undersigned Select Portfolio Servicing, Inc., as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on December 14, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 18, Aden Hills, Unit Two, according to plat thereof recorded in Map Book 27, Page 16, of the records in the Office of the Judge of Probate of Mobile County, Alabama. Property street address for informational purposes: 7971 Suzanne Way , Mobile, AL 36695. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Select Portfolio Servicing, Inc., (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-04667
Call News 10/25/2023, 11/01/2023, 11/08/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Patrick Shawn Becker Jr. and Shellie Newton, husband and wife, originally in favor of Mortgage Electronic Registration Systems, Inc. solely as nominee for Homestar Financial Corp, on December 27, 2021, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Instrument No. 2022000495; the undersigned PennyMac Loan Services, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 16, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 4, Scenic Hills Estates, Resubdivision of Lots Numbered 3 through 11, Unit One, according to plat thereof recorded in Map Book 25, Page 36 of records in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 9450 Scenic Hills Dr , Semmes, AL 36575. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. PennyMac Loan Services, LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-02955
Call News 10/25/2023, 11/01/2023, 11/08/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Angela Christina Johnson to Gulf Winds Credit Union, dated August 21, 2020 said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Instrument Number 2020051090. Said mortgage was subsequently sold, assigned and transferred to Towne Mortgage Company d/b/a AmeriCU Mortgage. Under and by virtue of the power of sale contained in said mortgage, the undersigned, Towne Mortgage Company d/b/a AmeriCU Mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse in Mobile County, Alabama on December 7, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following describe real estate situated in Mobile County, Alabama, to-wit: COMMENCING AT THE SOUTHWEST CORNER OF LOT 19 OF SUBDIVISION OF LOT 3 OF THE MCVOY TRACT ACCORDING TO THE MAP IN DEED BOOK 156 N.S., PAGES 70-71, PROBATE COURT RECORDS OF MOBILE COUNTY, ALABAMA; THENCE NORTH ALONG THE LINE BETWEEN LOT 19 AND 17 OF SAID SUBDIVISION 200 FEET TO AN IRON STAKE FOR THE POINT OF BEGINNING; THENCE WEST 45 FEET AND PARALLEL WITH THE SOUTH LINE OF LOT 17 TO AN IRON STAKE; THENCE NORTH 75 FEET TO AN IRON STAKE AND PARALLEL WITH THE WEST LINE OF LOT 17; THENCE EAST 113 FEET 4 INCHES TO AN IRON STAKE AND PARALLEL WITH THE SOUTH LINE OF LOT 17 AND LOT 19; THENCE SOUTH 25 DEGREES 25 MINUTES EAST A DISTANCE OF 61 FEET, MORE OR LESS, TO THE POINT OF A CURVE WITH A RADIUS OF 50 FEET; THENCE FOLLOWING SAID RADIUS 22.21 FEET TO AN IRON STAKE; THENCE WEST 100 FEET TO AN IRON STAKE AND PARALLEL WITH THE SOUTH LINE OF LOT 19 TO THE POINT OF BEGINNING. Property Street Address for Informational Purposes: 3416 Gonzales Rd, Mobile, AL 36605 Said property will be sold “AS IS”. NO REPRESENTATION OR WARRANTY, EXPRESSED OR IMPLIED, IS MADE AS TO THE TITLE OF SAID PROPERTY. Said property is subject to any title deficiencies including but not limited to: any outstanding ad valorem taxes – including taxes which are a lien but not yet due and payable, federal tax liens any matters which might be disclosed by an accurate survey and inspection of the property, any assessments liens, encumbrances, zoning ordinances, restrictions, covenants, and matters of record superior to the Mortgage first set out above. Said property will be sold subject to the right of redemption of all parties entitled thereto. The highest bidder must tender the total amount of the winning bid in certified funds at the time and place of sale. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand the rights and programs as a part of the foreclosure process. This sale will be made for the purpose of paying the same and all expenses of this sale, as provided in said Mortgage and by Alabama law. This sale is subject to postponement or cancellation. **This is an attempt to collect a debt and any information obtained may be used for that purpose.** Towne Mortgage Company d/b/a AmeriCU Mortgage, Mortgagee or Transferee Jonathan Smothers, Esq ALAW One Independence Plaza, Suite 416 Birmingham, AL 35209 Attorney for Mortgagee/Transferee
23-008776 A-4799577
Call News 10/25/2023, 11/01/2023, 11/08/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Mary J Glover, Unmarried, originally in favor of Chase Manhattan Mortgage Corporation, on December 3, 2004, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 5701 Page 832; the undersigned Federal Home Loan Mortgage Corporation, as Trustee for the FHLMC SLST 2020-3, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 29, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Commencing at the Northwest corner of the South half of the Northwest Quarter, Section 33, Township 2 South, Range 2 West, Mobile County, Alabama, thence South 00 degrees 27 minutes 00 seconds East, 1517.28 feet to the Point of Beginning of the property herein described; Thence North 89 degrees 33 minutes 00 seconds East 1001.65 feet to a point on the present West Right of Way line of View Point Road Extension (Right of Way varies); Thence South 00 degrees 13 minutes 00 seconds East along said West line a distance of 58.39 feet; Thence South 89 degrees 30 minutes 45 seconds West 160.0 feet; Thence South 06 degrees 01 minutes 05 seconds West, 92.09 feet to a point on the South line of property conveyed by instrument recorded in Real Property Book 2202, Page 459, Probate Court Records, Mobile County, Alabama; Thence South 89 degrees 33 minutes 00 seconds West along the South line of said property, a distance of 824.02 feet; Thence North 00 degrees 27 minutes 00 seconds West along the West line of said property, a distance of 150.0 feet to the Point of Beginning.. Property street address for informational purposes: 6649 View Point Rd , Eight Mile, AL 36613. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Federal Home Loan Mortgage Corporation, as Trustee for the FHLMC SLST 2020-3, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-07448
Call News 10/25/2023, 11/01/2023, 11/08/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed on November 20, 2006 by Christy S Langley a/k/a Christy Langley and Travis L Langley a/k/a Travis Langley, joint tenants with right of survivorship, both unmarried person, originally in favor of Regions Bank d/b/a Regions Mortgage, and recorded in 6085 at 582 on November 27, 2006, in the Office of the Judge of Probate of Mobile County, Alabama, and secured indebtedness having been transferred to Towd Point Mortgage Trust 2016-3, U.S. Bank National Association as Indenture Trustee. LOGS Legal Group LLP, as counsel for Mortgagee or Transferee and under and by virtue of power of sale contained in the said mortgage will, on November 30, 2023, sell at public outcry to the highest bidder at the main entrance of the Mobile County, Alabama, Courthouse in the City of Mobile, during the legal hours of sale, the following real estate situated in Mobile County, Alabama, to wit:
Lot 13, CRAIG PLACE as recorded in Map Book 16, Page 65 of the records in the Office of the Judge of Probate, Mobile County, Alabama.
For informational purposes only, the property address is: 119 Craig Dr, Saraland, AL 36571.
Any property address provided is not part of the legal description of the property sold herein and in the event of any discrepancy, the legal description referenced herein shall control.
This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. Furthermore, the property to be offered pursuant to this notice of sale is being offered for sale, transfer and conveyance AS IS, WHERE IS. Neither the mortgagee, nor the officers, directors, attorneys, employees, agents or authorized representative of the mortgagee make any representation or warranty relating to the title or any physical, environmental, health or safety conditions existing in, on, at or relating to the property offered for sale. Any and all responsibilities or liabilities arising out of or in any way relating to any such condition, including those suggested by Code of Ala. (1975) § 35-4-271, expressly are disclaimed. This sale is subject to all prior liens and encumbrances and unpaid taxes and assessments including any transfer tax associated with the foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars and no/100 ($5,000.00) in certified or cash funds at the time and place of the sale. The balance of the purchase price must be paid in certified funds by close of business on the next business day thereafter at the Law Office of LOGS Legal Group LLP at the address indicated below. LOGS Legal Group LLP reserves the right to award the bid to the next highest bidder, or to reschedule the sale, should the highest bidder fail to timely tender the total amount due.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
Towd Point Mortgage Trust 2016-3, U.S. Bank National Association as Indenture Trustee, and its successors and assigns
Mortgagee or Transferee
LOGS LEGAL GROUP LLP
1878 Jeff Rd. NW, Suite “I”
Huntsville, AL 35806
704-333-8107/ 22-022211
Attorneys for Mortgagee or Transferee
Call News October 25, 2023 and November 2, 2023 and November 9, 2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Bilizalde N. Mones to Mortgage Electronic Registration Systems, Inc., as nominee for Bank of America, N.A., dated October 22, 2009 said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 6593, Page 1363 . Said mortgage was subsequently sold, assigned and transferred to BANK OF AMERICA, N.A.. Under and by virtue of the power of sale contained in said mortgage, the undersigned, BANK OF AMERICA, N.A., will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse in Mobile County, Alabama on November 20, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following describe real estate situated in Mobile County, Alabama, to-wit: ALL THAT REAL PROPERTY SITUATED IN THE COUNTY OF MOBILE, STATE OF ALABAMA, DESCRIBED AS FOLLOWS, TO-WIT: LOT 11, MONTCLIFF, UNIT ONE, ACCORDING TO PLAT THEREOF RECORDED IN MAP BOOK 13, PAGE 88, OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE OF MOBILE COUNTY, ALABAMA. Property Street Address for Informational Purposes: 564 Markham Dr Mobile AL 36609 Said property will be sold “AS IS”. NO REPRESENTATION OR WARRANTY, EXPRESSED OR IMPLIED, IS MADE AS TO THE TITLE OF SAID PROPERTY. Said property is subject to any title deficiencies including but not limited to: any outstanding ad valorem taxes – including taxes which are a lien but not yet due and payable, federal tax liens any matters which might be disclosed by an accurate survey and inspection of the property, any assessments liens, encumbrances, zoning ordinances, restrictions, covenants, and matters of record superior to the Mortgage first set out above. Said property will be sold subject to the right of redemption of all parties entitled thereto. The highest bidder must tender the total amount of the winning bid in certified funds at the time and place of sale. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand the rights and programs as a part of the foreclosure process. This sale will be made for the purpose of paying the same and all expenses of this sale, as provided in said Mortgage and by Alabama law. This sale is subject to postponement or cancellation. **This is an attempt to collect a debt and any information obtained may be used for that purpose.** BANK OF AMERICA, N.A., Mortgagee or Transferee Jonathan Smothers, Esq ALAW One Independence Plaza, Suite 416 Birmingham, AL 35209 Attorney for Mortgagee/Transferee 23-010729 A-4799565
Call News 10/25/2023, 11/01/2023, 11/08/2023

FORECLOSURE NOTICE
Default having been made in the payment of the indebtedness described in and secured by that certain vendor’s lien retained in deed executed by DONNIE VICKERS AND DEBORAH VICKERS dated February 3, 2016 and recorded in Book LR7345, Page 901 Probate Records of Mobile County, Alabama to DORETTA ELLIS; and the undersigned holder of said vendor’s lien deed having declared the entire indebtedness due and payable notice is hereby given that the undersigned, under and by virtue of the powers contained in said vendor’s lien deed, will sell at public outcry for cash to the highest bidder during the legal hours of sale on the 14th day of November, 2023, at the front or main door of the Government Street entrance of Government Plaza, the Courthouse of Mobile County Alabama, , the following described real property lying and being situated in the County of Mobile, State of Alabama, to-wit:
Lots Twenty Two (22) and Twenty Three (23), Sun Valley Subdivision according to plat thereof recorded in Map Book 9, Pages 84-85 of the Probate Court Records of Mobile County, Alabama.
Said sale is made for the purpose of paying the indebtedness secured by said vendor’s lien deed and all charges as provided therein and the expense incident thereto, including a reasonable attorney’s fee.
Said property will be sold on an “as is, where is” basis subject to any easements, encumbrances, and exceptions contained in said vendor’s lien deed and those contained in the records of the Office of the Judge of Probate where the above-described property is situated. Said property will be sold without warranty or recourse, expressed or implied as to title, use and/or enjoyment, and will be sold subject to the right of redemption of all parties entitled thereto.
ALABAMA LAW GIVES SOME PERSONS WHO HAVE AN INTEREST IN PROPERTY THE RIGHT TO REDEEM THE PROPERTY UNDER CERTAIN CIRCUMSTANCES. PROGRAMS MAY ALSO EXIST THAT HELP PERSONS AVOID OR DELAY THE FORECLOSURE PROCESS. AN ATTORNEY SHOULD BE CONSULTED TO HELP YOU UNDERSTAND THESE RIGHTS AND PROGRAMS AS A PART OF THE FORECLOSURE PROCESS.
DORETTA ELLIS
Holder of said Vendor’s Lien Deed
JIM H. FERNANDEZ
FERNANDEZ, CRANE & COMBS, L.L.C.
Attorneys for Holder of said Vendor’s Lien Deed
Post Office Box 162
Mobile, Alabama 36601 / (251) 433-0738
Call News October 25, November 1 and November 8, 2023

LEGAL NOTICE
NOTICE OF MORTGAGE FORECLOSURE SALE
STATE OF ALABAMA
COUNTY OF MOBILE
THIS IS AN ATTEMPT TO COLLECT A DEBT. ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
Default having been made in the payment of the debt secured by that certain mortgage executed by Keith Mulvey and Susan Mulvey, Mortgagor(s), to Mortgage Electronic Registration Systems, Inc. as nominee for New Day Financial, LLC, Mortgagee, on January 17, 2009, said mortgage being recorded on February 3, 2009 in the Probate Office of Mobile County, Alabama in Instrument Number 2009007047, Book 6489, Page 39, and later assigned to U.S. Bank Trust National Association, as Trustee of the SCIG Series III Trust, by reason of such default, having declared all the indebtedness secured by said mortgage due and payable, and such default continuing, notice is hereby given that, acting under the power of sale contained in said mortgage, U.S. Bank Trust National Association, as Trustee of the SCIG Series III Trust will sell at public outcry, for cash, to the highest bidder, in front of the Courthouse door in the City of, Mobile County, Alabama during the legal hours of sale on November 29, 2023 the following described real estate situated in Mobile County, Alabama, to wit:
All that real property in the County of Mobile, State of Alabama, described as follows:
Lot 10, Vista Ridge, Unite Six, according to the plat thereof recorded in Map Book 47, Page 59, of the records in the Office of the Judge of Probate Court, Mobile County, Alabama.
Being the same property conveyed to Keith Mulvey and Susan Mulvey as joint tenants during their joint lives and upon the death of either of them, then to the survivor of them by deed from William C. McClain and Shelly L. McClain, husband and wife recorded 10/18/2005 in Deed Book 5860 page 154, in the Probate Judge’s Office for Mobile County, Alabama.
Commonly known as: 5212 Montiel Court, Mobile, AL 36693
Parcel ID #: 33-05-38-0-002-001.058
THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO.
Said sale will be made subject to any outstanding ad valorem taxes (including taxes which are a lien, whether or not now due and payable), any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, zoning ordinances, restrictions, covenants, and matters of record superior to the mortgage first set out above and restrictions of record in the Probate Office aforesaid, matters of survey, and to any Federal or State Tax liens, if any, and/or special assessments, if any, which might adversely affect the title to the premises.
Said sale will be made for the purpose of paying the indebtedness secured by the above described mortgage to U.S. Bank Trust National Association, as Trustee of the SCIG Series III Trust, Mortgagee, and the proceeds thereof will be applied as provided for in the terms of said mortgage.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to McMichael Taylor Gray LLC at the time and place of the sale. The balance of the purchase price must be paid in certified funds by noon the next business day to McMichael Taylor Gray LLC at 3550 Engineering Drive, Suite 260, Peachtree Corners, GA 30092.
McMichael Taylor Gray, LLC reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation.
U.S. Bank Trust National Association, as Trustee of the SCIG Series III Trust
AS ATTORNEY IN FACT FOR
Keith Mulvey and Susan Mulvey
TONI B. SMOKE, Attorney for Mortgagee
McMichael Taylor Gray, LLC
3550 Engineering Drive, Suite 260
Peachtree Corners, GA 30092
404-474-7149
MTG File No.: AL2023-00368
Call News October 25, and November 1, 8, 2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Joseph T. Samuels, Jr., single man, originally in favor of Mortgage Electronic Registration Systems, Inc., acting solely as nominee for Freedom Mortgage Corporation, on July 2, 2021, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Instrument Number 2021048957; the undersigned Freedom Mortgage Corporation, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on December 14, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Parcel A: A parcel of land and premises described as follows, to-wit: Beginning at the Northwest Corner of “Sasser Court” as recorded in Map Book 12, Page 13 in the Office of the Judge of Probate, Mobile County, Alabama; thence North 14 degrees 06 minutes 45 seconds West, 266.50 feet; thence North 22 degrees 21 minutes 29 seconds East, 318.83 feet to a point on the South right-of-way line of Sandhill Drive; thence South 86 degrees 30 minutes 16 seconds East and along the South right-of-way line of Sandhill Drive, 25.14 feet; thence South 46 degrees 33 minutes 16 seconds East and continuing along the Southerly right-of-way line of Sandhill Drive, 367.61 feet to the point of curvature of a cul-de-sac having a radius of 50 feet; thence run Southeasterly and along the arc of said cul-de-sac and being along the South right-of-way line of Sandhill Drive, 40.90 feet; thence South 41 degrees 42 minutes 11 seconds East, 135.96 feet to a point on the North line of said “SASSER COURT”; thence South 71 degrees 32 minutes 56 seconds West and along the North line of said “Sasser Court”, 170.71 feet to a point on the North right-of-way line of Sasser Lane; thence continue South 71 degrees 32 minutes 56 seconds West and along the North right-of-way line of said Sasser Lane, and also continuing along the North line of said “Sasser Court”, 123.00 feet; thence continuing South 71 degrees 32 minutes 56 seconds West and continuing along the North line of said “Sasser Court”, 191.51 feet to the Point of Beginning. Containing 3.68 acres. Parcel B: Commencing at the Northwest Corner of “Sasser Court” as recorded in Map Book 12, Page 13 in the Office of the Judge of Probate, Mobile County, Alabama; thence North 14 degrees 06 minutes 45 seconds West, 266.50 feet; thence North 22 degrees 21 minutes 29 seconds East; 107 .30 feet to the Point of Beginning; thence North 80 degrees 18 minutes 14 seconds West, 176.02 feet to a point; said point being the intersection of the South Right-of-Way line of Hildesheim Circle with the East Right-of-Way line of Hildesheim. Circle; thence North 8 degrees 46 minutes 46 seconds East and along the East Right-of-Way line of Hildsheim Circle, 181.93 feet to a point of the South Right-of-Way line of Sandhill Drive; thence South 86 degrees 30 minutes 16 seconds East and along the South Right-of-Way line of Sandhill Drive, 226.62 feet; thence South 22 degrees 21 minutes 29 seconds West 211.53 feet to the point of beginning. Containing 0.89 acres.. Property street address for informational purposes: 122 Sand Hill Dr , Eight Mile, AL 36613. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Freedom Mortgage Corporation, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-07557
Call News 10/25/2023, 11/01/2023, 11/08/2023

NOTICE OF
MORTGAGE FORECLOSURE SALE
STATE OF ALABAMA
COUNTY OF MOBILE
Default having been made of the terms of the loan documents secured by that certain mortgage executed by Ronald Emmery Hill And Ruby Ann Hill Husband And Wife to Financial Freedom Senior Funding Corporation dated March 5, 2009; said mortgage being recorded on March 18, 2009, in Book 6506, Page 1846 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to U.S. BANK TRUST NATIONAL ASSOCIATION, NOT IN ITS INDIVIDUAL CAPACITY BUT SOLELY AS OWNER TRUSTEE FOR VRMTG ASSET TRUST in Instrument 2023051933 in the Office of the Judge of Probate of Mobile County, ALABAMA.
The undersigned, U.S. BANK TRUST NATIONAL ASSOCIATION, NOT IN ITS INDIVIDUAL CAPACITY BUT SOLELY AS OWNER TRUSTEE FOR VRMTG ASSET TRUSTunder and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 20th day of November, 2023 the following property, situated in Mobile County, Alabama, to-wit:
THE FOLLOWING DESCRIBED REAL PROPERTY LOCATED IN THE COUNTY OF MOBILE, STATE OF ALABAMA, NAMELY: SOUTHEAST CORNER OF LOT 29-B FIRST ADDITION PINETUCKY AS PER PLAT RECORDED IN MAP BOOK 9, PAGE(S) 430, PROBATE COURT RECORDS, MOBILE COUNTY, STATE OF ALABAMA; THENCE SOUTH 70 DEG. 40’ EAST ALONG THE NORTH LINE OF MOFFAT ROAD TO A POINT ON THE EAST LINE OF LACOSTE ROAD; THENCE NORTH 00 DEG. 13’ 18” EAST ALONG SAID EAST LINE 303.27 FEET TO THE POINT OF BEGINNING OF THE PROPERTY HEREIN DESCRIBED; THENCE CONTINUE NORTH 00 DEG. 13’ 18” EAST 100.00 FEET TO A POINT; THENCE SOUTH 00 DEG. 04’ EAST 100.00 FEET TO A POINT; THENCE SOUTH 85 DEG. 53’ WEST 199.20 FEET TO THE POINT OF BEGINNING.
Said property is commonly known as 2980 Lacoste Rd, Mobile, AL 36618.
Should a conflict arise between the property address and the legal description the legal description will control.
Said property will be sold subject to any outstanding ad valorem taxes (including taxes which are a lien, but not yet due and payable), the right of redemption of any taxing authority, all outstanding liens for public utilities which constitute liens upon the property, any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, easements, rights-of-way, zoning ordinances, restrictions, special assessments, covenants, the statutory right of redemption pursuant to Alabama law, and any matters of record including, but not limited to, those superior to said Mortgage first set out above. Said property will be sold on an “as-is” basis without any representation, warranty or recourse against the above-named or the undersigned. The successful bidder must present certified funds in the amount of the winning bid at the time and place of sale.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The sale will be conducted subject (1) to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and (2) to final confirmation and audit of the status of the loan with the holder of the Mortgage.
U.S. BANK TRUST NATIONAL ASSOCIATION, NOT IN ITS INDIVIDUAL CAPACITY BUT SOLELY AS OWNER TRUSTEE FOR VRMTG ASSET TRUST
as holder of said mortgage
McCalla Raymer Leibert Pierce, LLC
Two North Twentieth
2 20th Street North, Suite 1000
Birmingham, AL 35203
(205) 216-4238
FT21@mccalla.com
File No. 23-05075AL
www.foreclosurehotline.net
Call News 10/25/2023,11/01/2023,11/08/2023

LEGAL NOTICE
NOTICE OF MORTGAGE FORECLOSURE SALE
STATE OF ALABAMA
COUNTY OF MOBILE
THIS IS AN ATTEMPT TO COLLECT A DEBT. ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
Default having been made in the payment of the debt secured by that certain mortgage executed by Mose Aron James, Jr, Mortgagor(s), to Citifinancial Corporation, LLC, Mortgagee, on August 9, 2007, said mortgage being recorded on August 13, 2007 in the Probate Office of Mobile County, Alabama in Instrument Number 2007062644, Book 6239, Page 172, and later assigned to U.S. Bank Trust National Association, as Trustee for LB-Dwelling Series V Trust, by reason of such default, having declared all the indebtedness secured by said mortgage due and payable, and such default continuing, notice is hereby given that, acting under the power of sale contained in said mortgage, U.S. Bank Trust National Association, as Trustee for LB-Dwelling Series V Trust will sell at public outcry, for cash, to the highest bidder, in front of the Courthouse door in the City of Mobile, Mobile County, Alabama during the legal hours of sale on November 15, 2023 the following described real estate situated in Mobile County, Alabama, to wit:
Lot 2, Block 1, of the resubdivision of the resubdivision of the First Unit of Gulf Heights, according to a plat thereof recorded in Map Book 5, Page 633, 634, of the records in the Office of the Judge of Probate Court of Mobile County, Alabama.
Subject to all restrictions, reservations, rights, easements, rights-of-way, provisions, covenants, terms, conditions and building set back line of record.
Commonly known as: 704 Caton Avenue, Mobile, AL 36617
Tax ID #: 29 02 44 0 027 010.XXX
THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO.
Said sale will be made subject to any outstanding ad valorem taxes (including taxes which are a lien, whether or not now due and payable), any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, zoning ordinances, restrictions, covenants, and matters of record superior to the mortgage first set out above and restrictions of record in the Probate Office aforesaid, matters of survey, and to any Federal or State Tax liens, if any, and/or special assessments, if any, which might adversely affect the title to the premises.
Said sale will be made for the purpose of paying the indebtedness secured by the above described mortgage to U.S. Bank Trust National Association, as Trustee for LB-Dwelling Series V Trust, Mortgagee, and the proceeds thereof will be applied as provided for in the terms of said mortgage.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to McMichael Taylor Gray LLC at the time and place of the sale. The balance of the purchase price must be paid in certified funds by noon the next business day to McMichael Taylor Gray LLC at 3550 Engineering Drive, Suite 260, Peachtree Corners, GA 30092.
McMichael Taylor Gray, LLC reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation.
U.S. Bank Trust National Association, as Trustee for LB-Dwelling Series V Trust
AS ATTORNEY IN FACT FOR
Mose Aron James, Jr.
TONI B. SMOKE, Attorney for Mortgagee
McMichael Taylor Gray, LLC
3550 Engineering Drive, Suite 260
Peachtree Corners, GA 30092
404-474-7149
MTG File No.: AL2023-00164
Call News October 18, 25 and November 1, 2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by George W. Cox and Crystal L. Cox aka Crystal Lynn Cox, husband and wife., originally in favor of Mortgage Electronic Registration Systems, Inc., as a nominee for Mortgage Research Center, LLC dba Veterans United Home Loans, on October 27, 2017, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Bk: LR7572 Pg: 1590; with loan modification agreement recorded in Instrument Number 2019004349 and Instrument Number 2022076840; the undersigned PennyMac Loan Services, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 29, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: A portion of Lot 4, according to map of Forest Home Subdivision, recorded in the Office of the Judge of Probate, Mobile County, Alabama, in Deed Book 114, Page 15 and being more particularly described as follows: Beginning at the Southwest corner of said Lot 4; said point being on the Easterly right of way line of U.S. Highway No. 45; thence North 64 degrees 24 minutes 10 seconds East a distance of 970.23 feet to a point on the East line of said Lot 4; said point also being on the Westerly right of way line of I. C. and G. Railroad; thence run Northwestwardly and along the Easterly line of said Lot 4 and also along the Westerly right of way line of the I. C. and G. Railroad a distance of 193.88 feet to the Northeast corner of said Lot; thence South 81 degrees 03 minutes 20 seconds West along the Northerly line of said Lot 4 a distance of 59.17 feet; thence South 64 degrees 24 minutes 10 seconds West a distance of 908.04 feet to a point on the Easterly right of way line of U.S. Highway No. 45; thence run Southeastwardly along the Easterly right of way line of said Highway a distance of 210.00 feet to the Point of Beginning.. Property street address for informational purposes: 5740 Highway 45 , Eight Mile, AL 36613. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. PennyMac Loan Services, LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-07442
Call News 10/18/2023, 10/25/2023, 11/01/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Devan Robert Smullen, a married man, originally in favor of Mortgage Electronic Registration SYstems, Inc., acting solely as nominee for GMFS, LLC, on April 27, 2018, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book LR7631 Page 560; the undersigned MidFirst Bank, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 30, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 1, John Dixon Subdivision, according to plat thereof recorded in Map Book 102, Page 93 of the records in the Office of the Judge of Probate, Mobile County, Alabama. Less and except Commencing at the Northeast corner of Lot 1, John Dixon Subdivision, as recorded in Map Book 102, Page 93 in the Office of the Judge of Probate, Mobile County, Alabama; thence South 00 degrees 04 minutes 50 seconds East, 185.00 feet to the point of beginning of the property herein described; thence South 00 degrees 04 minutes 50 seconds East, 35.00 feet; thence South 89 degrees 56 minutes 46 seconds West, 520.00 feet; thence North 00 degrees 04 minutes 50 seconds West, 220.00 feet; thence North 89 degrees 56 minutes 46 seconds East, 137.08 feet; thence South 00 degrees 04 minutes 50 seconds East 185.00 feet; thence North 89 degrees 56 minutes 46 seconds East 382.92 feet to the point of beginning.. Property street address for informational purposes: 12226 Potter Tract Road , Grand Bay, AL 36541. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. MidFirst Bank, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-06736
Call News 10/18/2023, 10/25/2023, 11/01/2023

FORECLOSURE NOTICE
Default having been made in the payment of the indebtedness described in and secured by that certain mortgage executed by TENEKIA S. HILL dated October 7, 2022 and recorded in Instrument No. 2022067086, Probate Records of Mobile County, Alabama to Thames, Jackson, Harris Company, Inc.; said mortgage was thereafter assigned to AUDREY PATTERSON by instrument dated October 7, 2022 and recorded as Instrument No. 2022072980 of the aforesaid probate court records; and the undersigned holder of said mortgage having declared the entire indebtedness due and payable notice is hereby given that the undersigned, under and by virtue of the powers contained in said mortgage, will sell at public outcry for cash to the highest bidder during the legal hours of sale on the 14TH DAY OF NOVEMBER, 2023, at the front or main door of the Government Street entrance of Government Plaza, the Courthouse of Mobile County Alabama, , the following described real property lying and being situated in the County of Mobile, State of Alabama, to-wit:
Lot 28, Block 6, according to the Survey of Government Street Extension, as recorded in Deed Book 156, Page 419 in the Office of the Judge of Probate of Mobile County, Alabama.
Said sale is made for the purpose of paying the indebtedness secured by said mortgage and all charges as provided therein and the expense incident thereto, including a reasonable attorney’s fee.
Said property will be sold on an “as is, where is” basis subject to any easements, encumbrances, and exceptions contained in said mortgage and those contained in the records of the Office of the Judge of Probate where the above-described property is situated. Said property will be sold without warranty or recourse, expressed or implied as to title, use and/or enjoyment, and will be sold subject to the right of redemption of all parties entitled thereto.
ALABAMA LAW GIVES SOME PERSONS WHO HAVE AN INTEREST IN PROPERTY THE RIGHT TO REDEEM THE PROPERTY UNDER CERTAIN CIRCUMSTANCES. PROGRAMS MAY ALSO EXIST THAT HELP PERSONS AVOID OR DELAY THE FORECLOSURE PROCESS. AN ATTORNEY SHOULD BE CONSULTED TO HELP YOU UNDERSTAND THESE RIGHTS AND PROGRAMS AS A PART OF THE FORECLOSURE PROCESS.
AUDREY PATTERSON
Holder of said Mortgage
JIM H. FERNANDEZ
FERNANDEZ, CRANE & COMBS, L.L.C.
Attorneys for Holder of said Mortgage
Post Office Box 162
Mobile, Alabama 36601 / (251) 433-0738
Call News October 25, November 1 and November 8, 2023

NOTICE OF FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Richard Ashley Sanderson, a married man, to Mortgage Electronic Registration Systems, Inc., as Mortgagee, as nominee for Century Lending Company, its successors and assigns, on August 5, 2014, said mortgage being recorded in the Office of the Judge of Probate of Mobile County, Alabama, on August 14, 2014 at Book LR7177, at Page 1695, as Document Number 2014040932. Freedom Mortgage Corporation, the current holder, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Mobile County Courthouse, in Mobile, Alabama, on November 16, 2023, during the legal hours of sale, the following described real estate, situated in Mobile County, Alabama, to-wit:
LOT 2, OAKLEIGH ESTATES, FIRST ADDITION, ACCORDING TO THE PLAT THEREOF RECORDED IN MAP BOOK 30, PAGE 2 OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA.
More commonly known as: 624 Oakview Dr, Saraland, AL 36571
This Property will be sold on as “as is, where is” basis, without warranty or recourse, expressed or implied as to title, use and/or enjoyment and will be sold subject to the right of redemption of all parties entitled thereto. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expense of foreclosure. The successful bidder must tender certified funds by noon the next business day to Law Office of Halliday, Watkins & Mann, P.C. Certified funds must be in the form of a wire transfer, bank or credit union’s cashier’s check, or bank official check payable to Halliday, Watkins & Mann, P.C. Halliday, Watkins & Mann, P.C. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. If sale is voided, Mortgagee/Transferee shall return the bid amount to the successful purchaser and the Mortgagee/Transferee shall not be liable to the purchase for any damages. If the sale is set aside for any reason, the purchaser at the sale shall be only entitled to a return of the deposit and bid amount, if paid. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit is purchase price against the expenses of sale and indebtedness secured by the real estate. This sale is subject to postponement or cancellation.
Freedom Mortgage Corporation (“Transferee”)
Halliday, Watkins & Mann, P.C.
244 Inverness Center Drive
Birmingham, AL 35242
Phone: (801) 355-2886
Call News October 18, 2023, October 25, 2023, November 1, 2023

NOTICE OF FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Steven J. Boyd and Amy J. Boyd, husband and wife, as joint tenants with right of survivorship, to Mortgage Electronic Registration Systems, Inc., as Mortgagee, as nominee for Freedom Mortgage Corporation, its successors and assigns, on January 20, 2022, said mortgage being recorded in the Office of the Judge of Probate of Mobile County, Alabama, on January 28, 2022, as Document Number 2022007040. Freedom Mortgage Corporation, the current holder, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Mobile County Courthouse, in Mobile, Alabama, on November 16, 2023, during the legal hours of sale, the following described real estate, situated in Mobile County, Alabama, to-wit:
LOT 20, YOUNGSTOWNE HILL, ACCORDING TO PLAT THEREOF RECORDED IN MAP BOOK 102, PAGE 66 OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE OF MOBILE COUNTY, ALABAMA.
More commonly known as: 2075 Jonah Ct, Semmes, AL 36575
This Property will be sold on as “as is, where is” basis, without warranty or recourse, expressed or implied as to title, use and/or enjoyment and will be sold subject to the right of redemption of all parties entitled thereto. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expense of foreclosure. The successful bidder must tender certified funds by noon the next business day to Law Office of Halliday, Watkins & Mann, P.C. Certified funds must be in the form of a wire transfer, bank or credit union’s cashier’s check, or bank official check payable to Halliday, Watkins & Mann, P.C. Halliday, Watkins & Mann, P.C. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. If sale is voided, Mortgagee/Transferee shall return the bid amount to the successful purchaser and the Mortgagee/Transferee shall not be liable to the purchase for any damages. If the sale is set aside for any reason, the purchaser at the sale shall be only entitled to a return of the deposit and bid amount, if paid. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit is purchase price against the expenses of sale and indebtedness secured by the real estate. This sale is subject to postponement or cancellation.
Freedom Mortgage Corporation (“Transferee”)
Halliday, Watkins & Mann, P.C.
244 Inverness Center Drive
Birmingham, AL 35242
Phone: (801) 355-2886
Call News October 18, 2023, October 25, 2023, November 1, 2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Kenneth O. McLaughlin and Stephanie B. McLaughlin, husband and wife, originally in favor of Mortgage Electronic Registration Systems, Inc., acting solely as nominee for PrimeLending, a Plainscapital Company, on August 20, 2010, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 6693 Page 99; as re-recorded in Book 6716 Page 402; with loan modification agreement(s) recorded in BK: LR7172 Page 84 and Instrument Number 2022028481; the undersigned Wells Fargo Bank, N.A., as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on December 7, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 12, The Legacy at Saybrook, Unit One, according to plat thereof recorded in Map Book 121, Page 43, of the records in the Office of the Judge of Probate of Mobile County, Alabama.. Property street address for informational purposes: 3842 Dwight Court , Mobile, AL 36619-1272. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Wells Fargo Bank, N.A., (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-40501
Call News 10/18/2023, 10/25/2023, 11/01/2023

FORECLOSURE NOTICE
Default having been made in the payment of the indebtedness described in and secured by that certain vendor’s lien deed conveyed from MARGARITA NEAL and MARIA AURELIA GALVAN to MARIA FRANCISCA GASPAR MIGUEL and EMILIO RAYMUNDO DIEGO, recorded in Mobile County, AL Probate Ct. records Instrument No. 2023023208, said default continuing notice is hereby given that the undersigned will, under and by virtue of the power of sale contained in said vendor’s lien deed, sell at public outcry for cash to the highest bidder at 12:00 noon on Nov. 15, 2023, at the front door of the Mobile County Courthouse the following described property to wit:
Lot 42 GREENLAWN SUB MBK 9 P 212 #SEC 31 T3S R2W #MP23 09 31 2 000 of the records in the Office of the Judge of Probate Court, Mobile County, AL. The property address is 2416 Alta Fescue Dr., Semmes, AL 36575.
Alabama Law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as part of the foreclosure process.
Said sale will be made for the purpose of paying said indebtedness and expenses incident to said sale, including a reasonable attorney’s fee.
CLIFFORD C. SHARPE
Attorney for Lienholder
307 Morgan Ave.
Mobile, AL 36606
Call News on Oct. 25, Nov. 1, 8, 2023

NOTICE OF
MORTGAGE FORECLOSURE SALE
STATE OF ALABAMA
COUNTY OF MOBILE
Default having been made of the terms of the loan documents secured by that certain mortgage executed by Mary Denaro And Emanuel C Denaro Wife And Husband to Option One Mortgage Corporation dated June 24, 2005; said mortgage being recorded on June 30, 2005, in Book 5803, Page 723 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to U.S. Bank, National Association, as Indenture Trustee on behalf of the holders of the Terwin Mortgage Trust 2005-11, Asset-Backed Securities, TMTS Series 2005-11 in Instrument 2023055249 in the Office of the Judge of Probate of Mobile County, ALABAMA.
The undersigned, U.S. Bank, National Association, as Indenture Trustee on behalf of the holders of the Terwin Mortgage Trust 2005-11, Asset-Backed Securities, TMTS Series 2005-11under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 16th day of November, 2023 the following property, situated in Mobile County, Alabama, to-wit:
Lot 4, Camelot Subdivision, according to plat thereof recorded in Map Book 20, Page 3 of the records in the Office of the Judge of Probate, Mobile County, Alabama.
Said property is commonly known as 307 Camelot Dr, Saraland, AL 36571.
Should a conflict arise between the property address and the legal description the legal description will control.
Said property will be sold subject to any outstanding ad valorem taxes (including taxes which are a lien, but not yet due and payable), the right of redemption of any taxing authority, all outstanding liens for public utilities which constitute liens upon the property, any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, easements, rights-of-way, zoning ordinances, restrictions, special assessments, covenants, the statutory right of redemption pursuant to Alabama law, and any matters of record including, but not limited to, those superior to said Mortgage first set out above. Said property will be sold on an “as-is” basis without any representation, warranty or recourse against the above-named or the undersigned. The successful bidder must present certified funds in the amount of the winning bid at the time and place of sale.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The sale will be conducted subject (1) to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and (2) to final confirmation and audit of the status of the loan with the holder of the Mortgage.
U.S. BANK, NATIONAL ASSOCIATION, AS INDENTURE TRUSTEE ON BEHALF OF THE HOLDERS OF THE TERWIN MORTGAGE TRUST 2005-11, ASSET-BACKED SECURITIES, TMTS SERIES 2005-11
as holder of said mortgage
McCalla Raymer Leibert Pierce, LLC
Two North Twentieth
2 20th Street North, Suite 1000
Birmingham, AL 35203
(205) 216-4238
FT21@mccalla.com
File No. 23-04986AL
www.foreclosurehotline.net
Call News 10/18/2023,10/25/2023,11/01/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Jonathan Leland Polite to Mortgage Electronic Registration Systems, Inc., as nominee for Village Capital and Investment LLC, dated September 20, 2021 said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Instrument Number 2021064873. Said mortgage was subsequently sold, assigned and transferred to Planet Home Lending, LLC. Under and by virtue of the power of sale contained in said mortgage, the undersigned, Planet Home Lending, LLC, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse in Mobile County, Alabama on November 9, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following describe real estate situated in Mobile County, Alabama, to-wit: LOT #14 SILVER ACRES, UNIT II PHASE II AS SHOWN IN MAP BOOK 106, PAGE 28 AS RECORDED IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA. Property Street Address for Informational Purposes: 9571 Hwy 45 Chunchula AL 36521 Said property will be sold “AS IS”. NO REPRESENTATION OR WARRANTY, EXPRESSED OR IMPLIED, IS MADE AS TO THE TITLE OF SAID PROPERTY. Said property is subject to any title deficiencies including but not limited to: any outstanding ad valorem taxes – including taxes which are a lien but not yet due and payable, federal tax liens any matters which might be disclosed by an accurate survey and inspection of the property, any assessments liens, encumbrances, zoning ordinances, restrictions, covenants, and matters of record superior to the Mortgage first set out above. Said property will be sold subject to the right of redemption of all parties entitled thereto. The highest bidder must tender the total amount of the winning bid in certified funds at the time and place of sale. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand the rights and programs as a part of the foreclosure process. This sale will be made for the purpose of paying the same and all expenses of this sale, as provided in said Mortgage and by Alabama law. This sale is subject to postponement or cancellation. **This is an attempt to collect a debt and any information obtained may be used for that purpose.** Planet Home Lending, LLC, Mortgagee or Transferee Jonathan Smothers, Esq ALAW One Independence Plaza, Suite 416 Birmingham, AL 35209 Attorney for Mortgagee/Transferee 23-008614 A-4796214
Call News 10/18/2023, 10/25/2023, 11/01/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Michael W Howell Jr aka Michael Howell, Jr, an unmarried man, originally in favor of Mortgage Electronic Registration Systems, Inc. as a nominee for Pacific Residential Mortgage, on September 24, 2021, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Instrument Number 2021064152; the undersigned PennyMac Loan Services, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 9, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 69, Woodside, Unit Two, according to the plat thereof recorded in Map Book 76, Page 63, of the records in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 6363 Woodside Dr S , Theodore, AL 36582. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. PennyMac Loan Services, LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-07125
Call News 10/18/2023, 10/25/2023, 11/01/2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Michael R. Payne, a married man joined by his wife Dee Ann Payne, originally in favor of Mortgage Electronic Registration Systems, Inc., acting solely as nominee for SMG Mortgage Group, on January 26, 2018, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in BK: LR7602 Pg: 1917; with Loan Modification Agreement recorded May 26, 2022 in Instrument Number 2022037152; the undersigned Allied First Bank, SB dba Servbank, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on November 9, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 62, Windgate Estates, according to plat thereof recorded in Map Book 28, Page 105, of the records in the Office of the Judge of Probate of Mobile County, Alabama.. Property street address for informational purposes: 1301 Repoll Rd , Mobile, AL 36695. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Allied First Bank, SB dba Servbank, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-06804
Call News 10/18/2023, 10/25/2023, 11/01/2023

MORTGAGE FORECLOSURE NOTICE
Default having been made in the terms of that certain Mortgage, executed on 06/29/2010, by Robert Davis, Jr. a/k/a Robert L. Davis, Jr., a married man, as Mortgagor, to MORTGAGE ELECTRONIC REGISTRATION SYSTEMS, INC AS A NOMINEE FOR HOMETOWN MORTGAGE SERVICES, INC. as Mortgagee, which said Mortgage is recorded in the Office of the Judge of Probate, Mobile County, Alabama, in Book 6672, Page 402 on 07/01/2010, and Modified in Instrument # 2020011166 recorded 2/26/2020 and Carrington Mortgage Services, LLC is currently the holder of the Mortgage, and underlying promissory note secured thereby, and Carrington Mortgage Services, LLC is authorized to enforce the terms of the Mortgage secured by said promissory note; and default having continued under the terms of said Mortgage, and by virtue of Alabama Code Section 35-10-3 and 35-10-2, the following described real property will be sold at public outcry, for cash, to the highest bidder, in front of the Courthouse door of said County, during the legal hours of sale, on 11/15/2023
LOT 66, HUNTERS COVE, UNIT ONE, PHASE TWO, ACCORDING TO PLAT THEREOF RECORDED IN MAP BOOK 116, PAGE 59, OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE OF MOBILE COUNTY, ALABAMA.
Subject to all easements, restrictions and reservations appearing of record. Said sale will also be made subject to any Federal Tax Liens and/or Special Assessments of any nature, if any, which might adversely affect the title to the property.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The property is being sold “as is, where is”. Said property is sold without warranty or recourse, expressed or implied as to title, use or enjoyment.
This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure.
This sale is subject to postponement or cancellation.
Kent D. McPhail
McPhail Sanchez, LLC
Attorney for Mortgagee/Transferee
126 Government Street
Mobile, AL 36602
251-438-2333
Call News 10/18/2023, 10/25/2023, 11/01/2023

NOTICE OF SALE UNDER POWER
FORECLOSURE NOTICE
WHEREAS, default has occurred in the performance of the covenants, terms and conditions of a mortgage from HANABLE SMITH JR, RHODA TAMERA DAVIS HUSBAND AND WIFE to MORTGAGE ELECTRONIC REGISTRATION SYSTEMS, INC., AS MORTGAGEE, AS NOMINEE FOR NEW SOUTH FEDERAL SAVINGS BANK, on the 19th day of February, 2007, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, on March 5, 2007, in Deed/Mortgage Book 6139, Page 1441, Mobile County, Alabama Records, said Mortgage having subsequently been transferred and assigned to Nationstar Mortgage LLC, by instrument recorded in the aforesaid Probate Office; notice is hereby given that the undersigned Nationstar Mortgage LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash at the main entrance to the Mobile county courthouse located at 205 Government Street, Mobile, AL 36652 in Mobile, Mobile County, Alabama, on December 13, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:
LOT 14, BLOCK 1, MARTIN PLACE, ACCORDING TO PLAT THEREOF RECORDED IN MAP BOOK 5, PAGE 141, OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA.
Said legal description being controlling, however the property is more commonly known as 1581 E MARTIN DR, MOBILE, AL 36605.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
This property will be sold on an “as is, where is” basis, subject to any easements, encumbrances, and exceptions reflected in the mortgage and those contained in the records of the Office of the Judge of Probate in the county where the above-described property is situated. This property will be sold subject to the right of redemption of all parties entitled thereto and subject to any outstanding ad valorem taxes (including taxes which are a lien, whether or not now due and payable). This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation.
Nationstar Mortgage LLC, Mortgagee/Transferee
THE BELOW LAW FIRM MAY BE HELD TO BE ACTING AS A DEBT COLLECTOR, UNDER FEDERAL LAW. IF SO, ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
Rubin Lublin, LLC, Attorney for Mortgagee/Transferee
11 N. Water Street, Suite 10290, Mobile, AL 36602
Telephone Number: (877) 813-0992 Case No. NAT-23-04545-1
rlselaw.com/property-listing
Call News 10/18/2023, 10/25/2023, 11/01/2023

FORECLOSURE NOTICE
Default having been made in the payment of the indebtedness described in and secured by that certain Mortgage executed by ELIJAH HOUSE, INC. dated September 30, 2020 and recorded as Instrument No. 2020060909 Probate Records of Mobile County, Alabama to Thames, Jackson, Harris Company, Inc.; said Mortgage was thereafter assigned to Curtis Wilson, Jr. by instrument dated October 6, 2020 and recorded as Instrument No. 2020061559 of the aforesaid Probate Court Records; and the undersigned holder of said mortgage having declared the entire indebtedness due and payable notice is hereby given that the undersigned, under and by virtue of the powers contained in said mortgage, will sell at public outcry for cash to the highest bidder during the legal hours of sale on the 6th day of NOVEMBER, 2023, at the front or main door of the Government Street entrance of Government Plaza, the Courthouse of Mobile County Alabama, , the following described real property lying and being situated in the County of Mobile, State of Alabama, to-wit:
PARCEL A
Lots 23, 24, 25 and 26, Houston Street, Second Extension, according to plat thereof recorded in Map Book 3, Page 477 of the records in the Office of the Judge of Probate of Mobile County, Alabama.
PARCEL B
Lot 1, Elijah House Subdivision, according to plat thereof recorded in Map Book 121, Page 45 of the records in the Office of the Judge of Probate, Mobile County, Alabama.
Said sale is made for the purpose of paying the indebtedness secured by said Mortgage and all charges as provided therein and the expense incident thereto, including a reasonable attorney’s fee.
Said property will be sold on an “as is, where is” basis subject to any easements, encumbrances, and exceptions contained in said mortgage and those contained in the records of the Office of the Judge of Probate where the above-described property is situated. Said property will be sold without warranty or recourse, expressed or implied as to title, use and/or enjoyment, and will be sold subject to the right of redemption of all parties entitled thereto.
ALABAMA LAW GIVES SOME PERSONS WHO HAVE AN INTEREST IN PROPERTY THE RIGHT TO REDEEM THE PROPERTY UNDER CERTAIN CIRCUMSTANCES. PROGRAMS MAY ALSO EXIST THAT HELP PERSONS AVOID OR DELAY THE FORECLOSURE PROCESS. AN ATTORNEY SHOULD BE CONSULTED TO HELP YOU UNDERSTAND THESE RIGHTS AND PROGRAMS AS A PART OF THE FORECLOSURE PROCESS.
CURTIS WILSON, JR.
Holder of said Mortgage
JIM H. FERNANDEZ
FERNANDEZ, CRANE & COMBS, L.L.C.
Attorneys for Holder of said Mortgage
Post Office Box 162
Mobile, Alabama 36601 / (251) 433-0738
Call News October 18, 2023, October 25, 2023 and November 1, 2023

FORECLOSURE NOTICE
Default having been made in the payment of the indebtedness described in and secured by that certain mortgage executed by PEARIS F. HOWARD aka PEARIS FITZGERALD HOWARD aka PEARIS HOWARD, an unmarried man, as Mortgagor(s) to Regions Bank, as Mortgagee, dated the 21st day of January, 2021, and recorded in Instrument No. 2021006742 et seq. of the records in the Office of the Judge of Probate Court of Mobile County, Alabama; said default continuing, notice is hereby given that the undersigned will, under and by virtue of the power of sale contained in said mortgage sell at public outcry for cash to the highest bidder during legal hours of sale, on the 7th day of November, 2023, in the city of Mobile, at the front door of the Court House of Mobile County, Alabama, the following described real property situated in the County of Mobile, State of Alabama, to-wit:
THE FOLLOWING LANDS AND PROPERTY, TOGETHER WITH ALL IMPROVEMENTS LOCATED THEREON. LYING IN MOBILE COUNTY. AL TO WIT: LOT 22SPICE POND PINES, UNIT ONE, ACCORDING TO THE PLAT THEREOF RECORDED IN MAP BOOK 56, PAGE 106 OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY. ALABAMA. SUBJECT TO: 1. BUILDING SETBACK LINE(S) AND EASEMENT(S) AS SHOWN ON RECORDED PLAT OF SUBDIVISION. 2. RESTRICTIVE COVENANTS CONTAINED IN INSTRUMENT(S) RECORDED IN REAL PROPERTY BOOK 4047 PAGE 492; REAL PROPERTY BOOK 4041, PAGE 1533 AND REAL PROPERTY BOOK 4253 PAGE 329(BUT OMITTING ANY COVENANT OR RESTRICTION BASED ON RACE, COLOR, RELIGION, SEX, HANDICAP, FAMILIAL STATUS OR NATIONAL ORIGIN.) 3. 30 FOOT ALABAMA POWER COMPANY EASEMENT AS SHOWN ON RECORDED PLAT OF SAID SUBDIVISION. 4. RESERVATION(S) OF OIL, GAS AND MINERALS CONTAINED IN INSTRUMENT(S) RECORDED IN REAL PROPERTY BOOK 4047, PAGE 492; REAL PROPERTY BOOK 4253. PAGE 329 AND REAL PROPERTY BOOK 512. PAGE 146. 5. EASEMENT(S) GRANTED ALABAMA POWER COMPANY BY INSTRUMENT(S) RECORDED IN DEED BOOK 557, PAGE 321 AND REAL PROPERTY BOOK 650PAGE 692. 6. CONVEYANCE OF OIL, GAS AND MINERALS RECORDED IN REAL PROPERTY BOOK 3225 PAGE 825: REAL PROPERTY BOOK 3225, PAGE 827 AND REAL PROPERTY BOOK 1427, PAGE 911. 7. OIL, GAS AND MINERAL LEASE(S) RECORDED IN REAL PROPERTY BOOK 3224 PAGE 180. 8. RIGHT(S) OF WAY GRANTED MOBILE COUNTY BY INSTRUMENT(S) RECORDED IN REAL PROPERTY BOOK 3680. PAGE 316 AND REAL PROPERTY BOOK 3680, PAGE 318. 9. TERMS. CONDITIONS. OBLIGATIONS AND REQUIREMENTS SET FORTH IN THE ARTICLES OF INCORPORATION OF SPICE POND PINES PROPERTY OWNERS ASSOCIATION RECORDED IN REAL PROPERTY BOOK 4041 PAGE 1503. AND RULES AND REGULATIONS CURRENTLY EXISTING OR WHICH MAY BE IMPOSED FROM TIME TO TIME BY SAID ASSOCIATION THIS BEING THE SAME PROPERTY CONVEYED TO PEARIS F. HOWARD DATED 04/10/2002 AND RECORDED ON 04/12/2002 IN BOOK 5145, PAGE 1143. IN THE MOBILE COUNTY RECORDERS OFFICE. PARCEL NO18 09 310 000 010.022.
This property will be sold on an “as is, where is” basis, subject to any easements, encumbrances, reservations and exceptions reflected in the mortgage and/or those contained in the records of the office of the Judge of Probate of the county where the above-described property is situated. This property will be sold without warranty or recourse, expressed or implied as to title, use and/or enjoyment and will be sold subject to the right of redemption of all parties entitled thereto. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
Said sale will be made for the purpose of paying said indebtedness and the expenses incident to this sale, including a reasonable attorney’s fee, and the other purposes set out in said mortgage. The sale will be conducted subject to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and also to final confirmation and audit of the status of the loan with the Mortgagee.
REGIONS BANK
Holder of said Mortgage
Goodman G. Ledyard
PIERCE LEDYARD JOHNSTON, P.C.
Attorneys for Mortgagee
Post Office Box 161389
Mobile, Alabama 36616
(251) 338-1300
Call News October 11, 18, 25 and November 1, 2023

NOTICE OF SALE UNDER POWER
FORECLOSURE NOTICE
WHEREAS, default has occurred in the performance of the covenants, terms and conditions of a mortgage from LYNN WORKMAN AKA LYNN K. WORKMAN, AN UNMARRIED WOMAN to Mortgage Electronic Registrations Systems, Inc., as Mortgagee, as Nominee for Hometown Lenders Inc. , on the 4th day of May, 2018, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, on May 25, 2018, in Deed/Mortgage Book LR7639, Page 1738, Mobile County, Alabama Records, said Mortgage having subsequently been transferred and assigned to Planet Home Lending, LLC, by instrument recorded in the aforesaid Probate Office; notice is hereby given that the undersigned Planet Home Lending, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash at the main entrance to the Mobile county courthouse located at 205 Government Street, Mobile, AL 36652 in Mobile, Mobile County, Alabama, on November 15, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:
BEGIN AT THE SOUTHWEST CORNER OF THE NORTH HALF OF THE SOUTH HALF OF THE NORTHWEST QUARTER OF THE SOUTHEAST QUARTER OF SECTION 26, TOWNSHIP 6 SOUTH; RANGE 3 WEST; RUN THENCE NORTH 138 FEET TO A POINT; RUN THENCE EAST 225 FEET TO A POINT; RUN THENCE SOUTH 138 FEET TO A POINT; RUN THENCE WEST 225 FEET TO THE POINT OF BEGINNING.
Said legal description being controlling, however the property is more commonly known as 9561 BEVERLY RD, IRVINGTON, AL 36544.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
This property will be sold on an “as is, where is” basis, subject to any easements, encumbrances, and exceptions reflected in the mortgage and those contained in the records of the Office of the Judge of Probate in the county where the above-described property is situated. This property will be sold subject to the right of redemption of all parties entitled thereto and subject to any outstanding ad valorem taxes (including taxes which are a lien, whether or not now due and payable). This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation.
Planet Home Lending, LLC, Mortgagee/Transferee
THE BELOW LAW FIRM MAY BE HELD TO BE ACTING AS A DEBT COLLECTOR, UNDER FEDERAL LAW. IF SO, ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
Rubin Lublin, LLC, Attorney for Mortgagee/Transferee
11 N. Water Street, Suite 10290, Mobile, AL 36602
Telephone Number: (877) 813-0992 Case No. PHL-23-04092-1
rlselaw.com/property-listing
Call News 10/18/2023, 10/25/2023, 11/01/2023

POSTPONEMENT
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by James L. Busby, Jr., a married man, originally in favor of Mortgage Electronic Registration Systems, Inc., solely as nominee for GMFS, LLC, on November 19, 2015, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book LR7325 Page 819 and being modified in Book LR7598 Page 987; the undersigned MidFirst Bank, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on October 26, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Parcel A Lots 6 and 7, Block 43 in Belle-Fontaine Beach Subdivision as per plat thereof recorded in Deed Book 156, Page 490-493 of the Records in the Office of the Judge of Probate of Mobile County, Alabama Parcel B Lots I, 2, 3, 4, 5, 8, 9, 10, 11, 12, 13, 14, 15, 16, 17, 18, 19, 20, 21, 22, and 23 in Block 43 in Belle-Fontaine Beach Subdivision as per plat thereof recorded in Deed Book 156, Page 409-493 of the Records in the Office of the Judge of Probate of Mobile County, Alabama. Property street address for informational purposes: 9885 East Avenue , Theodore, AL 36582. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. The above mortgage foreclosure sale has been postponed from October 26, 2023 until November 30, 2023, during the legal hours of sale in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama. MidFirst Bank, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-05880
Call News August 30, 2023, September 6, 2023, September 13, 2023, November 1, 2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Manuel F Vargas-Machuca aka Manuel Fernando Vargas-Machuca and Lori Vargas, husband and wife, originally in favor of Mortgage Electronic Registration Systems, Inc. solely as nominee for PrimeLending, A Plainscapital Company, on August 27, 2018, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book LR7677 Page 1369; the undersigned Lakeview Loan Servicing, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on September 14, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 25, Scott Plantation, Unit 6, revised plat, according to plat thereof recorded in Map Book 108, Page 124 and revised in Map Book 111, Page 5 of the records in the Office of the Judge of Probate of Mobile County, Alabama.. Property street address for informational purposes: 3025 Dairy Ct , Mobile, AL 36695. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. The above mortgage foreclosure sale has been postponed from September 14, 2023 until October 19, 2023, during the legal hours of sale in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama. The above mortgage foreclosure sale has been postponed from October 19, 2023 until November 20, 2023, during the legal hours of sale in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama. Lakeview Loan Servicing, LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-04196
Call News August 9, 2023, August 16, 2023, August 23, 2023, September 20, 2023, November 1, 2023

MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Mattie W. Rander joined by her husband, Walter J. Rander a/k/a Walter James Rander, originally in favor of Freedom Mortgage Corporation, on January 14, 1994, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 4131 Page 1872 and modified in Book 6110 Page 278; the undersigned Wells Fargo Bank, N.A., as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on March 16, 2023, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 5, Carsten Court, according to the Plat thereof recorded in Map Book 18, Page 88, and revised in Map Book 18, Page 111, of the records in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 2000 Carstens Ct , Mobile, AL 36617. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. The above mortgage foreclosure sale has been postponed from March 16, 2023 until May 11, 2023, during the legal hours of sale in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama. The above mortgage foreclosure sale has been postponed from May 11, 2023 until July 13, 2023, during the legal hours of sale in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama. The above mortgage foreclosure sale has been postponed from July 13, 2023 until August 24, 2023, during the legal hours of sale in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama. The above mortgage foreclosure sale has been postponed from August 24, 2023 until October 19, 2023, during the legal hours of sale in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama. The above mortgage foreclosure sale has been postponed from October 19, 2023 until November 20, 2023, during the legal hours of sale in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama. Wells Fargo Bank, N.A., (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 22-40400
Call News January 25, 2023, February 1, 2023, February 8, 2023, March 22, 2023, May 17, 2023, July 19, 2023, August 30, 2023, November 1, 2023

CONTINUATION OF MORTGAGE
FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed to Mortgage Electronic Registration Systems Inc., as nominee for Nationstar Mortgage LLC d/b/a Mr. Cooper on April 1, 2019, by Samuel D. Rollins, single, and recorded and secured indebtedness having been transferred MidFirst Bank. LOGS Legal Group LLP, as counsel for the Mortgagee or Transferee, under and by virtue of the power of sale contained in the said mortgage will sell at public outcry to the highest bidder for cash in front of the main entrance of the Mobile County, Alabama, Courthouse in the City of Mobile, Mobile County, Alabama, on the October 19, 2023, during the legal hours of sale the following real estate situated in Mobile County, Alabama, to wit:
Lot 83 of Winchester Subdivision, Unit Two, according to the Plat thereof recorded in Map Book 121, Page 96 of the records in the Office of the Judge of Probate of Mobile County, Alabama.
Notice of this foreclosure sale may also be provided to the following parties if applicable, who may have some interest in said property, in order that they might avail themselves of the opportunity to bid at said foreclosure sale: Internal Revenue Service and Secretary of Housing and Urban Development, 451 Seventh St Southwest, Washington, DC 20410 and Midland Credit Management, Inc., PO Box 11366, Birmingham, AL 35202.
For informational purposes only, the property address is: 9814 Winchester Cir S, Semmes, AL 36575. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. Five Thousand Dollars and no/100 ($5,000.00) must be tendered in certified funds at the time and place of the sale by the purchaser as a non-refundable deposit. The balance of the purchase price must be paid in certified funds within 24 HOURS thereafter at the law offices of LOGS Legal Group LLP, 1878 Jeff Rd. NW, Suite “I”, Huntsville, AL 35806, (704) 333-8107. LOGS Legal Group LLP reserves the right to award the bid to the next highest bidder, or to reschedule the sale, should the highest bidder fail to timely tender the total amount due.
MidFirst Bank, and its successors and assigns
Mortgagee or Transferee
LOGS LEGAL GROUP LLP
1878 Jeff Rd. NW, Suite “I”
Huntsville, AL 35806
(704) 333-8107/21-020933
Attorneys for Mortgagee or Transferee
Call News Run ad: on July 26, 2023 and August 2, 2023 and August 9, 2023.

The public sale provided for hereinabove was postponed on October 19, 2023, by public announcement being made at the main entrance of the Mobile County Courthouse, Mobile, Alabama, during the legal hours of sale. The foreclosure sale described hereinabove shall be held on the November 20, 2023, at the main entrance of the Mobile County Courthouse, Mobile, Alabama, during the legal hours of sale.
Call News 11/01/2023

NOTICE OF SALE UNDER POWER
FORECLOSURE NOTICE
WHEREAS, default has occurred in the performance of the covenants, terms and conditions of a mortgage from BRITTNEY A JEFFERSON, SINGLE WOMAN to MORTGAGE ELECTRONIC REGISTRATION SYSTEMS, INC., AS MORTGAGEE, AS NOMINEE FOR MORTGAGE RESEARCH CENTER, LLC DBA VETERANS UNITED HOME LOANS, on the 30th day of April, 2020, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, on May 4, 2020, at Instrument Number 2020026045, Mobile County, Alabama Records, said Mortgage having subsequently been transferred and assigned to Mortgage Research Center, LLC d/b/a Veterans United Home Loans, a Missouri Limited Liability Company, by instrument recorded in the aforesaid Probate Office; notice is hereby given that the undersigned Mortgage Research Center, LLC d/b/a Veterans United Home Loans, a Missouri Limited Liability Company, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash at the main entrance to the Mobile county courthouse located at 205 Government Street, Mobile, AL 36652 in Mobile, Mobile County, Alabama, on December 13, 2023, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:
LOT 37, TIMBERLANE, UNIT THREE, AS RECORDED IN MAP BOOK 21, PAGE 54, OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE OF MOBILE COUNTY, ALABAMA.
Said legal description being controlling, however the property is more commonly known as 2900 LONGLEAF DR, MOBILE, AL 36693.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
This property will be sold on an “as is, where is” basis, subject to any easements, encumbrances, and exceptions reflected in the mortgage and those contained in the records of the Office of the Judge of Probate in the county where the above-described property is situated. This property will be sold subject to the right of redemption of all parties entitled thereto and subject to any outstanding ad valorem taxes (including taxes which are a lien, whether or not now due and payable). This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation.
Mortgage Research Center, LLC d/b/a Veterans United Home Loans, a Missouri Limited Liability Company, Mortgagee/Transferee
THE BELOW LAW FIRM MAY BE HELD TO BE ACTING AS A DEBT COLLECTOR, UNDER FEDERAL LAW. IF SO, ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
Rubin Lublin, LLC, Attorney for Mortgagee/Transferee
11 N. Water Street, Suite 10290, Mobile, AL 36602
Telephone Number: (877) 813-0992 Case No. NAT-23-03049-2
The sale provided for hereinabove which was originally scheduled for October 18, 2023, was postponed until December 13, 2023. by public announcement being made at the Mobile County Courthouse, Mobile, Alabama, during the legal hours of sale. Said foreclosure sale shall be held on the 13th day of December, 2023, at the Mobile County Courthouse, Mobile, Alabama, during the legal hours of sale.
rlselaw.com/property-listing
Call News 09/20/2023, 09/27/2023, 10/04/2023, 11/01/2023

Estate Administration
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of GREGORY TODD WILLIS SR
Case No. 2023-0636
Take notice that Letters of Administration have been granted to the below named party on the 25th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANTHONY M. HOFFMAN, as Administrator of the estate of GREGORY TODD WILLIS SR, Deceased
Attorney of Record:
ANTHONY HOFFMAN, ESQ.
Call News November 1, 8, 15, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of FANNIE D. WADE
Case No. 2023-1723
Take notice that Letters Testamentary have been granted to the below named party on the 25th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
NATALIE WADE and MELODY WADE as Co-Executrices of the estate of FANNIE D. WADE, deceased
Attorney of Record:
ANTHONY M. HOFFMAN
Call News November 1, 8, 15, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JEFFREY MARK VAUGHN, Deceased
Case No. 2023-2017
Take notice that Letters Testamentary have been granted to the below named party on the 26th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
NANCY SMITH HOLLY as Executrix under the last will and testament of JEFFREY MARK VAUGHN, Deceased
Attorney of Record:
JASON HADLEY
Call News November 1, 8, 15, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF MOBILE COUNTY, ALABAMA
Estate of EMMA L. SPROUSE, Deceased
Case No. 2023-1015
Take notice that Letters Testamentary have been granted to the below named party on the 25th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
SHARON TAYLOR as Executrix under the last will and testament of EMMA L. SPROUSE, Deceased
Attorney of Record:
DANIEL G SAYERS
Call News November 1, 8, 15, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of WILLIE ALEXANDER SIMMS
Case No. 2023-1640
Take notice that Letters of Administration have been granted to the below named party on the 20th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANGELIA SIMMS as Administratrix of the estate of WILLIE ALEXANDER SIMMS, deceased
Attorney of Record:
ROBERT M. GALLOWAY, Esq.
Call News November 1, 8, 15, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of MYRTIS H. SCOTT AKA MYRTIS MARIE SCOTT, Deceased
Case No. 2023-1398
Take notice that Letters Testamentary have been granted to the below named parties on the 25th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
BRENDA KRANKE and JOANN MEADOWS as Co-Executrices under the last will and testament of MYRTIS H. SCOTT AKA MYRTIS MARIE SCOTT, Deceased
Attorney of Record:
BRENDA KRANKE AND JOANN MEADOWS, PRO SE
Call News November 1, 8, 15, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of DIXIE PLUMB
Case No. 2023-1960
Take notice that Letters of Administration have been granted to the below named party on the 20th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANTHONY M. HOFFMAN, as Administrator of the estate of DIXIE PLUMB, Deceased
Attorney of Record:
ANTHONY M. HOFFMAN
Call News November 1, 8, 15, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of LORI ANNE PHILLIPS
Case No. 2023-1963
Take notice that Letters of Administration have been granted to the below named party on the 25th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANTHONY M. HOFFMAN, as Administrator of the estate of LORI ANNE PHILLIPS, Deceased
Attorney of Record:
ANTHONY M. HOFFMAN
Call News November 1, 8, 15, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of MADELINE F. NELSON
Case No. 2023-1973
Take notice that Letters of Administration have been granted to the below named party on the 25th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
KARL ANTHONY GILLAN as Administrator of the estate of MADELINE F. NELSON, deceased
Attorney of Record:
CREOLA G. RUFFIN, Esq.
Call News November 1, 8, 15, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of PATRICIA A. HOLMES, Deceased
Case No. 2023-1718
Take notice that Letters Testamentary have been granted to the below named party on the 25th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
RHETTA MINGO as Executrix under the last will and testament of PATRICIA A. HOLMES, Deceased
Attorney of Record:
LUE E SULLIVAN SR
Call News November 1, 8, 15, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of LOUCRETIA ILER HOLLINGSWORTH, Deceased
Case No. 2023-2056
Take notice that Letters Testamentary have been granted to the below named party on the 25th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
DEBORRA HOLLINGSWORTH OUTLAW as Executrix under the last will and testament of LOUCRETIA ILER HOLLINGSWORTH, Deceased
Attorney of Record:
GILBERT DUKES III
Call News November 1, 8, 15, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of LLOYD T FORMBY
Case No. 2023-1922
Take notice that Letters of Administration have been granted to the below named party on the 25th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
REBEKAH FORMBY as Administratrix of the estate of LLOYD T FORMBY, deceased
Attorney of Record:
ROSE ANNA MCPHILLIPS, Esq.
Call News November 1, 8, 15, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of ANNE P. COWART, Deceased
Case No. 2023-2058
Take notice that Letters Testamentary have been granted to the below named party on the 25th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
MICHAEL R. COWART as Executor under the last will and testament of ANNE P. COWART, Deceased
Attorney of Record:
DUANE A. GRAHAM
Call News November 1, 8, 15, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of CLAUDETTE DOWLING CONINE
Case No. 2023-1500
Take notice that Letters Testamentary have been granted to the below named party on the 25th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
JOAN RENEE HUDSON as Executrix of the estate of CLAUDETTE DOWLING CONINE, deceased
Attorney of Record:
ANDREW M. JONES
Call News November 1, 8, 15, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of CLEO LOUIS CHARLEY, JR. AKA CLEO L. CHARLEY, JR., Deceased
Case No. 2023-1208
Take notice that Letters Testamentary have been granted to the below named party on the 25th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
CLAUDE CLIFFORD CHARLEY as Executor under the last will and testament of CLEO LOUIS CHARLEY, JR. AKA CLEO L. CHARLEY, JR., Deceased
Attorney of Record:
DAVID L RATCLIFFE
Call News November 1, 8, 15, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of QUITMAN DAVID BYRD, Deceased
Case No. 2023-1737
Take notice that Letters Testamentary have been granted to the below named party on the 25th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
SANDRA B SUMLIN as Executrix under the last will and testament of QUITMAN DAVID BYRD, Deceased
Attorney of Record:
JOSHUA P MYRICK
Call News November 1, 8, 15, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of CARMEN AIDA BROWN-BENDER, Deceased
Case No. 2023-1265
Take notice that Letters Testamentary have been granted to the below named party on the 25th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
JULIE GREER HATCHER as Executrix under the last will and testament of CARMEN AIDA BROWN-BENDER, Deceased
Attorney of Record:
CREOLA G. RUFFIN
Call News November 1, 8, 15, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of MELBA MARIE WILLIAMS, Deceased
Case No. 2023-0848
Take notice that Letters Testamentary have been granted to the below named party on the 18th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
TAMMY WILLIAMS ERNEST as Executrix under the last will and testament of MELBA MARIE WILLIAMS, Deceased
Attorney of Record:
BARRY A. FRIEDMAN
Call News October 25 and November 1, 8, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of BETTY ANN BELL SHILS
Case No. 2023-1711
Take notice that Letters of Administration on the Annexed Will have been granted to the below named party on the 19th day of October, 2023, by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANTHONY M. HOFFMAN, as Administrator CTA under the last will and testament of BETTY ANN BELL SHILS, Deceased
Attorney of Record:
ANTHONY M. HOFFMAN
Call News October 25 and November 1, 8, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of KENNETH ROY RONE
Case No. 2023-1741
Take notice that Letters Testamentary have been granted to the below named party on the 18th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
LAURIE RONE MORGAN as Executrix of the estate of KENNETH ROY RONE, deceased
Attorney of Record:
JEFFREY SETTERSTROM
Call News October 25 and November 1, 8, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of EDNA LOUISE PUGH, Deceased
Case No. 2023-1379
Take notice that Letters Testamentary have been granted to the below named party on the 18th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANGELA DENISE JOHNSON as Executrix under the last will and testament of EDNA LOUISE PUGH, Deceased
Attorney of Record:
RICARDO A. WOODS
Call News October 25 and November 1, 8, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of J MANSON MURRAY, Deceased
Case No. 2023-2021
Take notice that Letters Testamentary have been granted to the below named parties on the 18th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
MARIETTA M. URQUHART and ANNE BLAKE M. BROOKS as Co-Executrices under the last will and testament of J MANSON MURRAY, Deceased
Attorney of Record:
THOMAS E SHARP, Ill, Esq.
JAMES F. WATKINS
Call News October 25 and November 1, 8, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of ROBERT EUGENE MCFALL JR, Deceased
Case No. 2023-2019
Take notice that Letters Testamentary have been granted to the below named party on the 18th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
TERESA ELAINE MCFALL COLVIN as Executrix under the last will and testament of ROBERT EUGENE MCFALL JR., Deceased
Attorney of Record:
J. ROBERT TURNIPSEED
Call News October 25 and November 1, 8, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of BRENDA WEST LOFTIN, Deceased
Case No. 2022-2439
Take notice that Letters of Administration on the Annexed Will have been granted to the below named party on the 27th day of September, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANTHONY M. HOFFMAN Administrator CTA under the last will and testament of BRENDA WEST LOFTIN, Deceased
Attorney of Record:
ANTHONY M. HOFFMAN
Call News October 25 and November 1, 8, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of SCOTT BRADLEY LINGERFELT, Deceased
Case No. 2023-1043
Take notice that Letters Testamentary have been granted to the below named party on the 19th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
AMY SUE LINGERFELT as Executrix under the last will and testament of SCOTT BRADLEY LINGERFELT, Deceased
Attorney of Record:
JASON HADLEY
Call News October 25 and November 1, 8, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of EDWARD T HOLMAN
Case No. 2023-1647
Take notice that Letters of Administration have been granted to the below named party on the 19th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
PATRICE ROBINSON as Administratrix of the estate of EDWARD T HOLMAN, deceased
Attorney of Record:
ROSE ANNA MCPHILLIPS, Esq.
Call News October 25 and November 1, 8, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of WAYNE HILL
Case No. 2023-1619
Take notice that Letters of Administration have been granted to the below named party on the 19th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
BRITNEY WELCH as Administratrix of the estate of WAYNE HILL, deceased
Attorney of Record:
JOHN M. LASSITER JR., Esq.
Call News October 25 and November 1, 8, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JAMES PAUL HANSON
Case No. 2023-1980
Take notice that Letters of Administration have been granted to the below named party on the 19th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
MADELYN COLLUM as Administratrix of the estate of JAMES PAUL HANSON, deceased
Attorney of Record:
CAMILLE R. FORD, Esq.
Call News October 25 and November 1, 8, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of PHILLIP WAYNE GARDNER, Deceased
Case No. 2023-2022
Take notice that Letters Testamentary have been granted to the below named party on the 18th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
GREGORY C. GARDNER as Executor under the last will and testament of PHILLIP WAYNE GARDNER, Deceased
Attorney of Record:
THERESA N. WILLIAMSON
Call News October 25 and November 1, 8, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of GENEVIEVE SAWYER DENMARK, Deceased
Case No. 2023-2020
Take notice that Letters Testamentary have been granted to the below named party on the 18th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
RICHARD A. DENMARK as Executor under the last will and testament of GENEVIEVE SAWYER DENMARK, Deceased
Attorney of Record:
WILLIAM S MCFADDEN
Call News October 25 and November 1, 8, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of CHARLES HENRY BURNO SR.
Case No. 2023-1280
Take notice that Letters of Administration have been granted to the below named party on the 4th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
PAULINE HARRIS BURNO as Administratrix of the estate of CHARLES HENRY BURNO SR., deceased
Attorney of Record:
FRANK H. KRUSE, Esq.
Call News October 25 and November 1, 8, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of PAMELA G BRADY
Case No. 2023-1705
Take notice that Letters of Administration have been granted to the below named party on the 19th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
MICHELLE SALISBURY as Administratrix of the estate of PAMELA G BRADY, deceased
Attorney of Record:
MICHAEL R HOLBERG, Esq.
Call News October 25 and November 1, 8, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of SHERRYL KAY ALLEN
Case No. 2023-1154
Take notice that Letters of Administration have been granted to the below named party on the 19th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
JIMMY M ALLEN JR as Administrator of the estate of SHERRYL KAY ALLEN, deceased
Attorney of Record:
MICHAEL T. MURPHY, Esq.
Call News October 25 and November 1, 8, 2023

NOTICE OF COURT PROCEEDING
October 19, 2023
Case No. 2023-1929
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of CHARLOTTE A STRICKLAND, Deceased
On to-wit the 11th day of December, 2023 at 9:30 AM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the PROBATE OF WILL as filed by MARSHA PLATT STILTNER. NOTICE is hereby given to all parties in interest, specifically UNKNOWN HEIRS AND NEXT OF KIN OF CHARLOTTE A. STRICKLAND, who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
RICHARD E. SHIELDS
507 CHURCH STREET
MOBILE, AL 36602
Call News October 25, and November 1, 8, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of RONNIE EUGENE WILLIAMS
Case No. 2023-1865
Take notice that Letters of Administration have been granted to the below named party on the 13th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
BOBBY DARNELL WILLIAMS as Administrator of the estate of RONNIE EUGENE WILLIAMS, deceased
Attorney of Record:
B. VAUGHN DRINKARD, JR, Esq.
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of NOREEN MCALLISTER VICKERS, Deceased
Case No. 2023-1970
Take notice that Letters Testamentary have been granted to the below named party on the 11th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
MICHAEL PATRICK VICKERS as Executor under the last will and testament of NOREEN MCALLISTER VICKERS, Deceased
Attorney of Record:
GILBERT DUKES III
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JOSEPH LOUIS TODD
Case No. 2023-1687
Take notice that Letters of Administration have been granted to the below named party on the 10th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ETHEL MAE TODD as Administratrix of the estate of JOSEPH LOUIS TODD, deceased
Attorney of Record:
JOHN A WENZEL, Esq.
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JACQUELINE L THERRELL, Deceased
Case No. 2023-1969
Take notice that Letters Testamentary have been granted to the below named party on the 11th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
JOHN W THERRELL JR as Executor under the last will and testament of JACQUELINE L THERRELL, Deceased
Attorney of Record:
R. NASH CAMPBELL
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of MARGARET MARIE SWEATT
Case No. 2023-1815
Take notice that Letters of Administration have been granted to the below named party on the 12th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
STACY NEWELL MURPHY as Administratrix of the estate of MARGARET MARIE SWEATT, deceased
Attorney of Record:
STEPHEN E. CLEMENTS, Esq.
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of TERRY LYNN SUMERLIN, Deceased
Case No. 2023-1930
Take notice that Letters Testamentary have been granted to the below named party on the 4th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
TERA COCHRAN as Executrix under the last will and testament of TERRY LYNN SUMERLIN, Deceased
Attorney of Record:
DANIEL G SAYERS
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of EMMA STANDRIDGE, Deceased
Case No. 2023-1864
Take notice that Letters Testamentary have been granted to the below named party on the 4th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
BARBARA BRELAND as Executrix under the last will and testament of EMMA STANDRIDGE, Deceased
Attorney of Record:
RICK A. LA TRACE
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JAMES REID SPIRES, Deceased
Case No. 2023-1873
Take notice that Letters Testamentary have been granted to the below named parties on the 4th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
JAMES L SPIRES and JAMES R SPIRES JR as Co-Executors under the last will and testament of JAMES REID SPIRES, Deceased
Attorney of Record:
SHIRLEY M JUSTICE
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of CHARLES DALE SMITH, Deceased
Case No. 2023-1460
Take notice that Letters Testamentary have been granted to the below named party on the 4th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
JAMIE JO SMITH as Executrix under the last will and testament of CHARLES DALE SMITH, Deceased
Attorney of Record:
PAGE STANLEY ELLIS
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of RONALD FRANKLIN SILVA, Deceased
Case No. 2023-1902
Take notice that Letters Testamentary have been granted to the below named party on the 11th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
BARBARA L. COPELAND as Executrix under the last will and testament of RONALD FRANKLIN SILVA, Deceased
Attorney of Record:
NEIL CHUNN JOHNSTON JR.
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of DAVID L. ROBERTS
Case No. 2023-1691
Take notice that Letters of Administration have been granted to the below named party on the 3rd day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANTHONY M. HOFFMAN, as Administrator of the estate of DAVID L. ROBERTS, Deceased
Attorney of Record:
ANTHONY M. HOFFMAN
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of ROBERT ORESTIES NEWELL
Case No. 2023-1621
Take notice that Letters of Administration have been granted to the below named party on the 2nd day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
SHARON NEWELL WOODHAM as Administratrix of the estate of ROBERT ORESTIES NEWELL, deceased
Attorney of Record:
PAGE STANLEY ELLIS, Esq.
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of MARIETTA MURRAY, Deceased
Case No. 2023-1927
Take notice that Letters Testamentary have been granted to the below named parties on the 4th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
MARIETTA M. URQUHART and ANNE BLAKE M. BROOKS as Co-Executrices under the last will and testament of MARIETTA MURRAY, Deceased
Attorney of Record:
THOMAS E SHARP, Ill, Esq.
JAMES F. WATKINS
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of ANNIE MAGEE, Deceased
Case No. 2023-1926
Take notice that Letters Testamentary have been granted to the below named party on the 4th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
RYAN ZOGHBY as Executor under the last will and testament of ANNIE MAGEE, Deceased
Attorney of Record:
RYAN ZOGHBY, PRO SE
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of RANDY DOUGLAS JONES
Case No. 2023-1546
Take notice that Letters of Administration have been granted to the below named party on the 2nd day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANTHONY M. HOFFMAN, as Administrator of the estate of RANDY DOUGLAS JONES, Deceased
Attorney of Record:
Anthony Hoffman, Esq.
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of EDWINA J. JOHNSON
Case No. 2023-1383
Take notice that Letters Testamentary have been granted to the below named party on the 4th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
FAYE LORAINE CURTIS as Executrix of the estate of EDWINA J. JOHNSON, deceased
Attorney of Record:
K. DONELSON FOOSE
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of DENISE ANN JOHNSON
Case No. 2023-0858
Take notice that Letters of Administration have been granted to the below named party on the 2nd day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANTHONY M. HOFFMAN, as Administrator of the estate of DENISE ANN JOHNSON, Deceased
Attorney of Record:
ANTHONY M. HOFFMAN
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of CURTIS WAYNE HITT
Case No. 2023-1771
Take notice that Letters of Administration have been granted to the below named party on the 11th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
MELISSA HITT-LATHAM as Administratrix of the estate of CURTIS WAYNE HITT, deceased
Attorney of Record:
WILLIAM T. MCGOWIN IV, Esq.
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of RICHARD NELSON HERRING
Case No. 2023-1608
Take notice that Letters of Administration have been granted to the below named party on the 2nd day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
PATRICE ANDERSON as Administratrix of the estate of RICHARD NELSON HERRING, deceased
Attorney of Record:
JOHN A WENZEL, Esq.
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of LATAWERENCE FINKLEY
Case No. 2023-1652
Take notice that Letters of Administration have been granted to the below named party on the 2nd day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
DELORES WELCH as Administratrix of the estate of LATAWERENCE FINKLEY, deceased
Attorney of Record:
LATONYA MINES, Esq.
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of DOUGLAS COOLEY SR
Case No. 2023-1543
Take notice that Letters of Administration have been granted to the below named party on the 2nd day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
DEZSJEUN Z COOLEY as Administrator of the estate of DOUGLAS COOLEY SR, deceased
Attorney of Record:
RICHARD E. SHIELDS, Esq.
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of RUTH ANN CLEMENT
Case No. 2023-1493
Take notice that Letters of Administration have been granted to the below named party on the 2nd day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANTHONY M. HOFFMAN, as Administrator of the estate of RUTH ANN CLEMENT, Deceased
Attorney of Record:
ANTHONY M. HOFFMAN
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JAMES N. CHRISTIANSEN, Deceased
Case No. 2023-1932
Take notice that Letters Testamentary have been granted to the below named party on the 4th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
JAMES N. CHRISTIANSEN JR. as Executor under the last will and testament of JAMES N. CHRISTIANSEN, Deceased
Attorney of Record:
DUANE A. GRAHAM
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of CAROL ALLENE GODBEE, Deceased
Case No. 2023-1931
Take notice that Letters Testamentary have been granted to the below named party on the 11th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
DONALD WAYNE BARNETT as Executor under the last will and testament of CAROL ALLENE GODBEE, Deceased
Attorney of Record:
GILBERT DUKES III
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of ETTA DRISKELL BROWN Deceased
Case No. 2023-1799
Take notice that Letters Testamentary have been granted to the below named party on the 4th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ROBERT DON BROWN as Executor under the last will and testament of ETTA DRISKELL BROWN, Deceased
Attorney of Record:
WILLIAM M. LYON JR.
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of WILLIAM MOORE BAYLEY JR, Deceased
Case No. 2023-1659
Take notice that Letters Testamentary have been granted to the below named party on the 4th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
MEISHA DIANE BAYLEY HANNAH as Executrix under the last will and testament of WILLIAM MOORE BAYLEY JR., Deceased
Attorney of Record:
L. DANIEL MIMS
Call News October 18, 25, and November 1, 2023

NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of RICHARD MICHAEL BARTON, Deceased
Case No. 2023-1802
Take notice that Letters Testamentary have been granted to the below named party on the 11th day of October, 2023 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
MARTHA ELLEN BARTON as Executrix under the last will and testament of RICHARD MICHAEL BARTON, Deceased
Attorney of Record:
BRITTEN LESLIE BRITT
Call News October 18, 25, and November 1, 2023

Court Proceeding
NOTICE OF COURT PROCEEDING
October 30, 2023
Case No. 2022-1161-3
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of KIMBERLY MCCALL, Deceased
On to-wit the 18th day of December, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT BY SURETY as filed by WESTERN SURETY COMPANY. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper
DON DAVIS, DAVIS, Judge of Probate
Attorney:
JAMES J. DUFFY III
P.O. BOX 1109
MOBILE, AL 36633
Call News November 1, 8, 15, 2023

NOTICE OF COURT PROCEEDING
October 27, 2023
Case No. 2021-0059-7
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of THEODORE FLETCHER FIKES, Deceased
On to-wit the 4th day of December, 2023 at 3:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Final Settlement as filed by JAMES LARRY FIKES. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney Name and Address:
RON PEARMAN
555-A IROQUOIS ST
CHICKASAW, AL 36611
Call News November 1, 8, 15, 2023

NOTICE OF COURT PROCEEDING
October 27, 2023
Case No. 2021-0998-7
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of TOWANDA RASHAY HOLCOMBE O’FIELD, Deceased
On to-wit the 11th day of December, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Sale of Real Property for the Payment of Debts as filed by ANTHONY M HOFFMAN. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
ANTHONY M. HOFFMAN
P. O. BOX 11
Mobile, AL 36601
Call News November 1, 8, 15, 2023

NOTICE OF COURT PROCEEDING
October 27, 2023
Case No. 2020-1588-3
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of WILLIAM THOMAS CARVER SR, Deceased
On to-wit the 11th day of December, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Sale of Real Property for the Payment of Debts as filed by ANTHONY M. HOFFMAN. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
ANTHONY M. HOFFMAN
P. O. BOX 11
Mobile, AL 36601
Call News November 1, 8, 15, 2023

NOTICE OF COURT PROCEEDING
October 27, 2023
Case No. 2021-0497-2
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JULIA (JUDY) I. NICHOLAS, Deceased
On to-wit the 11th day of December, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT BY FORMER PERSONAL REPRESENTATIVE as filed by JOE SMITH. NOTICE is hereby given to all parties in interest, specifically LISA BUSBY AKA ALESIA DENISE BUSBY, who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, DAVIS, Judge of Probate
Attorney
ANTHONY M. HOFFMAN
P. O. BOX 11
Mobile, AL 36601
Call News November 1, 8, 15, 2023

NOTICE OF COURT PROCEEDING
October 24, 2023
Case No. 2021-2057-4
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of WANDA LEE CRAMER, Deceased
On to-wit the 4th day of December, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Sale of Real Property as filed by MICHAEL G CRAMER. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
D. BRAD HARDIN
PO BOX 1613
DAPHNE, AL 36526
Call News November 1, 8, 15, 2023

NOTICE OF COURT PROCEEDING
October 26, 2023
Case No. 2022-0136-4
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of RAY PERRY STEELE, Deceased
On to-wit the 11th day of December, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Sale of Real Property for the Payment of Debts as filed by ANTHONY M HOFFMAN. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
ANTHONY M. HOFFMAN
P. O. BOX 11
Mobile, AL 36601
Call News November 1, 8, 15, 2023

NOTICE OF COURT PROCEEDING
CASE NO. 2023-1666
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Notice of the filing of Petition for Summary Distribution in the estate of Hellen Juanita Ballard, Deceased
Notice is hereby given that a Petition for Summary Distribution has been filed by Leslie R. Meek on August 30, 2023, and that 30 days after the notice of publication hereof and pursuant to law the Court shall be requested to enter an order directing summary distribution of the estate of said decedent.
Don Davis, Judge of Probate
Attorney:
James E. Robertson, Jr., Esq.
P. O. Box 446
Mobile, AL 36601
Call News November 1, 2023

NOTICE OF COURT PROCEEDING
CASE NO. 2023-1893
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Notice of the filing of Petition for Summary Distribution in the estate of Judy Williams, Deceased.
Notice is hereby given that a Petition for Summary Distribution has been filed by Phyllis Williams on September 20, 2023, and amended on October 2, 2023, and that 30 days after the notice of publication hereof and pursuant to law the Court shall be requested to enter an order directing summary distribution of the estate of said decedent.
Don Davis, Judge of Probate
Petitioner:
Phyllis Williams
2058 Victory Court
Mobile, AL 36606
Call News November 1, 2023

NOTICE OF COURT PROCEEDING
October 24, 2023
Case No. 2022-1633-1
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of WILLIAM RAYFORD GARRETT, Deceased
On to-wit the 4th day of December, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Sale of Real Property as filed by MARGARET CHERYL RHODES. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
RITA DANIELL
P. O. BOX 1248
FAIRHOPE, AL 36533
Call News November 1, 8, 15, 2023

NOTICE OF COURT PROCEEDING
October 23, 2023
Case No. 2022-0797-2
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of MICHAEL DAVIS, Deceased
On to-wit the 11th day of December, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT AND REPORT OF INSOLVENCY as filed by LASHANDA L DAVIS. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
WILLIAM C. POOLE
917 WESTERN AMERICA CIR, STE 210
Mobile, AL 36609
Call News October 25, and November 1, 8, 2023

NOTICE OF COURT PROCEEDING
October 23, 2023
Case No. 2021-1760-3
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of BERNIE PURVIS, Deceased
On to-wit the 11th day of December, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT BY SURETY as filed by TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
BRIAN A. DODD
3973 BIBURY LN
BIRMINGHAM, AL 35242
Call News October 25, and November 1, 8, 2023

NOTICE OF COURT PROCEEDING
October 18, 2023
Case No. 2023-1568
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of MARY KATHLEEN SHERER, Deceased
On to-wit the 27th day of November, 2023 at 9:30 AM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the PROBATE OF WILL as filed by FLORENCE L LADD. NOTICE is hereby given to all parties in interest, specifically MERIDITH STEPHENS ASHWORTH who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
JEFFREY SETTERSTROM
3800 AIRPORT BLVD, SUITE 203
MOBILE, AL 36608
Call News October 25, and November 1, 8, 2023

NOTICE OF COURT PROCEEDING
October 17, 2023
Case No. 2019-2462-2
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of LOVE JOYCE WRIGHT YORK, Deceased
On to-wit the 27th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by PEIR ANGELIA YORK. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
RICHARD R. WILLIAMS
160 SOUTH CEDAR ST.
Mobile, AL 36602
Call News October 25, and November 1, 8, 2023

NOTICE OF COURT PROCEEDING
October 19, 2023
Case No. 2023-0599-2
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of FLORENCE HUGHES, Deceased
On to-wit the 27th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Sale of Real Property as filed by SHANITA DE NEICE SMITH. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
JOHN LAUTHIN MOORE IV
1050 DAUPHIN ST
MOBILE, AL 36604
Call News October 25 and November 1, 8, 2023

NOTICE OF COURT PROCEEDING
October 20, 2023
Case No. 2021-1895-2
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of LEVITA SUE CORBIN Deceased
On to-wit the 4th day of December, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT BY FORMER PERSONAL REPRESENTATIVE as filed by WILLIAM JOSEPH PHILLIPS. NOTICE is hereby given to all parties in interest, specifically JOSEPH A CORBIN who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, DAVIS, Judge of Probate
Attorney:
MICHAEL MARK LINDER JR
411 AZALEA ROAD
MOBILE, AL 36609
Call News October 25, and November 1, 8, 2023

NOTICE OF COURT PROCEEDING
October 18, 2023
Case No. 2021-2173-5
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of ROSS DIAMOND III, Deceased
On to-wit the 11th day of December, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by RACHAEL DIAMOND MCCALL. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
WILLIAM T. MCGOWIN IV,
P. O. Box 1287
Mobile, AL 36633
Call News October 25 and November 1, 8, 2023

NOTICE OF COURT PROCEEDINGS
November 13, 2023
Case No. 2023-1887
In Re: Charles Murdock Welch, an alleged incapacitated person
On to-wit, the 13th day of October, 2023, at 10:00 AM in Courtroom. 1, Third Floor, Mobile County Government Center Annex, 151 Government Street, Mobile, Alabama, 36602, the Court will proceed to consider the Petition for Letters of Conservatorship and Guardianship filed by Kim Hervet MacWilliam. Notice is hereby given to all parties in interest, specifically Christopher Charles Welch, who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
Don Davis
Judge of Probate
Attorney: John R. Nix, Esq.
1325 Dauphin Street
Mobile, AL 36604
Call News October 18, 25 and November 1, 2023

NOTICE OF COURT PROCEEDING
October 12, 2023
Case No. 2022-0528
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of ELVIN LEO BLAIR, Deceased
On to-wit the 13th day of November, 2023 at 9:30 AM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the PROBATE OF WILL as filed by NEWELL WESLEY RALSTON JR. NOTICE is hereby given to all parties in interest, specifically AZSPEN ROHR, PEGGY PARMER GILCHRIST, who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney: LUE E SULLIVAN SR
555 A IROQUOIS STREET
CHICKASAW, AL 36611
Call News October 18, 25, and November 1, 2023

NOTICE OF COURT PROCEEDING
October 13, 2023
Case No. 2023-0290-1
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of TREYH LASHAWN WEBSTER, Deceased
On to-wit the 4th day of December, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT BY SURETY as filed by RLI INSURANCE COMPANY. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney: JAMES J. DUFFY III
P.O. BOX 1109
MOBILE, AL 36633
Call News October 18, 25 and November 1, 2023

NOTICE OF COURT PROCEEDING
October 13, 2023
Case No. 2020-2299-6
IN THE PROBATE COURT OF
MOBILE COUNTY ALABAMA
Estate of BOBBY GENE RITTINGHOUSE, Deceased
On to-wit the 13th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Sale of Real Property as filed by ELIZABETH RITTINGHOUSE. NOTICE is hereby given to all parties in interest, specifically NICOLE MOTT, BRANDON RITTINGHOUSE, who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
PAGE STANLEY ELLIS
169 DAUPHIN STREET, SUITE 304
MOBILE, AL 36602
Call News October 18,25, and November 1, 2023

NOTICE OF COURT PROCEEDING
October 12, 2023
Case No. 2021-1502-2
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of ERNEST HOLLINS, Deceased
On to-wit the 27th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Final Settlement as filed by TRAVELERS CASUALTY AND SURETY COMPANY OF AMERICA. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney: BRIAN A. DODD
3973 BIBURY LN
BIRMINGHAM, AL 35242
Call News October 18, 25 and November 1, 2023

NOTICE OF COURT PROCEEDING
September 22, 2023
Case No. 2014-1753-1
IN THE PROBATE COURT OF
MOBILE, COUNTY, ALABAMA
Estate of RUDOLPH PUGH, Deceased
On to-wit the 6th day of November, 2023 at 2:00 p.m. in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Final Settlement as filed by CARRIE RIVERS. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
Don Davis, Judge of Probate
Petitioner: Carrie Rivers
6312 Spice Pond Rd.,
Mobile, AL 36613
Call News October 18, 25, and November 1, 2023

NOTICE OF COURT PROCEEDING
October 11, 2023
Case No. 2021-0561-1
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of BESSIE B WATT, Deceased
On to-wit the 27th day of November, 2023 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT BY SURETY as filed by WESTERN SURETY COMPANY. NOTICE is hereby given to all parties in interest, specifically JANICE FUNCHES, who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
JAMES J. DUFFY III
P.O. BOX 1109
MOBILE, AL 36633
Call News October 18, 25, and November 1, 2023

IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
CASE NO. 2021-0424
IN THE MATTER OF THE ESTATE OF CHARLES WINSTON JOHNS, SR., DECEASED,
NOTICE OF ESTATE SALE
Anthony M. Hoffman, as Administrator for the above-referenced Estate, gives notice of his intent to conduct an Estate Sale selling coins and silver.
The sale shall be conducted by Anthony Hoffman. The terms of said sale shall be that said coins will be sold as one lot, to sell all items for a price not less than the price as marked or for the highest offer. The SALE shall be conducted during the hours of 1:00 p.m. to 3:00 p.m. Friday, November 10, 2023, at 5 Dauphin Street, Suite 301, Mobile, Alabama 36602. Security will be present.
Same-day payment required in a manner satisfactory to the Administrator, with delivery of items upon payment.
Attorney:
ANTHONY M. HOFFMAN
P. O. BOX 11
Mobile, AL 36601
Call News October 18, 25, and November 1, 2023

Completion Notice
LEGAL NOTICE
In accordance with Chapter 1, Title 39, Code of Alabama, 1975, as amended, notice is hereby given that Shaw Integrated & Turf Solutions, Inc.
Contractor, has completed the Contract for Renovation at Theodore High School, Flooring for Library, Band Room, Office/Admin Guidance BSC #23-07, at 6201 Swedetown Road N Theodore, AL 365082 for the State of Alabama and the County of Mobile.
Owner(s), and have made request for final settlement of said Contract. All persons having any claim for labor, materials, or otherwise in connection with this project should immediately notify Shaw Integrated & Turf Solutions, Inc. at 616 East Walnut Avenue, Dalton, GA 30721.
Call News October 25, and November 1, 8, 15, 2023

LEGAL NOTICE
In accordance with Chapter 1, Title 39, Code of Alabama, 1975, as amended, notice is hereby given that Shaw Integrated & Turf Solutions, Inc.
Contractor, has completed the Contract for Renovation at Eichold Mertz Elementary School, Flooring for Media Center and Office BSC #22-11, at 2815 Government Blvd Mobile, AL 36606 for the State of Alabama and the County of Mobile.
Owner(s), and have made request for final settlement of said Contract. All persons having any claim for labor, materials, or otherwise in connection with this project should immediately notify Shaw Integrated & Turf Solutions, Inc. at 616 East Walnut Avenue, Dalton, GA 30721.
Call News October 25, and November 1, 8, 15, 2023

LEGAL NOTICE
In accordance with Chapter 1, Title 39, Code of Alabama, 1975, as amended, notice is hereby given that Shaw Integrated & Turf Solutions, Inc.
Contractor, has completed the Contract for Renovation at Mary G Montgomery High School, Flooring for Media Center and Auditorium BSC #22-12, at 4275 Snow Road Semmes, AL 36575 for the State of Alabama and the County of Mobile.
Owner(s), and have made request for final settlement of said Contract. All persons having any claim for labor, materials, or otherwise in connection with this project should immediately notify Shaw Integrated & Turf Solutions, Inc. at 616 East Walnut Avenue, Dalton, GA 30721.
Call News October 25, and November 1, 8, 15, 2023

LEGAL NOTICE
In accordance with Chapter 1, Title 39, Code of Alabama, 1975, as amended, notice is hereby given that Shaw Integrated & Turf Solutions, Inc.
Contractor, has completed the Contract for Renovation at Breitling Elementary School, Flooring for Library and Front Office BSC #23-05, at 8350 Grand Bay Wilmer Road Grand Bay, AL 36541 for the State of Alabama and the County of Mobile.
Owner(s), and have made request for final settlement of said Contract. All persons having any claim for labor, materials, or otherwise in connection with this project should immediately notify Shaw Integrated & Turf Solutions, Inc. at 616 East Walnut Avenue, Dalton, GA 30721.
Call News October 25, and November 1, 8, 15, 2023

LEGAL NOTICE
In accordance with Chapter 1, Title 39, Code of Alabama, 1975, as amended, notice is hereby given that Shaw Integrated & Turf Solutions, Inc.
Contractor, has completed the Contract for Renovation at Blount High School, Flooring for various areas BSC #23-13, at 5450 Lott Road, Prichard, AL 36613 for the State of Alabama and the County of Mobile.
Owner(s), and have made request for final settlement of said Contract. All persons having any claim for labor, materials, or otherwise in connection with this project should immediately notify Shaw Integrated & Turf Solutions, Inc. at 616 East Walnut Avenue, Dalton, GA 30721.
Call News October 25, and November 1, 8, 15, 2023

NOTICE OF COMPLETION
In accordance with Chapter 1, Title 39, Code of Alabama, 1975, notice is hereby given that
Bay Area Contracting, Inc. (Contractor), has completed the Contract for (Construction), (Renovation), (Alteration), (Equipment), (Improvement) of Brooks Park Landing Public Access Enhancements For the State of Alabama and the (Mobile) (Chickasaw), Alabama, Owners, and have made request for final settlement of said Contract. All persons having any claim for labor, materials, and otherwise in connection with this project should immediately notify Kimley-Horn and Associates, Inc. 11 North Water Street, Suite 9290 Mobile, AL 36602
Bay Area Contracting, Inc., Contractor
P O Box 8312 Mobile, AL 36689
Call News October 18, 25 and November 1, 8, 2023

LEGAL NOTICE
H.O. WEAVER & SONS, INC. hereby gives notice of completion of contract with the MOBILE COUNTY COMMISSION for construction of Project No. MCR-2022-104 in MOBILE COUNTY. This notice will appear for four consecutive weeks beginning on 10/18/2023 and ending on 11/1/2023 All claims should be filed at H.O. Weaver & Sons, Inc P.O. Box 8039 Mobile, AL 36689 during this period.
H. O. WEAVER & SONS, INC.
Call News October 18, 25, and November 1, 2023

NOTICE OF COMPLETION
WATER DISTRIBUTION SYSTEM IMPROVEMENTS
CONTRACT A
LeMoyne Water System, Inc.
Nordan Contracting Co., Inc. has completed the contract requirements for the above project. ANY PERSONS HAVING A CLAIM AGAINST THE PROJECT SHOULD NOTIFY William G. Luker, Speaks & Associates, Consulting Engineers, Inc., 732 Oak Circle Drive West, Mobile, Alabama 36609 (telephone 251-666-4646). All claims should be filed within 30 days of publication of this notice.
Nordan Contracting Company, Inc.
PO Box 336
Saraland, AL 36571-0336
Call News October 11, 18,25, and November 1, 2023

Notice is hereby given that Underground, Inc., has completed the contract with Mobile County Water, Sewer, and Fire Protection Authority for GOMESA Bellingrath SS Force Main Ext. – Phase B (Contract No. 448923B). Any claims held against same shall be itemized, notarized and presented
to Mobile County Water, Sewer, and Fire Protection Authority at its offices or same will be barred.
Call News October 11, 18, 25 and November 1, 2023

STORAGE SALE
In accordance with the provisions of State law, there being due and unpaid charges for which the undersigned is entitled to satisfy an owner and/or manager’s lien of the goods stored at The Storage Center location(s) listed below.
The Storage Center #8059
3641 Government Blvd.
Mobile, AL 36693
Unit 1085 Hydea Martin 3701 Carlyle Close Mobile, Al 36609, Unit 1074 Shadaven Edwin 2132 Riverside Dr. Mobile, Al 36605, Unit 2277 Alvin Parker 6369 Parker Hill Rd Milton, Fl 32570, Unit 2133 Shakayla Sumpter 1025 Cherokee St. Mobile, Al 36606, Unit 1148 Annie Sneed 3050 Westgate Dr. Mobile, Al 36606, Unit 2181 Terra Jones 3220 Cottage Hill Rd. Apt 9203 Mobile, Al 36606, Unit 2332 Alisha Hammond 3700 Carlyle Close Apt 756 Mobile, Al 36609, Unit 3023 Mya Newman 5185 Gamepoint Dr. W Theodore, Al 36582, Unit 2200 Labarron Perkins 7070 Grelot Rd. Apt 716 Mobile, Al 36695
And, due notice having been given, to the owner of said property and all parties known to claim an interest therein, and the time specified in such notice for payment of such having expired, the goods will be sold to the highest bidder or otherwise disposed of at public auction to be held at www.storagetreasure.com, which will end Thursday, November 16,2023 @ 10 A.M. Any questions regarding the above information are to be addressed to the manager of this facility at the phone number shown above.
Call News November 1, 8, 2023

Notice is hereby given that PODS ENTERPRISES, LLC, located at 185 Compass Circle, North Kingstown, RI 02852, will sell or otherwise dispose of the contents of containers belonging to certain customers that owe PODS rent if payment is not received by November 3, 2023. Auction will be held online at www.StorageTreasures.com starting on December 20, 2023 and ending at 10 AM on December 27, 2023. The following individuals and the respective amounts owed are as follows: Jennifer Lee Allen & $1,687.05.
Call News November 1, 8, 15, 2023

Extra Space Storage will hold a public auction to sell personal property described below belonging to those individuals listed below at the location indicated:
7997: 5441 US Hwy 90 W, Mobile, AL 36619
Auction Date: 11/15/2023 at 1:15 PM
Unit: 1327
Call News November 1, 2023

Extra Space Storage will hold a public auction to sell personal property described below belonging to those individuals listed below at the location indicated:
7926: 3679 Airport Blvd, Mobile, AL 36608
Auction Date: 11/15/2023 at 12:30 PM
Unit: 2050, 2173
Call News November 1, 2023

Extra Space Storage will hold a public auction to sell personal property described below belonging to those individuals listed below at the location indicated:
7403: 429 Bel Air Blvd, Mobile, AL 36606
Auction Date: 11/15/2023 at 12:00 PM
Unit: 214, 1102
Call News November 1, 2023

BILL
STATE OF ALABAMA
COUNTY OF MOBILE
Notice is hereby given that a bill as described in the synopsis below will be introduced in the 2024 Regular Session of the Legislature of Alabama and application for its passage and enactment will be made:
A BILL
TO BE ENTITLED
AN ACT
SYNOPSIS: To authorize any Class 2 municipality to establish a delegation agreement with the Department of Environmental Management for the local enforcement of the Scrap Tire Environmental Quality Act; and provide for jurisdiction for violations within a Class 2 municipality.
Call News October 18, 25, and November 1, 8, 2023

SHERIFF’S SALE
CASE NO. CV 2021 900846
STATE OF ALABAMA
COUNTY OF MOBILE
Napper Land, LLC.
VS
Jason Quinnelly
Under and by virtue of a Writ of Fieri Facias issued out of the Circuit Court of Mobile County in the above styled case, I will proceed to sell to the highest and best bidder, for cash, on November 16, 2023 at the hour of 12:00 NOON, at Wilmer Garage, 13357 US Highway 98, Wilmer, Al. 36587, all the right, title and interest of Jason Quinnelly, in and to the following described Personal property, to-wit:
2019 Ford F-250 Super-Duty Serial No. 1FT7W2BT4KEE55973 Sold subject to existing liens, if any.
PAUL BURCH JR SHERIFF,
MOBILE COUNTY
Call News November 1, 2023

SHERIFF’S SALE
CASE NO. CV 2021 901524
STATE OF ALABAMA
COUNTY OF MOBILE
Charles A Ray
VS
Basil L Huddleston
Under and by virtue of a Writ of Fieri Facias issued out of the Circuit Court of Mobile County in the above styled case, I will proceed to sell to the highest and best bidder, for cash, on November 20, 2023 at the hour of 12:10 P.M., at the courthouse, Government Street Entrance to the North Tower of Government Plaza, all the right, title and interest of Basil Huddleston, in and to the following described Real property, to-wit:
Lot 26 Kings Lynn Sub Unit 2 MBK 19 P 50 #SEC 21 T3S R2W #MP23 05 21 1 000 Sold subject to existing liens, if any.
PAUL BURCH JR SHERIFF,
MOBILE COUNTY
Call News October 25 and November 1, 8, 2023

PUBLIC HEARING
NOTICE
MOBILE COUNTY HOUSING
AUTHORITY PUBLIC HEARING
The purpose of the public hearing is to obtain input from residents and members of the community relative to the Annual Plan for 2024 and the Five Year Action Plan to be submitted to the U. S. Department of Housing and Urban Development.
The Public Hearing will be held Monday, November 13, 2023, 5:00 p.m. at our office located at 16545 U. S. Hwy 45, Citronelle, AL 36522.
All residents are encouraged to attend this hearing. The hearing is open to all residents and citizens in the community. Any citizen needing a reasonable accommodation may contact the Housing Authority. The Public Housing Agency Plan will be available for public review at the public housing office between the hours of 9:00 a.m. and 4:00 p.m. Persons may also submit written comments prior to the public hearing.
For further information, please contact Tyronnda Turner Bethune, Executive Director at (251) 866-9696.
MOBILE COUNTY HOUSING AUTHORITY
PUBLIC HEARING
Call News September 27 and October 4, 11, 18, 25, November 2, 8, 2023

PUBLIC MEETING
Joint MOBILE METROPOLITAN
PLANNING ORGANIZATION (MPO) POLICY BOARD
TECHNICAL COORDINATING
COMMITTEE (TCC)/
CITIZEN ADVISORY COMMITTEE (CAC)
MEETING
The Mobile MPO Policy Board will have a joint meeting with the TCC/CAC on Wednesday, November 8th, 2023 at 10:00 AM at the GM&O Building located at 110 Beauregard Street, Mobile, AL 36602.
The Policy Board will review and adopt the following changes to the FY 2024-2027 Transportation Improvement Program:
· 100070136;STPAA; PE; Causeway Access Management Plan and Signalization on SR-16 (US-90/98) from west of the Bankhead Tunnels to the US-98 Bypass; 11/1/2023; $367,853
· 100070137;STPAA; CN; Causeway Access Management Plan and Signalization on SR-16 (US-90/98) from west of the Bankhead Tunnels to the US-98 Bypass; 9/24/2027; $2,707,141
· 100077792; STPMB;PE; Resurfacing, Restoration, and Rehabilitation of Snow Road South from Jeff Hamilton Road to Airport Blvd; 12/1/2023; $367,350
· 100077792; STPMB;CN; Resurfacing, Restoration, and Rehabilitation of Snow Road South from Jeff Hamilton Road to Airport Blvd; 6/15/2025; $2,449,000
· 100077793; STMB;PE; Resurfacing, Restoration, and Rehabilitation of Snow Road North from Tanner Williams Road to U.S. Highway 98; 12/1/2023; $883,800
· 100077794; STMB;CN; Resurfacing, Restoration, and Rehabilitation of Snow Road North from Tanner Williams Road to U.S. Highway 98; 9/15/2025; $5,892,000
· 100077358; SP; Traffic Impact Study for SR-158 at I-65; 10/1/2023; $124,195
Also on the agenda is an amendment to the FY2024 Unified Planning Work Program to include a task for a Traffic Impact/Feasibility Study for McCrary Road from US-98 to Spice Pond Road Extension and Spice Pond Road Extension from McCrary Road to Lott Road for $57,225.00
Physically challenged persons who need special accommodations should contact SARPC in advance so arrangements can be made to meet their needs. Additional information may be obtained from the Transportation Planning Coordinator at the South Alabama Regional Planning Commission, (251)433-6541 or transporation@sarpc.org.
Call News November 1, 8, 2023

Abandoned Vehicle Auction
The following car has been abandoned at 801 Donald St Mobile, AL 36617 and will be sold at public auction on Dec 6 @ 8 a.m.
2GCEC19H2R1301303
94 Chev GMC
Call News November 1, 8, 2023

The following car has been abandoned at 3267 Schillinger Rd N Semmes, AL 36575 and will be sold at public auction on Dec 6 @ 8 a.m.
2TIBU4EE6BC708755
2011 Toyota Corolla
Call News November 1, 8, 2023

The following abandoned vehicle(s) will be sold at public auction on 12/06/2023 at 9:00 A.M. at 3704 Cottage Hill Rd Mobile AL 36609
2002 Nissan Sentra
VIN#3N1CB51D62L673566
Call News November 1, 8, 2023

The following abandoned vehicle(s) will be sold at public auction on 12/06/2023 at 9:00 A.M. at 5863 HWY 90 Theodore AL 36582
2017 Hyundai Elantra
VIN#5NPD74LF6HH139021
2018 Audi A6
VIN#WAUG8AFC2JN060670
Call News November 1, 8, 2023

The following abandoned vehicle(s) will be sold at public auction on 12/06/2023 at 9:00 A.M. at 6944 Pocahontas Dr Mobile AL 36618
2013 Dodge Grand Caravan
VIN#2C4RDGDG2DR735263
Call News November 1, 8, 2023

These abandoned vehicles will be sold on 11-30-23 at 5781 Three Notch Rd., Mobile AL 36619 at 9 a.m. if not redeemed before then.
Jeep ZACNJABB6LPL31541
Call News October 25, and November 1, 2023

The following vehicles were abandoned and will be auctioned 12/18/23 at 10 a.m. at 470 Schillinger Rd S Mobile, AL 36695.
2007 Toyota Avalon Gold
Vin# 4T1BK36B87U227934
Call News October 25 and November 1, 2023

The following car has been abandoned at 3267 Schillinger Rd N Semmes Al 36575 and will be sold at public auction on Nov 29 at 8 a.m.
1GYEC63878R145765
08 Cadi Escalade
Call News October 25 and November 1, 2023

The following vehicles were abandoned and will be auctioned 12/18/23 at 10 a.m. at Palmer’s Airport Hyundai 7680 Airport Blvd Mobile, AL 36608.
2016 Hyundai Elantra Silver
Vin# 5NPDH4AE1GH673453
2016 Hyundai Sonata Black
Vin# 5NPE34AF6GH299496
2014 Hyundai Sonata Black
Vin# 5NPEB4AC5EH896841
Call News October 25 and November 1, 2023

The following car has been abandoned at 5908 HWY 90 West Theodore, AL 36582 and will be sold at public auction on Nov 29 @ 8 a.m.
2015 Yamaha XVS95CFL
JYAVN05E8FA009992
Call News October 25 and November 1, 2023

ABANDONED VEHICLE
In accordance with Section 32-13-1, Code of Alabama 1975, notice is hereby given to the owner. Lienholders, and other interested parties that the following described abandoned vehicle will be sold at public auction for cash to the highest bidder 9:00 am, December 12, 2023, at Mobile Police Impound, 1251 Virginia Street, Lot B, Mobile, AL 36604.
2004 HYUNDAI SANTA FE
KM8SC13D54U730503
BOAT TRAILER
13DBK11M22AA45340
2003 TOYOTA
TACOMA 5TEWN72NX3Z289177
2004 TOYOTA HIGHLANDER
JTEDP21A440012959
2018 KIA SOUL
KNDJP3A50J7612400
2005 HYUNDAI ACCENT
KMHCG35C25U359858
2004 FORD EXPLORER
1FMZU62K94UB17809
2001 MAZDA B3000
4F4YR12U81TM31031
2015 TOYOTA CAMRY
4T1BF1FK3FU942112
2008 CHEVROLET SILVERADO
2GCEC13J981259223
2002 MERCEDES C
WDBRF61J92F197099
2004 BUICK CENTURY
2G4WS52J841281770
2004 HONDA ACCORD
1HGCM66554A009253
2009 CHEVROLET COBALT
1G1AL18H997180281
2000 DODGE DAKOTA
1B7GL22X6YS553179
YAMAHA 4-WHEELER
UNKNOWN VIN
1992 FORD MUSTANG
1FACP41M6NF179530
2003 VOLKSWAGEN NEW BEETLE
3VWCK21Y03M320120
2006 CHEVROLET EQUINOX
2CNDL63F166131767
2002 LEXUS IS
JTHBD192920046094
2000 LINCOLN TOWN CAR
1LNHM81W0YY934791
2017 KIA OPTIMA
KNAGT4L39H5173871
2002 CHEVROLET SILVERADO
1GCHC23U22F131399
2004 JEEP LIBERTY
1J4GK48K44W143200
2012 NISSAN FRONTIER
1N6AD0ERXCC415259
BLACK MINI-BIKE
2001 DODGE RAM
3B7HF13Z71G250432
2009 YAMAHA XV250
JYAVG04E59A009609
2001 YAMAHA YFS200
JY43JM0351C027656
1999 HONDA VT600
JH2PC2139XM902702
2004 POLARIS SPORTSMAN
4XACH50AX4A336841
2008 TAO TAO 250
L5CAFMLT98M003353
2007 TOYOTA AVALON
4T1BK36B87U251196
2011 NISSAN ALTIMA
1N4AL2AP3BN435416
2000 FORD CROWN VICTORIA
2FAFP73W2YX155120
1999 DODGE RAM VAN
2B7HB11X5XK501263
2005 FORD ESCAPE
1FMYU03145KB05000
2004 HONDA ACCORD
1HGCM56674A106845
2011 TOYOTA SEQUOIA
5TDZM5G12BS002887
2004 FORD EXPLORER
1FMZU63K54UB91985
2011 CHEVROLET EQUINOX
2CNALDEC9B6393542
2009 TOYOTA CAMRY
4T1BE46K09U373504
1989 HARLEY-DAVIDSON FXRP-F
1HD1EFL15KY130226
2019 DODGE CHARGER
2C3CDZAG9KH525711
2001 SUZUKI LS650
JS1NP41A312102506
2014 FORD TAURUS
1FAHP2E87EG170885
2012 NISSAN ALTIMA
1N4AL2AP9CN418962
2007 MERCEDES-BENZ C
WDBRF52H17A939540
1999 GMC DENALI
1GKEK13R2XR906743
2020 CAN-AM RYKER
3JB2GEG2XLJ004653
2006 INFINITI G35
JNKCV51E66M513114
2005 HONDA CIVIC
2HGES165X5H515097
2005 CHRYSLER 300
2C3JA43R45H154009
2000 FORD EXPLORER
1FMZU63PXYUB31668
2001 TOYOTA TUNDRA
5TBRT34111S201710
2014 LINCOLN MKZ
3LN6L2G95ER818134
1999 PONTIAC SUNFIRE
3G2JB1244XS854923
2005 UTLO AG612
BR612X0135AFG2005
2007 NISSAN ALTIMA
1N4AL21E27C195034
2006 DODGE RAM
1D7HA16N96J183125
1993 JEEP WRANGLER
1J4FY29S7PP244596
2002 LINCOLN CONTINENTAL
1LNHM97V42Y694608
2020 HONDA ACCORD
1HGCV1F4XLA155394
2006 HYUNDAI SONATA
5NPEU46F46H041711
2013 FORD EXPLORER
1FM5K7B86DGA20354
2010 SUBARU LEGACY
4S3BMCE65A3210539
2012 NISSAN ALTIMA
1N4AL2AP2CC104064
2009 NISSAN ALTIMA
1N4AL21E89N527839
2001 TOYOTA TUNDRA
5TBRT34151S186564
2013 DODGE AVENGER
1C3CDZAB4DN529969
2019 HYUNDAI SANTA FE
5NMS33AD1KH104843
2013 FORD FUSION
3FA6P0H72DR149108
2001 CHEVROLET TAHOE
1GNEC13T71J261539
2019 KIA FORTE
3KPF24AD6KE082761
2003 PONTIAC GRAND AM
1G2NF52F13C216174
2012 VOLKSWAGEN PASSAT
1VWAP7A32CC083366
2002 SUZUKI GSX-R750
JS1GR7HAX22103602
2008 DODGE CHARGER
2B3LA33G38H236056
2004 HONDA ACCORD
1HGCM66564A058722
2010 HYUNDAI VERACRUZ
KM8NUDCCXAU105576
2014 HONDA GROM
MLHJC6116E5000999
1998 CHEVROLET CAMARO
2G1FP22K6W2139985
2006 HONDA CR-V
JHLRD78986C056902
2003 MERCURY GRAND
MARQUIS 2MEFM75W13X706998
2001 HONDA ACCORD
1HGCG56661A144943
2014 TOYOTA CAMRY
4T4BF1FKXER354731
2015 TOYOTA RAV4
2T3WFREVXFW189875
2002 HONDA ACCORD
1HGCG22542A034857
2011 TOYOTA AVALON
4T1BK3DB9BU392452
2008 CHRYSLER 300C
2C3LA63H28H241181
2004 NISSAN 350Z
JN1AZ34D84T163995
2009 PONTIAC G6
1G2ZG57N294181162
2014 DODGE CHARGER
2C3CDXBGXEH189252
1998 FORD RANGER
1FTYR10U2WPA29937
1990 CHEVROLET CAPRICE
1G1BL54E9LR102523
2010 TOYOTA COROLLA
JTDBU4EE7AJ065206
1995 CHEVROLET GMT-400
1GBEC19K5SE150106
2002 TOYOTA CAMRY
4T1BE32KX2U087794
2007 MERCURY GRAND MARQUIS
2MEFM74V37X617450
1995 GMC YUKON
1GKEC13K1SJ752999
2006 DODGE RAM 1500
1D7HA16N96J183125
2018 CHEVROLET MALIBU
1G1ZD5ST3JF170103
2007 NISSAN ALTIMA
1N4AL21E27C195034
2007 VOLVO S80
YV1AS982271023271
2013 CHEVROLET TAHOE
1GNLC2E08DR340045
2015 VOLKSWAGEN PASSAT
1VWBV7A33FC093371
2016 CHEVROLET IMPALA
2G1WB5E30G1189275
2004 NISSAN MURANO
JN8AZ08T04W221095
2000 CHEVROLET BLAZER
1GNDT13W8Y2164098
2006 HONDA ACCORD
1HGCM56366A153180
2005 INFINITI FX35
JNRAS08U25X108639
1998 LINCOLN NAVIGATOR
5LMRU27L3WLJ31463
2011 DODGE NITRO
1D4PT4GK7BW597333
1996 DODGE RAM 1500
3B7HC13Y5TG182179
2010 MERCURY MILAN
3MEHM0JG6AR617325
2005 ARCTIC CAT
4UF01ATR01T308969
2015 GMC YUKON
1GKS1BKC4FR169262
2009 HONDA ACCORD
1HGCP26799A187465
2013 DODGE AVENGER
1C3CDZCG1DN709290
1998 MERCURY GRAND MARQUIS
2MEFM75W9WX693549
2014 SCION XB
JTLZE4FE5EJ065743
2003 TOYOTA CELICA GT
JTDDR32T730146643
2005 CHEVROLET MONTE CARLO
2G1WW12E859155585
Call News October 25 and November 1, 2023

The following vehicles, located at 1850 Shelton Beach Rd., Saraland, Ala., will be auctioned on November 29, 2023 at 9 a.m.
2010 LINCOLN MKS BLACK
1LNHL9ER0AG602164 473417
2015 DODGE JOURNEY RED
3C4PDCAB5FT531016 473690
2007 HONDA ACCORD BLACK
1HGCM66827A080442 473911
1997 GMC SAVANA WHITE
1GDHG31RXV1028060 473784
2013 FORD FUSION MAROON
3FA6P0H75DR281277 473912
2017 HYUNDAI SONATA BROWN
5NPE24AFXHH473686 473909
2007 HYUNDAI SONATA MAROON
5NPEU46F87H210968 474500
1984 HALEY DAVIDSON FLTC BLUE
1HD1DBL37EY700003 474535
2017 TOYOTA COROLLA SILVER
5YFBURHEXHP710283 474598
2014 DODGE GR CARAVAN WHITE
2C4RDGBG2ER185499 474718
2007 CHEVROLET IMPALA RED
2G1WC58R579180795 474786
2000 LAND ROVER DISCOVERY WHITE
SALTY1549YA236894 474798 LL
2017 NISSAN ALTIMA WHITE
1N4AL3AP9HC492858 475022
2006 INFINITI M35 BLACK
JNKAY01E26M111219 475171
2008 FORD FOCUS BLACK
1FAHP33N68W164956 474948 LL
2000 HONDA ACCORD GRAY
1HGCG1654YA081612 381167
2013 GMC SIERRA RED
3GTP2VE75DG318161 387254
2019 PETERBILT 579 RED
1XPBDP9X2KD629968 475228
Call News October 25 and November 1, 2023

Bay City Paint & Body Inc 6220 Theodore Dawes Rd, Theodore, Ala., will auction off the following abandoned vehicles on December 4, 2023 @ 9:00 a.m.
2006 HONDA CIVIC
2HGFG12616H532019
2005 CHEVY IMPALA
1G1WF52E759394360
2017 HONDA ACCORD
1HGCR1F55HA100183
2018 TOYOTA COROLLA
5YFBURHE9JP766141
2001 SATURN LW200
1G8JU82F01Y515148
2007 ACURA RL
JH4KB16627C002490
2002 FORD EXPLORER
1FMDU73W12UC43421
Call News October 25 and November 1, 2023