MOBILE COUNTY PUBLIC NOTICES 03-20-2024 CLICK HERE

BID NOTICES
INVITATION TO BIDDERS
Sealed proposals will be received by the Board of School Commissioners of Mobile County, until 2:00 P.M., legally prevailing time, on April 18, 2024 for the Maryvale Maintenance Shop Fuel Station at the Mobile County Public School System Facilities Office, 1 Magnum Pass, Mobile, AL 36618, at which time and place they will be publicly opened and read.
A cashier’s check or bid bond payable to Board of School Commissioners of Mobile County in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder’s proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract.
Drawings and Specifications may be examined at the office of the Architect, Ward Scott Morris Architecture, Inc., 1606 Paul Bryant Drive, Tuscaloosa, Alabama, and at TuscaBlue, 2806 Greensboro Avenue, Tuscaloosa, Alabama.
Hard copy bid documents may be obtained from TuscaBlue via www.ward-scottplans.com, upon deposit of $150.00 per set, which will be refunded in full on the first two sets issued to each trade contract bidder submitting a bona fide bid, upon return of documents in good condition within ten days of bid date. Other sets for contractors, and sets for dealers, may be obtained with the same deposit, which will be refunded as above, less cost of printing, reproduction, handling, and distribution. Electronic PDF bid documents are available for download from the same website free of charge.
Bid bonds are to be issued by an acceptable bonding company licensed to do business in the State, with a Power of Attorney, to confess judgment thereon, with the understanding that it shall guarantee that the bidder shall not withdraw his bid for the guarantee period of sixty (60) days after the scheduled closing time for the receipt of bids; that if his bid is accepted, he will enter into a formal contract with the Owner, and that in the event of a withdrawal of said bid within said period, or the failure to enter into said contract within the time specified, the bidder shall be liable to the Owner for the full amount of the bid guarantee as liquidated damages and not as a forfeit or as a penalty. The bid bond and certified checks on unsuccessful bidders will be returned upon awarding the contract or rejection of all bids, in no event, later than the number of days in the guarantee period from the opening of proposals. That of the successful bidder will be returned when formal contract and bonds are accepted and approved.
Bids must be submitted on proposal forms furnished by the Architect or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect; the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner’s judgment, the best interests of the Owner will thereby be promoted.
All Bidders are required to attend a mandatory pre-bid conference to be held at the Mobile County Public School System Facilities Office, 1 Magnum Pass, Mobile, AL 36618 at 10:00 A.M. on April 4, 2024. The bidder’s company employee attending the pre-bid conference shall have qualifications and experience with the construction to be performed within this project. Any questions concerning the pre-bid conference shall be directed to the Architect.
Nonresident bidders must accompany any written bid documents with a written opinion of an attorney at law licensed to practice law in such nonresident bidder’s state of domicile, as to the preferences, if any or none, granted by the law of that state to its own business entities whose principal places of business are in that state in the letting of any or all public contracts.
Call News March 20, 27, and April 3, 2024
|
ADVERTISEMENT FOR CONTRACTOR PRE-QUALIFICATION AND
CONSTRUCTION BIDS
FOR: ELBERTA MIDDLE SCHOOL – PHASE 1 in Elberta, Alabama
For the BALDWIN COUNTY BOARD OF EDUCATION
Bay Minette, Alabama
Only general contractors who have been approved to bid pursuant to prequalification procedures and criteria established by the Owner will be eligible to bid for the Project.
The Owner shall qualify Contractors who have successfully completed similar size and scope projects on time for satisfied Owners. Pre-Qualification Applications shall be received at the office of OTK Architecture, llc C/O Otis Gatlin, 1302 North McKenzie Street, Foley, Alabama 36535 until 4:00 PM CST on April 4, 2024. Written prequalification procedures and criteria are available for review at the office of the Architect.
The Architect for this project: OTK Architecture, LLC, 1302 N. McKenzie St., Foley, AL 36535 Phone: 251-270-6401 Project Contact: otis.gatlin@otkarchitecture.com
Once prequalified bidders are determined, sealed bids for Phase I will be received by the Baldwin County Board of Education, C/O Marlana Hanner, 23651 Flowers Road, Robertsdale, Alabama 36567 until 2:00 PM CST on a Bid Date provided to qualifying Contractors at which time and place they will be publicly opened and read.
A mandatory pre-bid conference shall be held on Tuesday, April 9, 2024 at 9:00 am at the BCBE office in Robertsdale at the address listed above.
For each project, a cashier’s check or bid bond payable to the Baldwin County Board of Education in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder’s proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract.
When available Plans, Specifications and Contract Documents are open to public inspection at the office of the Architect.
Bid Documents may be obtained from the Architect upon deposit of $300.00 per set, which will be refunded in full on the first set issued to each general contract bidder submitting a bonafide bid, upon return of documents in good condition within ten days of bid date. Other sets for general contractors, and sets for subcontractors and dealers, may be obtained with the same deposit, which will not be refunded. Bids must be submitted on proposal forms furnished by the Architect or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect; the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered.
The Owner reserves the right to reject any or all bid proposals and to waive technical errors if, in the Owner’s judgment, the best interests of the Owner will thereby be promoted.
PROJECT DESCRIPTION:
ELBERTA MIDDLE SCHOOL – PHASE 1
The work includes construction services required to provide all construction fencing, sitework, surcharge work, surcharge removal, building pad and grading and drainage work as indicated in the document set prepared by OTK Architecture, llc and made ready for Phase II work to commence. The Phase I work also includes but is not limited to assumption of the ADEM permit and installation and upkeep of BMP requirements by this contractor.
Owner’s Representative:
Mr. Frank Boatwright Jr.
Facilities and Maintenance Director
Baldwin County Board of Education
23651 Flowers Road
Robertsdale, Alabama 36567
Call News March 20, 27, and April 3, 2024
|
INVITATION TO BID
The Water Works Board of the City of Birmingham will be accepting bids covering the installation of water mains and appurtenances connected thereto and 110 water services along 4th Avenue West; 4th Court West; 6th Avenue West; 6th Street West; 7th Street West; 7th Avenue West and 17th Street Ensley located in the City of Birmingham, Alabama. Plans and specifications may be obtained by contacting Douglass W. Stockham, IV via email at doug.stockham@bwwb.org or Janice Acoff at janice.acoff@bwwb.org. Please state the bid name in the subject field when sending plans and specifications request. A Mandatory Pre-Bid Conference will be held on Thursday, March 28, 2024, at 10:30 a.m. local via conference call Number: 1-888-278-0296 / Access Code: 2875407. Bids will not be accepted from Contractors who do not attend the Pre-Bid Conference. Sealed Bids will be received by The Water Works Board of the City of Birmingham, System Development Department, 3600 First Avenue North, Birmingham, Alabama until 9:00 a.m. local time on Thursday, April 11, 2024. The Sealed Bids will be opened and read at 10:15 a.m. local time on Thursday, April 11, 2024, by System Development staff in the System Development Conference Room on the Second Floor of the Main Campus Building located at 3600 First Avenue, North in Birmingham, Alabama via conference call as stated above.
Call News March 13, 20, 2024
|
INVITATION TO BID
The Water Works Board of the City of Birmingham will be accepting bids covering the installation of water mains and appurtenances connected thereto and 45 water services along Center Street; 1st Place West; 1st Street West; Center Place West; 37th Avenue West and 39th Avenue West located in the City of Birmingham, Alabama. Plans and specifications may be obtained by contacting Douglass W. Stockham, IV via email at doug.stockham@bwwb.org or Janice Acoff at janice.acoff@bwwb.org. Please state the bid name in the subject field when sending plans and specifications request. A Mandatory Pre-Bid Conference will be held on Thursday, March 28, 2024, at 10:00 a.m. local via conference call Number: 1-888-278-0296 / Access Code: 2875407. Bids will not be accepted from Contractors who do not attend the Pre-Bid Conference. Sealed Bids will be received by The Water Works Board of the City of Birmingham, System Development Department, 3600 First Avenue North, Birmingham, Alabama until 9:00 a.m. local time on Thursday, April 11, 2024. The Sealed Bids will be opened and read at 10:00 a.m. local time on Thursday, April 11, 2024, by System Development staff in the System Development Conference Room on the Second Floor of the Main Campus Building located at 3600 First Avenue, North in Birmingham, Alabama via conference call as stated above.
Call News March 13, 20, 2024
|
Notice To Bidders
Sealed bid packages for Bid 24-05-10
Landscaping Services will be received in the Purchasing Department of the Birmingham Water Works Board, located at 3600 First Avenue North, Birmingham, Alabama 35222, until 10:00 a.m. (CST), March 29, 2024. All sealed bids will be opened and read to the public on this date. All potential suppliers must receive an executed copy of the applicable Receipt of Bid Sheet, with a time stamp, from the BWW Purchasing Department before their bid package may be considered responsive. The bid packages must be hand-delivered to the BWW Purchasing Department, which is located at 3600 First Avenue North, Birmingham, Alabama 35222. The bid packages must be directed to the attention of the Purchasing Manager and marked in the lower left-hand corner of the envelope as follows: “Bids for 24-05-10: Landscaping Services”. The General Contractor License number should be listed in the lower right-hand corner of the envelope. Bid packages may be obtained through our website at www.bwwb.org, by emailing Rosalind Jones at Rosalind.jones@bwwb.org, or by calling 205-244-4078.
Call News March 13, 20, 27, 2024
|
MOWA Choctaw Housing Authority
Clearing of Land
Invitation Bid Meeting
RFQ-03-07-2024-001
NOTICE IS HEREBY GIVEN that the MOWA Choctaw Housing Authority (MCHA) is soliciting for sealed bids for Project: RFQ-03-07-2024-001.
This project includes clearing 29 acres in Mt. Vernon, AL. The Contractor shall furnish all labor, tools, equipment, and incidentals thereto required for completion of the project. The contractor will furnish all material for the project. A mandatory Pre-Bid meeting will be held at the MOWA Choctaw Housing Authority, 1080 A Red Fox Road, Mt. Vernon, AL 36560 on March 26, 2024, at 2:00 PM (CT). Bids are due on April 1, 20224, at the MOWA Choctaw Housing Authority by 12:00 PM (CT) at 1080 A Red Fox Road, Mt. Vernon, AL 36560, Bids will be opened and publicly read aloud at the MCHA Conference Room on April 1, 2024 @ 12:00pm. MCHA reserves the right to reject any or all the bids. The awarding of bids will be pending approval of the MOWA Choctaw Housing Authority.
This invitation for Bid is open to selected General Contractors; however, the award shall be made under unrestricted solicitation to the lowest/responsive/responsible bidder using the “X” Factor tabulation (Indian Preference). The Project will be awarded to one Prime Contractor.
All bids must be sealed and addressed to the MOWA Choctaw Housing Authority and plainly marked with the Bidder’s name and the Project name. Bids shall be on a Lump Sum basis per the Project documents; segregated bids will not be accepted. Bid documents and specifications are made a part of this Invitation for Bid.
For additional information contact Darren Snow at 251-431-5151 or Lillie Steiner at lilliesteiner@mowachoctaw.com.
MOWA Choctaw Housing Authority 1080 A Red Fox Road, Mt. Vernon, AL 36560 251-829-5000
Call News March 13, 20, 2024
|
INVITATION TO BID
Sealed proposals will be received by City of Saraland at the City Clerk’s Office located at 943 Saraland Blvd. South, Saraland, AL 36571 on
March 28, 2024 at 2:00pm local time for the
City of Saraland Public Library Roof Replacement Project
111 Saraland Loop, Saraland, AL 36571
and will be publicly opened and read at the next scheduled council meeting on March 28, 2024.
The scope of work includes replacing the entire roofing system of the Saraland Public Library.
Project overview: All roofing systems are to be properly inspected and the old roofing removed. The decking shall be cleaned of debris and properly prepared for the new replacement roof systems. All damaged or rotten wood decking shall be replaced. All decking is to be secured, re-nailed and taped as necessary for code compliance. All metal eaves, valleys, coping, lead or rubber boots and caps are to be replaced and then sealed of any improper openings or leaks and to match in color as approved by the city.
The flat roofing area shall be cleaned and pressure washed. The contractor is to install an approved urethane sealant on all laps and seams. A minimum of two urethane base coats shall be installed in accordance with the manufacturer’s instructions and shall be approved by the city. A minimum of two silicone top coats shall be installed in accordance with the manufacturer’s instructions and shall be approved by the city.
The shingle roofing area shall have all old shingles and underlayment removed. The proper synthetic underlayment shall be installed with the proper deck tape with ice and water shield installed. The contractor is to replace all shingles with Architectural type shingles meeting or exceeding the required ICC wind speeds. The type, color, and manufacture of the shingles are to be approved by the city.
The contractor is to replace all rotten facia wood with new and to install new aluminum facia metal around the entire building. The type, color, and manufacture of the shingles and the aluminum facia metal are to be approved by the city.
Debris removal, site clean-up, magnet clearing and hauling is the responsibility of the contractor and all A/C units are to protected from damage by roofing tacks, shingles, or other debris.
Warranties: A Five (5) year warranty on all workmanship and a Twenty (20) year warranty on roof product materials is required. Architectural type shingles shall have a Thirty (30) year warranty.
A cashier’s check or bid bond payable to the City of Saraland in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder’s proposal. Performance and Payment Bonds and evidence of insurance are required in the bid documents and will be required at the signing of the Contract.
All bidders are encouraged to visit the City of Saraland Library located at 111 Saraland Loop and consult with the Building Inspection Department to familiarize themselves with all aspects of the project.
Contact Info: City of Saraland Building Inspection Department, 933 Saraland Blvd. South, Saraland, AL. 36571
Attn: Inspection Services Director Mike Black, mblack@saraland.org , phone (251) 679-5502
Bids must be submitted on proposal forms furnished by the Building Inspection Department. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or the bid will not be received or considered by the Building Inspection Department/Architect; the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. No bid may be withdrawn after the scheduled closing time for receipt of bids for a period of (30) days.
The Owner reserves the right to reject any or all proposals and to waive technical errors, if in the Owner’s judgement, it is in the best interests of the Owner and will thereby be promoted.
Call News March 13, 20, 27, 2024
|
Chickasaw Housing Authority is requesting sealed bids from qualified Contractors to complete a Window Replacement Project at the Authority’s properties, located in Chickasaw, AL. Interested Contractors shall provide a bid for the replacement of a total of 2,574 windows of various sizes in the 139 buildings located on one housing site. The windows shall be impact resistant to a minimum of DP50, and must be Energy Star rated. The Contractor will be responsible for confirming and verifying the window count, window sizes, and window placement. This project is expected to begin in the 4th quarter of 2024, and the Contractor will be expected to complete the work within twelve (12) months of the Notice to Proceed. The deadline for submissions in response to this Request for Proposals is April 9, 2024 March 20, 2024, 11:30 AM Central Time. Interested Contractors should contact Michael Sweet at Chickasaw Housing Authority, 604 Dumont Street, Chickasaw, AL. 36611, or (251)457-6841 ext. 302 or chick604@bellsouth.net for a complete RFP solicitation document.
Call News March 13, 20, 2024
|
The Marine Environmental Sciences Consortium/Dauphin Island Sea Lab is receiving sealed bids for plumbing repairs in the dormitory bathrooms. Bids will be opened at the Dauphin Island Sea Lab Administration Building on Wednesday, March 27, 2024, at 2 p.m. https://disl.edu/about/administration/
Call News March 13, 20, 27, 2024
|
INVITATION FOR BIDS
GOMESA FORCE MAIN EXTENSION TO JOE CARL
PHASE B – FORCE MAIN
(Project No. 448932)
Sealed Proposals, subject to the conditions herein, will be received by Mobile County Water, Sewer and Fire Protection Authority (MCWS), 5780 Theodore Dawes Rd., Theodore, AL 36582 until 10:00 a.m., Local Time, April 4, 2024 and then publicly opened and read for furnishing all labor and materials, and performing all work for constructing GOMESA Force Main Extension to Joe Carl Phase B – Force Main (Project No. 448932). The work consists primarily of the installation of approximately 16,700 LF of 2”, 3”, and 6” HDPE sanitary sewer force main, approximately 200 LF of 2”, 3”, and 6” D.I. force main, and approximately 130 LF of 12” Steel Encasement by horizontal directional drill and open cut methods.
Plans and specifications may be viewed at the office of Mobile County Water, Sewer and Fire Protection Authority and at Volkert, Inc., 1110 Montlimar Blvd., Suite 1050, Mobile, AL 36609. Also, electronic specifications may be obtained by email for review only from Volkert, Inc. (contact: keturah.doherty@volkert.com). All bids must be submitted on a hard copy numbered set of plans and specifications obtained from Volkert, Inc. as described in the Instructions to Bidders.
Copies of the Plans and Specifications for bidding purposes may be obtained from Volkert, Inc. upon payment of a charge of $75.00 for each set to Volkert, Inc., to cover the cost of printing, reproduction, handling and distribution and will not be refunded. No plans and specifications will be issued to contractors later than twenty-four (24) hours prior to the time indicated above for receiving bids.
An envelope containing bids must be sealed, marked, addressed as follows, and delivered to the Mobile County Water, Sewer and Fire Protection Authority, 5780 Theodore Dawes Road, Theodore, AL 36582 “Bid for GOMESA Force Main Extension to Joe Carl Phase B – Force Main (Project No. 448932),” to be opened at 10:00 a.m., Local Time, April 4, 2024. The Bidder’s Alabama State Contractor’s License Number shall be included on the envelope containing the submitted proposal.
MOBILE COUNTY WATER, SEWER AND FIRE PROTECTION AUTHORITY
Call News March 13, 20, 27, 2024
|
ADVERTISEMENT FOR BIDS
Sealed proposals will be received by the Board of School Commissioners of Mobile County, Alabama at the Mobile County Public School System, Facilities Department Conference Room, Building F, 1 Magnum Pass, Mobile, Alabama 36618 until 2:00 PM, CST, April 2, 2024, for:
B.C. RAIN CHILLER REPLACEMENT, FPN 21-04, DCM #2020798, PSCA #9124 at which time and place they will be publicly opened and read.
A cashier’s check or bid bond payable to Board of School Commissioners of Mobile County, Alabama in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000, must accompany the bidder’s proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract.
A Mandatory Prebid Meeting will be held in the Facilities Conference Room, Building F, 1 Magnum Pass, Mobile, Alabama 36618 at 2:30 PM on Tuesday, March 26, 2024.
Drawings and specifications may be examined at the office of Watermark Design Group, 2970 Cottage Hill Road, Suite #200, Mobile, Al 36606, and the Facilities Department, Building F, 1 Magnum Pass, Mobile, Alabama 36618.
Bid Documents (hardcopy) may be obtained from the Architect upon deposit of $50.00 per set, which will be refunded in full on the first set issued to each general contract bidder submitting a bonafide bid, upon return of documents in good condition within ten days of bid date. Other sets for general contractors and sets for subcontractors and dealers, may be obtained with the same deposit, which will be refunded as above, less cost of printing, reproduction, handling, and distribution. Bid Documents (digital) may be obtained from the Architect at no cost via email request to smcarthur@watermarkarch.com and upon completion of a digital transfer agreement.
Bids must be submitted on proposal forms furnished by the Architect or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect; the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner’s judgement, the best interests of the Owner will thereby be promoted.
BOARD OF SCHOOL COMMISSIONERS OF MOBILE COUNTY, ALABAMA
Call News 3/6/24, 3/13/24, and 3/20/24
|
ADVERTISEMENT FOR BIDS
Sealed proposals will be received by the Board of School Commissioners of Mobile County at the Facilities Conference Room, 1 Magnum Pass, Building F, Mobile, AL 36618 until 2:00 p.m. local time, Tuesday April 9, 2024 for MCPSS Central Office Cooling Towers and Canopy, One Magnum Pass, Mobile, AL 36618. DCM #2023069; PSCA 9472; FPN 23-20; at which time and place they will be publicly opened and read.
A cashier’s check or bid bond payable to the Board of School Commissioners of Mobile County in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000.00 must accompany the bidder’s proposal. Performance and Payment Bonds and evidence of insurance required in the Bid Documents will be required at the signing of the Contract.
Drawings and Specifications may be examined at the office of The Architects Group, Inc. 710 Downtowner Blvd. Mobile, AL 36609; The Facilities Department of MCPSS at 1 Magnum Pass, Mobile, AL 36618; and FW Dodge Plan Rooms in Montgomery and Birmingham, CMD Group, Document Processing Center, 30 Technology Parkway South, Suite 500, Norcross, GA 30092-2912 and through SCAN.
A Mandatory Pre-Bid Meeting is scheduled to be held at 2:00 p.m. local time on Tuesday March 26, 2024, at the Facilities Conference Room, 1 Magnum Pass, Building F, Mobile, AL 36618.
Bid Documents may be obtained from The Architects Group, Inc. (251) 343.1811 upon deposit of $200.00 (check payable to “The Architects Group, Inc.”) per set which will be refunded in full on the first set issued to each general contract bidder submitting a bona fide bid, upon return of documents in good condition within ten days of bid date. Other sets for general contractors and sets for subcontractors and dealers may be obtained with the same deposit, which will be refunded as above, less cost of printing, reproduction, handling and distribution.
Bids must be submitted on proposal forms furnished by the Architect or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect; the bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner’s judgement, the best interests of the Owner will thereby be promoted.
BOARD OF SCHOOL COMMISSIONERS OF MOBILE COUNTY
Call News March 6, 13, 20, 2024
|
ADVERTISEMENT FOR BIDS
Sealed proposals will be received from qualified General Contractors at the offices of:
The Mobile County Public School System’s Facilities Conference Room, 1 Magnum Pass Building F, Mobile, Alabama 36618 until 2:00 PM local prevailing time, March 26, 2024, and thereafter opened publicly for construction of:
B.C. RAIN HIGH SCHOOL SECURITY CAMERA UPGRADE FOR MOBILE COUNTY PUBLIC SCHOOL SYSTEM, MOBILE, ALABAMA.
The work includes Security Camera Upgrade with all trades incorporated in the General Contract.
Obtaining Bid Documents: Electronic images of bid documents may be viewed on-line at no cost through Alabama Graphics web site (www.algraphicsplanroom.com) and hard copies at the office of the Architect. Questions pertaining to accessing the web site should be directed to Bryant Haynie 334/263-0529. Access jobs under “PUBLIC JOBS” for the above-named project. Bidders may obtain Bid Documents as directed below. Bid Documents may only be obtained from:
Alabama Graphics
350 E. Fred D. Gray Ave
Montgomery, Alabama 36104
Bid Documents: Bid Documents either paper copies OR full sets of electronic copies (pdf format) may be purchased through the Alabama Graphics DPR web site upon payment to Alabama Graphics. The cost will be $ 125.00 per set. This is the full cost of printing, handling, and distribution.
Official interpretations will be based on complete, full-size sets. Bid documents may be used only for the purpose of bidding and constructing this project. Documents may not be copied in whole or in part by electronic or other means. Anyone placing an order for plans and specifications will be notified of all addenda by e-mail. The architect retains all copyrights and ownership of the documents.
Award will be made only to competent and responsible bidders as mandated by Title 39 of the Code of Alabama respondents who have the experience and other qualifications as set forth in the bid documents. Pre-bid qualification is not required. All bidders must be licensed under Title 34 of the Code of Alabama and evidence thereof must appear on the proposal envelope (outside in clear view) or it will not be opened.
A Mandatory Pre-bid conference will be held at 2:00 PM, local time on March 19, 2024, at: The Mobile County Public School System, Facilities Conference Room, Building F, 1 Magnum Pass, Mobile, Alabama 36618 for the purpose of reviewing the project and answering Bidder’s questions.
This project qualifies for the Sales Tax Saving Program and the Owner intends to implement this program.
Pursuant to State Law a cashier’s check or bid bond payable to the Owner in an amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000.00, must be enclosed with the bid to secure the bid for at least 30 days. Conditional bids will be rejected. A list of major subcontractors must be submitted as indicated in the Supplemental Instructions to Bidders. Performance and Payment Bonds and evidence of specified insurance are pre-requisites of contract award. Right is reserved by the Awarding Authority to reject all bids and to waive irregularities.
The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner’s judgment, the best interests of the Owner will thereby be promoted.
Call News March 6, 13, 20, 2024
|
ADVERTISEMENT FOR BIDS
Notice is hereby given that The Utilities Board of the Town of Citronelle dba South Alabama Utilities, a Public Corporation will receive sealed bids for the following described work at the office of South Alabama Utilities, 8100 Joy Street, (P.O. Box 428) Citronelle, Alabama 36522, until 4:00 p.m., local time, on Tuesday, April 9, 2024, then publicly opened and read at the Board meeting starting at 1:00 p.m. on Wednesday, April 10, 2024:
WATER SYSTEM IMPROVEMENTS FOR THE ESCATAWPA AREA
200,000-GALLON ELEVATED WATER STORAGE TANK (PEDESPHERE TYPE)
SAU BID #24-03
And other necessary items.
Bidders for this project are notified that this project will be fully or partially funded with Federal funds and is subject to the Federal laws and regulations associated with the American Rescue Plan (ARP) Fiscal Recovery Fund grant. Any contract resulting from this solicitation will be subject to the terms and conditions of said funding award, the SLFRF Financial Assistance Standard Terms and Conditions (OMB Approved No. 1505-0271) and Program-Specific Terms and Conditions, the Standard Sub-Award Terms and Conditions, American Rescue Plan Act, Treasury Regulations 31 C.F.R. § 35 et seq., all applicable terms and conditions in 2 C.F.R. Part 200 (including Appendix II to Part 200), and all other OMB circulars, executive orders or other federal laws or regulations, as applicable. The United States Department of Treasury, the United States, or any of its departments, agencies, or employees is not and will not be a party to this solicitation or any resulting contract. Notwithstanding, any contract that is awarded as a result of this Advertisement for Bids may require adherence to the standard Federal Contracting provisions.
Plans and specifications may be inspected and obtained at the office of Speaks & Associates, Consulting Engineers, Inc., 732 Oak Circle Drive West, Mobile, Alabama 36609. A deposit of $75.00 payable to Speaks & Associates, along with a completed Request for Bid Documents form (which may be obtained by emailing brendah@speaks.cc and requesting it), is required for each set of plans and specifications. The deposit will not be refunded. No plans and specifications will be issued to contractors later than the Thursday prior to receiving bids.
The bidder must provide their name, address, and other information required by the Project Engineer on the Request for Bid Documents form in order to obtain a numbered set of Contract Documents, which will be assigned to that bidder. The Contract Documents are for that bidder’s exclusive use and a bid submitted by any other bidder using a numbered set that has not been assigned to them is automatically disqualified. This provision will not be waived.
It is the bidder’s responsibility to verify with the Project Engineer no later than 72 hours prior to the bid time and date that they have received all addenda and other supplemental information issued by the Engineer during the bid period for use in preparing the bid.
A bid bond or certified check equal to five percent (5%) of the base bid payable to The Utilities Board of the Town of Citronelle dba South Alabama Utilities, a Public Corporation must accompany each bid. No bid may be withdrawn for a period of 60 days following the bid opening unless approved by the Owner.
Each bid must be submitted in a sealed envelope on forms provided in the specifications and shall be clearly marked bid for: Water System Improvements for the Escatawpa Area – 200,000-Gallon Elevated Water Storage Tank (Pedesphere Type) – SAU Bid 24-03. The entire bid book must be submitted in the bid package, along with the experience documentation, resumes, design sketches, and other items called for by the bid documents. The Owner reserves the right to reject any and all bids and to waive any formalities in the bidding.
Contractors bidding on this project must hold a current license from the State Licensing Board of General Contractors, Montgomery, Alabama.
Owner:
The Utilities Board of the Town of Citronelle
dba South Alabama Utilities, a Public Corporation
Call News March 6, 13, 20, and 27, 2024
|
THE WATER WORKS BOARD OF THE CITY OF BIRMINGHAM
LAKE PURDY DAM STABILITY IMPROVEMENTS PROJECT
Project Number: P.01034
Capital Budget Number: BP-616-12
NOTICE TO BIDDERS
Sealed Bids for the construction of the Lake Purdy Dam Stability Improvements Project will be received by The Water Works Board of the City of Birmingham Engineering Department, Attn: Hattye McCarroll. P.E.; Chief Engineer, 3600 First Avenue North, Birmingham, Alabama 35222 until 10:00 a.m. local time on Thursday, May 2, 2024. Bids received after said time will be rejected and returned unopened.
Construction of Lake Purdy Dam Stability Improvements Project includes but not limited to the following scope of work:
1. Roadway Construction
a. Site work, grading and widening of the roadway.
b. Construction and installation of roadway erosion and sedimentation control.
c. Installation of chert which includes transportation and excavation of chert from a borrow area and placing, grading, and compacting on the roadbed.
d. Installation of a dense grade stone pavement on the entrance road of all graded or new roadbed where chert or other pavement is not applied.
e. Installation of storm pipes along the roadway.
f. Maintenance of roadway throughout the duration of the project.
2. Dam Rehabilitation
a. Demolition and disposal of all materials of the existing pole barn in the laydown area.
b. Clearing, grubbing, and grading.
c. Providing and maintaining erosion and sediment control measures, and obtaining stormwater NPDES Permit.
d. Construction of a sedimentation pond and outfall structure.
e. Extending and encasing the existing low-level outlet pipes.
f. Providing reinforced concrete for pipe encasement, stilling basin, training walls, retaining walls, spillway control section, and raising the dam crest.
g. Providing roller compacted concrete (RCC) buttressing of the dam.
h. Installing cast-in-place concrete step-facing system.
i. Installation of earthfill berms for support of non-overflow sections of the dam and temporary levels to serve as grouting platforms.
j. Performing comprehensive foundation grouting through and underneath the dam.
k. Passive dowels into rock, masonry, and concrete to secure proposed work to foundation and/or existing dam.
l. Conducting CCTV and geo-location of lower inlet pipe at valve house.
m. Repair and sealing of interior walls of valve house.
n. Replacement of valves in valve house and replacement of roof in valve house.
o. Installing filter drains within the earthfill abutments.
p. Constructing earthfill abutments.
q. Miscellaneous site improvements and site piping as required.
r. Other miscellaneous associated items as necessary to complete the work.
Bids shall be based on a lump sum plus unit price items plus contingency allowance items as indicated in the Bid Form.
Bidding Documents may be examined at the office of the Chief Engineer of The Water Works Board of the City of Birmingham, 3600 First Avenue North, Birmingham, AL; and the office of Arcadis U.S., Inc., 1143 1st Ave. South, Birmingham, AL.
Prime Contractor bidders may obtain one complete set of Bidding Documents on or after March 6 2024 from the office of the Chief Engineer of The Water Works Board of the City of Birmingham upon payment of a $300.00 deposit by company check or by certified check and signing a nondisclosure statement. No personal checks or any other form of payment except as noted will be accepted. This deposit shall be refunded in full to each prime contractor bidder upon the return of the Bidding Documents in a reusable condition within 10 days after the bid opening. Additional sets of Bidding Documents for prime contractor bidders, subcontractors, vendors or dealers may be obtained upon payment of said $300.00 deposit and signing a nondisclosure statement. This deposit shall be refunded less the costs of printing, reproduction, handling, and distribution, upon return of the documents in reusable condition within 10 days after the bid opening. Company check or Certified check for documents shall be made payable to The Water Works Board of the City of Birmingham, 3600 First Avenue North, Birmingham, Alabama, 35222 and mailed to the Attn: Hattye McCarroll P.E.; Chief Engineer. No additional charge will be made for delivery via UPS ground. Those requesting shipment of documents via carriers other than UPS ground will be made at the requesting firm’s expense. Partial sets of Bidding Documents will not be available to any Bidder. Neither the OWNER nor the ENGINEER will be responsible for full or partial sets of Bidding Documents, including any addenda, obtained from other sources. No Bidder may withdraw or alter a bid within 60 calendar days after the actual date of the bid opening.
A mandatory pre-bid conference and site visit will be held at 9:00 a.m. local time on Thursday, March 28, 2024 at the OWNER’s Cahaba Pump Station, located at 4012 Sicard Hollow Rd, Birmingham, AL 35243. All prospective Bidders and interested parties are required to attend the pre-bid conference. The purpose of the pre-bid conference is to raise questions pertaining to the Bidding and Contract documents and for the OWNER or its representatives to clarify any points. All Contractors shall complete and submit HUB Bid Solicitation Notice (HUB Form 3) no later than seven (7) days after the scheduled date of the pre-bid conference. This form may be submitted in person at the pre-bid conference. Bids will NOT BE ACCEPTED from any Prospective Bidder who does not attend the mandatory Pre-Bid Conference.
Each bid shall be accompanied by a cashier’s check, drawn on an Alabama Bank, or bid Bond in the amount of five percent (5%) of the bid not to exceed $50,000.00 in the form and subject to conditions provided for in the Specifications.
The successful Bidder will be required to furnish a Performance Bond and a Payment Bond each in an amount equal to 100 percent of the Contract Award.
Bidders shall comply with all statutory requirements in accordance with the Instructions to Bidders. Bids will only be received from Contractors who are licensed by the State of Alabama.
Contract time of commencement and completion will be in accordance with the Agreement.
The Water Works Board of the City of Birmingham (“BWWB”) has adopted a voluntary Historically Underutilized Business (“HUB”) Program designed to encourage the participation of HUB firms in construction projects. To that end, the BWWB will never exclude any firm from participation in, deny any person benefits of, or otherwise discriminate in connection with the award and performance of BWWB contracts based on racial, gender, social, or economic status.
It is the intent of the BWWB to foster competition among contractors, suppliers and vendors that will result in better quality and more economical services for the BWWB. Under this program, the BWWB has established a goal of 30% participation of HUB firms for services required for BWWB construction projects. The BWWB’s stated goal will not be the determining factor in construction contract awards; rather bidders must demonstrate compliance with the Good Faith Efforts, more particularly outlined in the HUB Program, toward meeting said goal.
Failure on the part of a bidder to fully submit the information required herein may be considered by the BWWB in evaluating whether the bidder is responsive to bid requirements.
Alabama Code §31-13-9 (1975) provides that as a condition for the award of any contract by The Water Works Board of the City of Birmingham, a business entity or employer that employs one or more employees within the state of Alabama shall provide documentation of enrollment in the E-Verify program.
Each Prospective Bidder must complete, as a condition for the award of any Contract by The Water Works Board of the City of Birmingham, the Certification Regarding Debarment in Section 00 20 10. The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).
Legislature of Alabama Act 2013-205 grants the Alabama Department of Revenue (ADOR) the authority to issue certificates of exemption from sales and use taxes for construction projects for certain governmental agencies. Pursuant to Act 2013-205, Section 1(g) the Contractor accounts for the sales tax not included in the Bid Form by submitting an Accounting of Sales Tax-Attachment to BWWB Bid Form. Failure to provide an accounting of sales tax shall render the bid non-responsive. Other than determining responsiveness, sales tax accounting shall not affect the bid pricing nor be considered in the determination of the lowest responsible and responsive bidder. After Notice of Award, Contractor and Subcontractor licensed by the State Licensing Board for General Contractors must comply with ADOR requirements for making an application for qualification of the exemption and are responsible for ADOR reporting requirements for the duration of the project.
If a Contract is to be awarded, it will be awarded to the Bidder with the best price on the best terms for the OWNER, who has neither been disqualified nor rejected pursuant to these Contract Documents, and whose Bid based on an evaluation by the OWNER indicates that the award will be in the best interest of the Project and will result in the lowest overall cost to the OWNER for completion of the project. If a Contract is to be awarded, it will be awarded within 90 calendar days after the day of the opening of bids.
The OWNER reserves the right to reject any and all proposals, the right to waive irregularities or to accept any proposal deemed to be in the best interest of the OWNER.
Owner:
The Water Works Board of the City of Birmingham
3600 First Avenue North
Birmingham, Alabama 35222
Hattye McCarroll, P.E
Telephone number (205) 244-4182
Engineer:
ARCADIS, U.S., Inc.
1143 1st Ave South, Suite 109
Birmingham, Alabama 35233
Mr. Dhiraj Parekh, P.E
Telephone number (205) 930-5956
Call News February 28, and March 6, 13, 20, 27, April 3, 10, 17, 24, 2024
|
ADVERTISEMENT FOR BIDS
Sealed proposals will be received by the Board of School Commissioners of Mobile County at the Purchasing Department, 1 Magnum Pass, Mobile, Alabama 36618 until 10:00 a.m. local time on Tuesday, March 26, 2024 in the Facilities Conference Room, Building F at which time and place they will be publicly opened and read for:
INDIAN SPRINGS ELEMENTARY SCHOOL CANOPY
MOBILE, ALABAMA
DCM #2023810
A cashier’s check or bid bond payable to the Board of School Commissioners of Mobile County in the amount not less than five (5) percent of the amount of the bid, but in no event more than $10,000 must accompany the bidder’s proposal. Performance and Payment Bonds and evidence of insurance required in the bid documents will be required at the signing of the Contract.
Drawings and specifications may be examined at the office of GOODWYN MILLS CAWOOD, LLC, 11 N. WATER STREET, SUITE 15250, MOBILE, AL 36602, (251) 460-4006, the Facilities Department, 1 Magnum Pass, Mobile, Alabama 36618, F.W. Dodge Plan Rooms in Montgomery and Birmingham, CMD Group, Document Processing Center, 30 Technology Parkway South, Suite 500, Norcross, GA 30092-2912, and through Skysite.
A Mandatory Pre-Bid Meeting is scheduled to be held at 10:00 a.m. local time, Tuesday, March 19, 2024 in the Facilities Conference Room, Building F, at MCPSS.
General Contractors may procure plans and specifications from Goodwyn Mills Cawood, LLC attn: Doris Furr at doris.furr@gmcnetwork.com upon payment of a deposit of Twenty dollars ($20.00) for a one time administrative fee for digital/file sharing access or Seventy Five dollars ($75.00) (printed) per set. Contractors are encouraged to use the digital plans. Refunds will be issued for printed sets only issued by the Architect to each general contract bidder on the first two (2) sets issued submitting a bonafide bid, upon return of documents in good and reusable condition within ten (10) days of bid date. Additional sets for General Contractors, and sets for subs and vendors, may be obtained with the same deposit, which will be refunded as above, less cost of printing, reproduction, handling and distribution, which is estimated to be the same as the deposit amount.
Bids must be submitted on proposal forms furnished by the Board of School Commissioners of Mobile County or copies thereof. All bidders bidding in amounts exceeding that established by the State Licensing Board for General Contractors must be licensed under the provisions of Title 34, Chapter 8, Code of Alabama, 1975, and must show evidence of license before bidding or bid will not be received or considered by the Architect. The bidder shall show such evidence by clearly displaying his or her current license number on the outside of the sealed envelope in which the proposal is delivered. The Owner reserves the right to reject any or all proposals and to waive technical errors if, in the Owner’s judgment, the best interests of the Owner will thereby be promoted.
BOARD OF SCHOOL COMMISSIONERS
OF MOBILE COUNTY
Call News March 3, March 10, and March 17, 2024
|
THE WATER WORKS BOARD OF
THE CITY OF BIRMINGHAM
Painting & Repairs to Warrior Potable Water Tank
Project Number: P.03508
Capital Budget Number: 1H
NOTICE TO BIDDERS
Sealed Bids for the Painting & Repairs to Warrior Potable Water Tank will be received by The Water Works Board of the City of Birmingham, Engineering Department, Attn: Hattye D. McCarroll, P.E.; Chief Engineer, until 10:00 a.m. local time on Thursday, March 14, 2024, in the Engineering Department Conference Room on the Second Floor of the Main Campus Building located at 3600 First Avenue, North in Birmingham, Alabama, at which time they will be opened and read. Bids received after said time will be rejected and returned unopened.
The Contractor shall provide all labor, materials, tools, equipment, and incidentals required to do all cleaning, silt removal inside tank, surface preparation, painting, and repairs including installing shell manholes, sampling system, sump pit inside, mixing system, roof ventilation covers, roof finial vents screens, drain valve, any repairs requiring welding, removal and replacement of foundation grout and caulk, cable climb system inside, refinishing of concrete surfaces, protection of all finished paint surfaces of the tank, and other miscellaneous associated items as necessary to complete the Work. It will be the responsibility of the contractor to maintain the roadway once the project is started. This Work includes all structural, sanitary, safety and repair items as instructed in the attached report in Appendix A.
Bidding Documents may be examined at the office of the BWWB Project Manager – Engineering Department – Mr. Tony Free, Project Engineer, The Water Works Board of the City of Birmingham, 3600 First Avenue, North, Birmingham, AL 35222.
Prime Contractor bidders may obtain one complete set of Bidding Documents from the office of the Chief Engineer of The Water Works Board of the City of Birmingham upon payment of $250.00 deposit by company check or by certified check and signing a nondisclosure statement. No personal checks or any other form of payment except as noted will be accepted. This deposit shall be refunded in full to each prime contractor bidder upon the return of the Bidding Documents and drawings in a reusable condition within 10 days after the bid opening. Additional sets of Bidding Documents for prime contractor bidders, subcontractors, vendors, or dealers may be obtained upon payment of said $250.00 deposit and signing a nondisclosure statement. This deposit shall be refunded less the costs of printing, reproduction, handling, and distribution, upon return of the documents in reusable condition within 10 days after the bid opening. Company check or Certified check for documents shall be made payable to The Water Works Board of the City of Birmingham, 3600 First Avenue North, Birmingham, Alabama, 35222 and mailed to the Attn: Ms. Hattye McCarroll. P.E.; Chief Engineer. No additional charge will be made for delivery via UPS ground. Those requesting shipment of documents via carriers other than UPS ground will be made at the requesting firm’s expense. Partial sets of Bidding Documents will not be available to any Bidder. Neither the OWNER nor the ENGINEER will be responsible for full or partial sets of Bidding Documents, including any addenda, obtained from other sources. No Bidder may withdraw or alter his bid within sixty (60) calendar days after the actual date of the Bid Opening.
A Mandatory Pre-Bid Conference and Site Visit will be held at 10:00 a.m. local time on Thursday, February 29, 2024 in the Engineering Department Conference Room located as shown above. After a short pre-bid meeting, a site visit will follow at the Warrior Tank, 301 10th Street West, Warrior, Alabama 35180. All Prospective Bidders are required to attend the Pre-Bid Conference and site visit. The purpose of the Pre-Bid Conference is to raise questions pertaining to the Bidding Documents and Contract Documents and for the OWNER or its representatives to clarify any points. Bids will NOT BE ACCEPTED from any Prospective Bidder who does not attend the Pre-Bid Conference and site visit. All Prospective Bidders must complete and include the HUB Resource Engagement Form (HUB Form 3) with their sealed bid (NO EXCEPTIONS). HUB Program Acknowledgement (HUB Form 1), HUB Compliance Form (HUB Form 2), HUB Subcontractor Performance Form (HUB Form 5) and HUB Subcontractor Utilization Form (HUB Form 6) of Section 00451 HUB Program must be submitted at the Bid Opening as shown above.
Each bid shall be accompanied by a cashier’s check, drawn on an Alabama Bank, or Bid Bond in the amount of five percent (5%) of the bid not to exceed $10,000.00 in the form and subject to conditions provided for in the Specifications.
The Successful Bidder will be required to furnish a Performance Bond and a Labor & Material Payment Bond each in an amount equal to one hundred percent (100%) of the Contract Award.
Bidders shall comply with all statutory requirements in accordance with the Instruction to Bidders. Bids will only be received from Contractors who are licensed by the State of Alabama.
Contract time of commencement and completion will be in accordance with the Agreement.
The Water Works Board of the City of Birmingham (“BWWB”) has adopted a voluntary Historically Underutilized Business (“HUB”) Program designed to encourage the participation of HUB firms in construction projects. To that end, the BWWB will never exclude any firm from participation in, deny any person benefits of, or otherwise discriminate in connection with the award and performance of BWWB contracts based on racial, gender, social, or economic status.
It is the intent of the BWWB to foster competition among contractors, suppliers and vendors that will result in better quality and more economical services for the BWWB. Under this program, the BWWB has established a goal of 30% participation of HUB firms for services required for BWWB construction projects. The BWWB’s stated goal will not be the determining factor in construction contract awards; rather bidders must demonstrate compliance with the Good Faith Efforts, more particularly outlined in the HUB Program, toward meeting said goal.
Failure on the part of a bidder to fully submit the information required herein may be considered by the BWWB in evaluating whether the bidder is responsive to bid requirements.
Alabama Code §31-13-9 (1975) provides that as a condition for the award of any contract by The Water Works Board of the City of Birmingham, a business entity or employer that employs one or more employees within the state of Alabama shall provide documentation of enrollment in the E-Verify program.
Each Prospective Bidder must complete, as a condition for the award of any Contract by The Water Works Board of the City of Birmingham, the Certification Regarding Debarment in Section 00201. The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).
Legislature of Alabama Act 2013-205 grants the Alabama Department of Revenue (ADOR) the authority to issue certificates of exemption from sales and use taxes for construction projects for certain governmental agencies. Pursuant to Act 2013-205, Section 1(g) the Contractor accounts for the sales tax not included in the Bid Form by submitting an Accounting of Sales Tax-Attachment to BWWB Bid Form. Failure to provide an accounting of sales tax shall render the bid non-responsive. Other than determining responsiveness, sales tax accounting shall not affect the bid pricing nor be considered in the determination of the lowest responsible and responsive bidder. After Notice of Award, Contractor and Subcontractor licensed by the State Licensing Board for General Contractors must comply with ADOR requirements for making application for qualification of the exemption and are responsible for ADOR reporting requirements for the duration of the project.
If a Contract is to be awarded, it will be awarded to the lowest responsive and responsible Bidder, who has neither been disqualified nor rejected pursuant to these Contract Documents, and whose Bid based on an evaluation by the OWNER indicates that the award will be in the best interest of the Project and will result in the lowest overall cost to the OWNER for completion of the project. If a Contract is to be awarded, it will be awarded within 60 calendar days after the day of the opening of bids.
The OWNER reserves the right to reject any and all proposals, the right to waive irregularities or to accept any proposal deemed to be in the best interest of the OWNER.
Owner:
The Water Works Board of the City of Birmingham (BWWB)
3600 First Avenue North
Birmingham, Alabama 35222
Hattye D. McCarroll, P.E., Chief Engineer
Telephone: (205) 244-4182
Owner’s Contact for Plans and Specifications
Engineering Department Administrative Assistant
Telephone: (205) 244-4180
Facsimile: (205) 244-4680
Owner’s Project Manager:
Primary Contact:
Mr. Tony Free
Project Engineer
Telephone: (205) 244-4288
E-mail: Tony.Free@bwwb.org
Call News February 14, 21, 28, and March 6, 13, 20, 2024
|
THE WATER WORKS BOARD OF
THE CITY OF BIRMINGHAM
Painting & Repairs to Cahaba Cove Potable Water Tank
Project Number: P.03507
Capital Budget Number: 1H
NOTICE TO BIDDERS
Sealed Bids for the Painting & Repairs to Cahaba Cove Potable Water Tank will be received by The Water Works Board of the City of Birmingham, Engineering Department, Attn: Hattye D. McCarroll, P.E.; Chief Engineer, until 10:00 a.m. local time on Thursday, March 14, 2024, in the Engineering Department Conference Room on the Second Floor of the Main Campus Building located at 3600 First Avenue, North in Birmingham, Alabama, at which time they will be opened and read. Bids received after said time will be rejected and returned unopened.
The Contractor shall provide all labor, materials, tools, equipment, and incidentals required to do all cleaning, silt removal inside tank, surface preparation, painting, replacement of interior ladder rungs, relocation of the interior portion of the overflow pipe to the tank exterior, and repairs including installing roof ventilation cover, roof finial vents screens, any repairs requiring welding, removal and replacement of foundation grout and caulk, new cable climb system inside and outside, refinishing of concrete surfaces, protection of all finished paint surfaces of the tank, and other miscellaneous associated items as necessary to complete the Work. It will be the responsibility of the contractor to maintain the roadway once the project is started.
This Work includes all structural, sanitary, safety and repair items as instructed in the attached report in Appendix A. In this attached report, regarding the Repair item #2 listed on page 5, the contractor is to leave the antenna in place and is not to remove or repair this item. Regarding the sampling system currently installed on this tank, only the existing sample lines should be replaced in the riser pipe. Please see the attached drawings in Appendix A for further information regarding this item.
Bidding Documents may be examined at the office of the BWWB Project Manager – Engineering Department – Mr. Tony Free, Project Engineer, The Water Works Board of the City of Birmingham, 3600 First Avenue, North, Birmingham, AL 35222.
Prime Contractor bidders may obtain one complete set of Bidding Documents from the office of the Chief Engineer of The Water Works Board of the City of Birmingham upon payment of $250.00 deposit by company check or by certified check and signing a nondisclosure statement. No personal checks or any other form of payment except as noted will be accepted. This deposit shall be refunded in full to each prime contractor bidder upon the return of the Bidding Documents and drawings in a reusable condition within 10 days after the bid opening. Additional sets of Bidding Documents for prime contractor bidders, subcontractors, vendors, or dealers may be obtained upon payment of said $250.00 deposit and signing a nondisclosure statement. This deposit shall be refunded less the costs of printing, reproduction, handling, and distribution, upon return of the documents in reusable condition within 10 days after the bid opening. Company check or Certified check for documents shall be made payable to The Water Works Board of the City of Birmingham, 3600 First Avenue North, Birmingham, Alabama, 35222 and mailed to the Attn: Ms. Hattye McCarroll. P.E.; Chief Engineer. No additional charge will be made for delivery via UPS ground. Those requesting shipment of documents via carriers other than UPS ground will be made at the requesting firm’s expense. Partial sets of Bidding Documents will not be available to any Bidder. Neither the OWNER nor the ENGINEER will be responsible for full or partial sets of Bidding Documents, including any addenda, obtained from other sources. No Bidder may withdraw or alter his bid within sixty (60) calendar days after the actual date of the Bid Opening.
A Mandatory Pre-Bid Conference and Site Visit will be held at 10:00 a.m. local time on Thursday, February 29, 2024 in the Engineering Department Conference Room located as shown above. After a short pre-bid meeting, a site visit will follow at the Cahaba Cove Tank, 106 Pine Bluff Trail, Trussville, Alabama 35173. All Prospective Bidders are required to attend the Pre-Bid Conference and site visit. The purpose of the Pre-Bid Conference is to raise questions pertaining to the Bidding Documents and Contract Documents and for the OWNER or its representatives to clarify any points. Bids will NOT BE ACCEPTED from any Prospective Bidder who does not attend the Pre-Bid Conference and site visit. All Prospective Bidders must complete and include the HUB Resource Engagement Form (HUB Form 3) with their sealed bid (NO EXCEPTIONS). HUB Program Acknowledgment (HUB Form 1), HUB Compliance Form (HUB Form 2), HUB Subcontractor Performance Form (HUB Form 5) and HUB Subcontractor Utilization Form (HUB Form 6) of Section 00451 HUB Program must be submitted at the Bid Opening as shown above.
Each bid shall be accompanied by a cashier’s check, drawn on an Alabama Bank, or Bid Bond in the amount of five percent (5%) of the bid not to exceed $10,000.00 in the form and subject to conditions provided for in the Specifications.
The Successful Bidder will be required to furnish a Performance Bond and a Labor & Material Payment Bond each in an amount equal to one hundred percent (100%) of the Contract Award.
Bidders shall comply with all statutory requirements in accordance with the Instruction to Bidders. Bids will only be received from Contractors who are licensed by the State of Alabama.
Contract time of commencement and completion will be in accordance with the Agreement.
The Water Works Board of the City of Birmingham (“BWWB”) has adopted a voluntary Historically Underutilized Business (“HUB”) Program designed to encourage the participation of HUB firms in construction projects. To that end, the BWWB will never exclude any firm from participation in, deny any person benefits of, or otherwise discriminate in connection with the award and performance of BWWB contracts based on racial, gender, social, or economic status.
It is the intent of the BWWB to foster competition among contractors, suppliers and vendors that will result in better quality and more economical services for the BWWB. Under this program, the BWWB has established a goal of 30% participation of HUB firms for services required for BWWB construction projects. The BWWB’s stated goal will not be the determining factor in construction contract awards; rather bidders must demonstrate compliance with the Good Faith Efforts, more particularly outlined in the HUB Program, toward meeting said goal.
Failure on the part of a bidder to fully submit the information required herein may be considered by the BWWB in evaluating whether the bidder is responsive to bid requirements.
Alabama Code §31-13-9 (1975) provides that as a condition for the award of any contract by The Water Works Board of the City of Birmingham, a business entity or employer that employs one or more employees within the state of Alabama shall provide documentation of enrollment in the E-Verify program.
Each Prospective Bidder must complete, as a condition for the award of any Contract by The Water Works Board of the City of Birmingham, the Certification Regarding Debarment in Section 00201. The Certification must be complete in its entirety and must be included with the Prospective Bidder’s Bid (NO EXCEPTIONS).
Legislature of Alabama Act 2013-205 grants the Alabama Department of Revenue (ADOR) the authority to issue certificates of exemption from sales and use taxes for construction projects for certain governmental agencies. Pursuant to Act 2013-205, Section 1(g) the Contractor accounts for the sales tax not included in the Bid Form by submitting an Accounting of Sales Tax-Attachment to BWWB Bid Form. Failure to provide an accounting of sales tax shall render the bid non-responsive. Other than determining responsiveness, sales tax accounting shall not affect the bid pricing nor be considered in the determination of the lowest responsible and responsive bidder. After Notice of Award, Contractor and Subcontractor licensed by the State Licensing Board for General Contractors must comply with ADOR requirements for making application for qualification of the exemption and are responsible for ADOR reporting requirements for the duration of the project.
If a Contract is to be awarded, it will be awarded to the lowest responsive and responsible Bidder, who has neither been disqualified nor rejected pursuant to these Contract Documents, and whose Bid based on an evaluation by the OWNER indicates that the award will be in the best interest of the Project and will result in the lowest overall cost to the OWNER for completion of the project. If a Contract is to be awarded, it will be awarded within 60 calendar days after the day of the opening of bids.
The OWNER reserves the right to reject any and all proposals, the right to waive irregularities or to accept any proposal deemed to be in the best interest of the OWNER.
Owner:
The Water Works Board of the City of Birmingham (BWWB)
3600 First Avenue North
Birmingham, Alabama 35222
Hattye D. McCarroll, P.E., Chief Engineer
Telephone: (205) 244-4182
Owner’s Contact for Plans and Specifications
Engineering Department Administrative Assistant
Telephone: (205) 244-4180
Facsimile: (205) 244-4680
Owner’s Project Manager:
Primary Contact:
Mr. Tony Free
Project Engineer
Telephone: (205) 244-4288
E-mail: Tony.Free@bwwb.org
Call News February 14, 21, 28, and March 6, 13, 20, 2024
|
STATE OF ALABAMA
DEPARTMENT OF REVENUE
COLLECTION SERVICES DIVISION
INVITATION FOR BIDS FOR THE SALE OF PROPERTY
LOCATED IN MOBILE COUNTY, ALABAMA
Notice is hereby given pursuant to Section 40-29-23(b), Code of Alabama 1975, that the Alabama Department of Revenue is accepting sealed bids for the sale of the following real properties described below, acquired as a result of a Sheriff’s Sale. Sealed bids shall be submitted online at: https://www.ebuy.alabama.gov, until the closing date and time of 11:59 p.m., Friday, March 29, 2024, at which time all bids will be opened and read in the Collection Services Division. Bids will not be accepted after the above stated date and time.
Description of property offered:
A PORTION LOT 35 HILLVIEW PARK ADD MBK 3 PG 532 BEING DESC AS FOLL COMG AT NW COR SD LOT 35 PT ALSO BEING ON E ROW/L OF MYERS RD TH RUN SLY & ALG E ROW/L OF MYERS 100 FT TO POB TH CONT SLY & ALG E ROW LINE OF MYERS RD 100 FT TH ON INT ANG OF 87 DEG 35 MIN RUN ELY 225 FT TH NLY & PAR WITH MYERS RD 100 FT TH WLY 225 FT TO POB #SEC 24 T3S R2W #MP23 06 24 3 001
The property is located at or near 5012 Myers Rd Eight Mile, AL 36613; Parcel Identification Number: 23-06-24-3-001-064.000; as described in Sheriff’s Deed Real Property Book 4728, Page 1769-1770.
The parcels are being offered “as is” and “where is” without recourse against the State of Alabama Department of Revenue. It is the responsibility of the bidder to inspect the property conditions before submitting a bid by drive-by only, without trespassing on the property in any manner. Bidders must agree to all terms listed online before submitting a bid. If you wish to bid on this property, please complete the Sealed Bid Form online.
The minimum bid for this parcel is $5,000.
EACH bid submitted online must be accompanied by an EFT bid deposit payment of ten percent (10%) of the total amount of the bid. Any bid submitted without payment of the bid deposit will not be considered. The deposits of unsuccessful bidders will be returned following the bid closing date.
NO BID SHALL BE RECEIVED FOR ANY REASON ANY TIME AFTER THE ADVERTISED DEADLINE. IT SHALL BE THE SOLE RESPONSIBILITY OF THE BIDDER TO ENSURE ACTUAL RECEIPT OF THE BID BY THE COLLECTION SERVICES DIVISION PRIOR TO THE ADVERTISED DEADLINE.
The Alabama Department of Revenue reserves the right to withdraw the property from sale at any time and the right to reject any or all bids.
For more information about the sale contact:
Alabama Department of Revenue
Collection Services Division-Sealed Bid Sale
P. O. Box 327820
Montgomery, AL 36132-7820
Telephone: (334) 242-1229
Call News March 6, 13, 20, 2024
|
Divorce
IN THE CIRCUIT COURT OF
MOBILE COUNTY ALABAMA
DOMESTIC RELATIONS DIVISION
NOTICE OF DIVORCE ACTION
CASE NO. 02-DR-2023-901381.00S
Rochelle Logan Harris, Plaintiff
Vs
Kerry Renard Harris, Defendant
Kerry Renard Harris, (Defendant), whose whereabouts is unknown, must answer the
Plaintiff’s Petition for Divorce and other relief by May 6, 2024 or, thereafter, a Judgment
of default may be rendered against him/her in the above styled case. The defendant’s written answer must be filed with the court and a copy mailed to the plaintiff’s attorney of record at the
address provided below.
Done this February 29, 2024
SHARLA KNOX, CIRCUIT CLERK
s/Sharla_Knox
ATTY: Shelia W. Goodwin, Esq.
853 Cammack Road
Birmingham, AL 35211
(205) 568-9251
sheliagoodwin@icloud.com
Call News March 13, 20, 27, and April 3, 2024
|
IN THE CIRCUIT COURT OF
MOBILE COUNTY, ALABAMA
DOMESTIC RELATIONS DIVISION
NOTICE OF DIVORCE ACTION
CASE NO. DR 2024-900103.00 WHH
VICKI SUE STERLING SERAFIN-ZAMBRANO, Plaintiff
vs.
DIEGO SERAFIN-ZAMBRANO, Defendant
DIEGO SERAFIN-ZAMBRANO, (Defendant), whose whereabouts is unknown, must answer the plaintiff’s Petition for Divorce and other relief by April 29, 2024 or, thereafter, a Judgment by Default may be rendered against him/her in the above styled case. The Defendant’s written answer must be filed with the Court and a copy mailed to the Plaintiff’s attorney of record at the address provided below.
Done this 14th day of February, 2024.
Sharla Knox, Circuit Clerk
Attorney for plaintiff:
Thomas F. Monk
1111 Easts I-65 Service Rd. S Suite 112
Mobile, AL 36606
monk@mobileattorney.net
Call News March 6, 13, 20, 27, 2024
|
Complaint
IN THE CIRCUIT COURT OF
MOBILE COUNTY, ALABAMA
02-CV-2023-900759
TEMEKO SANDERS, Plaintiff,
v.
MARK WRIGHT, et al., Defendants.
PUBLICATION NOTICE
To: Mark Wright
Address Unknown
You are hereby notified that Tameko Sanders has filed a complaint on April 24, 2023 in the Mobile County Circuit Court against Mark Wright (“Defendant”). The lawsuit concerns a car accident that occurred in Mobile County on May 19, 2021. Numerous attempts to locate the Defendant have been unsuccessful.
This notice is to run for four consecutive weeks. Mark Wright is hereby notified that he must answer the complaint by the 13th day of April, 2024, which is 30 days from the last date of publication. The answer must be filed with the Clerk of the Mobile County Circuit Court or a judgment by default may be rendered against Mark Wright.
Done this 16th day of February, 2024.
S/ Sharla Knox
Clerk of the Mobile County Circuit Court
/s/ Robert A. Arnwine, Jr.
Robert A. Arnwine (ASB-5964-B65A)
Morgan & Morgan Alabama PLLC
2 South Water Street, Ste 200
Mobile, AL 36602
T: 659.204.6364
F: 659.204.6389
rarnwine@forthepeople.com
Counsel For Plaintiff
Call News February 28, and March 6, 13, 20, 2024
|
NOTICE OF PUBLICATION
IN THE CIRCUIT COURT OF
MOBILE COUNTY, ALABAMA
Civil Action No. CV-2023-902514
GULF WINDS CREDIT UNION, Plaintiff
vs.
BREATTA CRUM, Defendant.
NOTICE OF PUBLICATION
To: Breatta Crum, Defendant named above
You are hereby notified that the above-styled action seeking a judgment against the Defendant, Breatta Crum, was filed against you in said court on November 28, 2023, and that by reason of an order for service of summons by publication entered by the court on February 21, 2024, you are hereby commanded and required to file with the clerk of said court and serve upon Joshua D. Friedman, Esquire, whose address is Post Office Box 2767, Mobile, Alabama 36652, an answer to the complaint within thirty (30) days of the last date of publication, to-wit: by the 1st day of May, 2024
Sharla Knox, Clerk of Court
s/ Sharla Knox
March 6th, 2024
Michelle C. Wells, Assistant to
150 Government Street, Suite 2000
Mobile, Alabama 36602
(251) 432-5521; (251) 432-0633 (fax)
mcw@helmsinglaw.com
Call News March 13, 20, 27, and April 3, 2024
|
NOTICE OF HEARING
IN THE CIRCUIT COURT OF
MOBILE COUNTY ALABAMA
DOMESTIC RELATIONS DIVISION
NOTICE OF HEARING MOTION
CASE NO 02-DR 2011-500793.05 WHH
KARTARIUS D. JOHNSON, Plaintiff
Vs
ALLEAN J. WALLACE, Defendant
Notice is hereby given to KARTARIUS D. JOHNSON, whose whereabouts is unknown, that a hearing on the REQUEST TO AMEND DIVORCE DECREE AND WAIVE PARENTAL RIGHTS filed by ALLEAN J. WALLCE will be heard in the Domestic Relations Court, 2nd Floor, Mobile Government Plaza, 205 Government Street, Mobile Alabama, on TBD 2024 at 9:00 A.M. at which time said KARTARIUS D. JOHNSON is to appear.
Done this 21st day of FEBRUARY, 2024.
s/Sharla Knox
SHARLA KNOX, CIRCUIT CLERK
ATTY: ALLEAN J. WALLACE (PRO SE)
PSC 851 BOX 1642
FPO, AE 09834
TELEPHONE (904) 624-9582
Attorney for: PRO SE
E-MAIL: alleanjwallace@gmail.com
Call News March 13, 20, 27 and April 3, 2024
|
NOTICE OF PENDING ACTION
IN THE CIRCUIT COURT OF
MOBILE COUNTY, ALABAMA
02-CV-2024-900456
CARL MATTSON, JR. and CONNIE R. MATTSON, Plaintiff
V.
ONE ACRE IN THE NORTHEAST CORNER OF THE EAST HALF OF NORTHWEST QUARTER OF THE SOUTHEAST QUARTER OF SECTION 8, TOWNSHIP 3 SOUTH, RANGE 4 WEST; Key No. 11550066; Parcel No. R02-25-03-08-0-000-051.000 Property Address: 5251 Albert Evans Road, Wilmer, Alabama 36587 and ROY CLAYTON GOULD, KATHY GOULD, and FICTITIOUS DEFENDANTS A, B, C, D, E, and F, being the heirs at law of DORA BOOKER a/k/a DORA L. COLWELL, DECEASED, and being those persons or entities who may claim an interest in that
certain real property located in Mobile County, Alabama, being more particularly described above,
whose identities are unknown to the Plaintiff, but who will be added by amendment when ascertained, Defendants.
NOTICE OF PENDING ACTION
NOTICE TO DEFENDANTS OF COMPLAINT ISSUED OUT OF THE CIRCUIT COURT OF MOBILE COUNTY, ALABAMA – CASE NUMBER CV-2024-900456, CARL MATTSON, JR. and CONNIE R. MATTSON v. PARCELS OF REAL PROPERTY SITUATED IN MOBILE COUNTY, ALABAMA – ONE ACRE IN THE NORTHEAST CORNER OF THE EAST HALF OF NORTHWEST QUARTER OF THE SOUTHEAST QUARTER OF SECTION 8, TOWNSHIP 3 SOUTH, RANGE 4 WEST, and ROY CLAYTON GOULD and KATHY GOULD, and FICTITIOUS DEFENDANTS A, B, C, D, E & F, being the heirs and next of kin of DORA BOOKER a/k/a DORA L. COLWELL, DECEASED, and those persons or entities who may claim an interest in the property described above (PARCEL ID NO. R02-25-03-08-0-000-051.000, KEY NO. 11550066.
NOTICE is hereby given in the above-entitled cause on the 21st day of February, 2024, the above-named Plaintiffs filed in said Circuit Court, a cause of action against the above-named Defendants for ejectment and to quiet the title to the above-described real property in favor of the Plaintiffs, extinguishing any rights of the Defendants in and to the real property.
NOW THEREFORE, any person claiming an interest in and to the above-described real property is hereby commanded to answer to or plead by March 22, 2024 to the Complaint filed the above-entitled case or suffer the entry of a default judgment.
WITNESS my hand on this the 22nd day of February 2024.
ATTEST
/s SHARLA KNOX
CLERK OF THE CIRCUIT COURT
OF MOBILE COUNTY, ALABAMA
/s DAVID VAUGHN
DAVID VAUGHN, ESQ.
Attorney for the Plaintiffs
Post Office Box 1678
Daphne, Alabama 36526
(251)626-2688
dpvlaw@bellsouth.net
Call News February 28, and March 6, 13, 20, 2024
|
NOTICE OF PUBLICATION
IN THE DISTRICT COURT OF
MOBILE COUNTY
STATE OF ALABAMA
CASE NO.: DV-2023-903106
LISA MEEKS and JAY MEEKS
v.
CM AUTOMOTIVE and CHARLES ARTHUR
NOTICE OF SERVICE BY PUBLICATION
TO: CM AUTOMOTIVE and CHARLES ARTHUR.
Take notice that a Complaint has been filed against you in the District Court of Mobile
County, Alabama, in the case styled, “Lisa Meeks and Jay Meeks v. CM Automotive and Charles Arthur”, Case No. DV-2023-903106.
You must file an answer to said Complaint on or before thirty (30) days from the date of the last publication of this Notice or a default judgment will be taken against you. Your answer must be mailed to Lisa Meeks and Jay Meeks, 1000 Creekstone Drive, Mobile, AL 36608 and filed with the Court.
Dated this 11th day of March 2024.
Call News March 13, 20, 27, and April 3, 2024
|
BREACH OF CONTRACT
LEGAL NOTICE
District Court of Alabama,
Mobile County
Case No. DV-2023-901968
ONEMAIN FINANCIAL GROUP, LLC, Plaintiff
VS
LEBARON C FOSTER ALLEN, Defendant
Claim: $9,308.28 plus interest, costs and attorney fees For: BREACH OF CONTRACT/OPEN ACCOUNT
Affidavit having been filed herein that service of process cannot be made because either the residence of defendants are unknown and cannot with reasonable diligence be ascertained, or, the identity of defendant is unknown, or, the resident defendant has been absent for more than thirty days since the filing of this suit, or that defendant avoids service and avers facts showing such avoidance.
Now therefore said defendants are hereby commanded within thirty days after the last publication hereof to plead to the said complaint.
Issued: 2/26/24
Sharla Knox, Clerk, District Court
Mobile County, Alabama
Tiffany B. Smith
McPhail Sanchez, LLC
126 Government Street
Mobile, AL 36602
251-438-2333
Call News March 6, 13, 20, 27, 2024
|
LEGAL NOTICE
DISTRICT COURT OF ALABAMA,
MOBILE COUNTY
CASE NO. DV-2023-904485
Pen Air Credit Union, PLAINTIFF
vs
Jacob B. Roberts, DEFENDANT
CLAIM: $ 18,563.07
FOR: Breach of Contract
Affidavit having been filed herein that service of process cannot be made because either the residence of defendant is unknown, and cannot with reasonable diligence be ascertained or the identity of defendant is unknown or the resident defendant has been absent for more than thirty days since the filing of this suit, or that defendant avoids service and avers facts showing such avoidance.
NOW, THEREFORE, SAID DEFENDANT IS HEREBY COMMANDED WITHIN THIRTY DAYS AFTER THE LAST PUBLICATION HEREOF TO PLEAD TO THE SAID COMPLAINT.
ISSUED: February 20, 2024
Sharla Knoxx, Clerk, District Court of Alabama, Mobile County
Attorney for the Plaintiff:
Josuah D. Friedman
Post Office Box 2767
Mobile, Alabama 36652
Call News February 28, and March 6, 13, 20, 2024
|
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed on April 29, 2011 by Rufus C Butler and Doris L Butler, husband and wife, originally in favor of Wells Fargo Bank, N.A., and recorded in 6774 at 1538 on May 4, 2011, in the Office of the Judge of Probate of Mobile County, Alabama. LOGS Legal Group LLP, as counsel for Mortgagee or Transferee and under and by virtue of power of sale contained in the said mortgage will, on May 1, 2024, sell at public outcry to the highest bidder at the main entrance of the Mobile County, Alabama, Courthouse in the City of Mobile, during the legal hours of sale, the following real estate situated in Mobile County, Alabama, to wit:
Lot 29, Knollwood, Unit One, according to the plat thereof recorded in Map Book 29, Page 55, of the records in the Office of the Judge of Probate, Mobile County, Alabama.
For informational purposes only, the property address is: 7217 Knollwood Road, Mobile, AL 36619-7225.
Any property address provided is not part of the legal description of the property sold herein and in the event of any discrepancy, the legal description referenced herein shall control.
This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. Furthermore, the property to be offered pursuant to this notice of sale is being offered for sale, transfer and conveyance AS IS, WHERE IS. Neither the mortgagee, nor the officers, directors, attorneys, employees, agents or authorized representative of the mortgagee make any representation or warranty relating to the title or any physical, environmental, health or safety conditions existing in, on, at or relating to the property offered for sale. Any and all responsibilities or liabilities arising out of or in any way relating to any such condition, including those suggested by Code of Ala. (1975) § 35-4-271, expressly are disclaimed. This sale is subject to all prior liens and encumbrances and unpaid taxes and assessments including any transfer tax associated with the foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars and no/100 ($5,000.00) in certified or cash funds at the time and place of the sale. The balance of the purchase price must be paid in certified funds by close of business on the next business day thereafter at the Law Office of LOGS Legal Group LLP at the address indicated below. LOGS Legal Group LLP reserves the right to award the bid to the next highest bidder, or to reschedule the sale, should the highest bidder fail to timely tender the total amount due.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
Wells Fargo Bank, N.A., and its successors and assigns
Mortgagee or Transferee
LOGS LEGAL GROUP LLP
10130 Perimeter Parkway, Suite 400
Charlotte, NC 28216
(704) 333-8107/ 24-023679
Attorneys for Mortgagee or Transferee
Call News March 20, 2024 and March 27, 2024 and April 3, 2024
|
NOTICE OF FORECLOSURE SALE
MOBILE COUNTY
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Jacob Collin Johnson, unmarried and Emma Victoria Wages, unmarried originally in favor of Navy Federal Credit Union on July 30, 2020, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, Instrument Number 2020045842; the undersigned Navy Federal Credit Union, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash or certified funds, in front of the main entrance of the Courthouse at Mobile County, Alabama, on April 23, 2024, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:
Commencing at the point where the Southeast line of Natchez Road intersects the South line of the Northeast Quarter of Section 8, Township 3 South, Range 4 West, thence Eastwardly, along the South line of the Northeast Quarter of the said Section 8, a distance of 1,267.34 feet to the West line of Albert Evans Road, thence North 00 degrees 24 minutes 25 seconds East, along the West line of said road, 412.50 feet to the point of beginning of the property herein described; thence North 89 degrees 35 minutes 35 seconds West, a distance of 276.58 feet, thence North 45 degrees 00 minutes East, a distance of 393.95 feet to the West line of the said Albert Evans Road, thence South 00 degrees 24 minutes 25 seconds West, along the West line of the said road, 280.54 feet to the point of beginning.
Property street address for informational purposes: 5321 Albert Evans Rd S Wilmer, AL 36587
THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, SUBJECT TO ANY EASEMENTS, ENCUMBRANCES, AND EXCEPTIONS REFLECTED IN THE MORTGAGE AND THOSE CONTAINED IN THE RECORDS OF THE OFFICE OF THE JUDGE OF PROBATE OF THE COUNTY WHERE THE ABOVE-DESCRIBED PROPERTY IS SITUATED. THIS PROPERTY WILL BE SOLD WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender cash or certified funds made payable to Aldridge Pite, LLP at the time and place of the sale. Aldridge Pite, LLP reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Navy Federal Credit Union, Mortgagee/Transferee ALDRIDGE PITE, LLP Six Piedmont Center 3525 Piedmont Road, N.E., Suite 700 Atlanta, GA 30305. Attorney for Mortgagee/Transferee.
THIS OFFICE IS ACTING AS A DEBT COLLECTOR AND IS ATTEMPTING TO COLLECT A DEBT. ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
Call News 3/20/2024, 3/27/2024, 4/3/2024
|
NOTICE OF
MORTGAGE FORECLOSURE SALE
STATE OF ALABAMA
COUNTY OF MOBILE
Default having been made of the terms of the loan documents secured by that certain mortgage executed by Dexin J Hensley And Jennifer Hensley, Husband And Wife, to Mortgage Electronic Registration Systems, Inc., as mortgagee, as nominee for Embrace Home Loans, Inc., its successors and assigns dated January 28, 2020; said mortgage being recorded on January 29, 2020, as Instrument No. 2020005692 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to Embrace Home Loans, Inc. in Instrument 2022007021 in the Office of the Judge of Probate of Mobile County, ALABAMA.
The undersigned, Embrace Home Loans, Inc., under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 26th day of April, 2024 the following property, situated in Mobile County, Alabama, to-wit:
LOT 8 PENNINGTON PLACE, ACCORDING TO THE PLAT THEREOF RECORDED IN MAP BOOK 93, PAGE 54 OF THE RECORDS, IN THE OFFICE OF THE JUDGE OF PROBATE OF MOBILE COUNTY, ALABAMA.
Said property is commonly known as 6995 Walther Rd, Grand Bay, AL 36541.
Should a conflict arise between the property address and the legal description the legal description will control.
Said property will be sold subject to any outstanding ad valorem taxes (including taxes which are a lien, but not yet due and payable), the right of redemption of any taxing authority, all outstanding liens for public utilities which constitute liens upon the property, any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, easements, rights-of-way, zoning ordinances, restrictions, special assessments, covenants, the statutory right of redemption pursuant to Alabama law, and any matters of record including, but not limited to, those superior to said Mortgage first set out above. Said property will be sold on an “as-is” basis without any representation, warranty or recourse against the above-named or the undersigned. The successful bidder must present certified funds in the amount of the winning bid at the time and place of sale.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The sale will be conducted subject (1) to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and (2) to final confirmation and audit of the status of the loan with the holder of the Mortgage.
EMBRACE HOME LOANS, INC.
as holder of said mortgage
McCalla Raymer Leibert Pierce, LLC
Two North Twentieth
2 20th Street North, Suite 1000
Birmingham, AL 35203
(205) 216-4238
FT21@mccalla.com
File No. 24-05646AL
www.foreclosurehotline.net
Call News 03/20/2024,03/27/2024,04/03/2024
|
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Amy M. Todd, an unmarried female, originally in favor of Mortgage Electronic Registration Systems, Inc., solely as nominee for Embrace Home Loans, Inc., on August 24, 2021, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Instrument Number 2021056842; the undersigned MSR Asset Vehicle LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on May 1, 2024, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 24, Burma Hills, Unit 2, according to plat thereof recorded in Map Book 16, Page 44 of the records in the Office of the Judge of Probate of Mobile County, Alabama.. Property street address for informational purposes: 2304 Burma Hills Dr , Mobile, AL 36693. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. MSR Asset Vehicle LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 24-02139-PH-AL
Call News 03/20/2024, 03/27/2024, 04/03/2024
|
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Sylvester Bryant, Jr., Marie Bryant, husband and wife, originally in favor of Mortgage Electronic Registration Systems, Inc., as nominee for SouthStar Funding, LLC, on March 13, 2006, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 5938 Page 1983; the undersigned U.S. Bank Trust Company, National Association, as trustee, as successor-in-interest to U.S. Bank National Association, as successor in interest to Bank of America National Association, successor by merger to LaSalle Bank National Association, as Trustee for GSAMP Trust 2006-HE4, Mortgage Pass-Through Certificates, Series 2006-HE4, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on May 1, 2024, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 34, in Block 10 of Glendale Subdivision of Prichard, according to a map thereof recorded in Map Book 2, Page 55, of the records in the Office of the Judge of Probate, Mobile County, Alabama, and more particularly described as follows: Being bounded by a line beginning at a point on the North side of Third Avenue and 1057.2 feet Eastwardly from the Northeast intersection of Third Avenue and North Boulevard, which point is the Southwest corner of said Lot 34; thence Northwardly along the West line of said Lot, 100 feet to the Northwest corner thereof, thence running Eastwardly along the North line of said Lot 34, 60 feet to the Northeast corner thereof; thence running Southwardly along the East line of said Lot, 100 feet to the North side of Third Avenue, thence running Westwardly along the North side of Third Avenue 60 feet to the point of beginning.. Property street address for informational purposes: 439 Irby Street, Prichard, AL 36610. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. U.S. Bank Trust Company, National Association, as trustee, as successor-in-interest to U.S. Bank National Association, as successor in interest to Bank of America National Association, successor by merger to LaSalle Bank National Association, as Trustee for GSAMP Trust 2006-HE4, Mortgage Pass-Through Certificates, Series 2006-HE4, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 24-02138-PH-AL
Call News 03/20/2024, 03/27/2024, 04/03/2024
|
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Alberta Hosea and Timothy Hosea, wife and husband, originally in favor of Mortgage Electronic Registration Systems, Inc. as nominee for First Southern Mortgage Company Inc., on February 6, 2006, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 5919 Page 491; the undersigned The Bank of New York Mellon Trust Company, National Association fka The Bank of New York Trust Company, N.A. as successor to JPMorgan Chase Bank, N.A., as Trustee for Residential Asset Mortgage Products, Inc., Mortgage Asset-Backed Pass-Through Certificates, Series 2006-RS3, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on May 1, 2024, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 31, Carlisle, Unit Five as recorded in Map Book 32, Page 112 in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 6021 Scottsdale Drive , Mobile, AL 36618. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. The Bank of New York Mellon Trust Company, National Association fka The Bank of New York Trust Company, N.A. as successor to JPMorgan Chase Bank, N.A., as Trustee for Residential Asset Mortgage Products, Inc., Mortgage Asset-Backed Pass-Through Certificates, Series 2006-RS3, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 24-02133-PH-AL
Call News 03/20/2024, 03/27/2024, 04/03/2024
|
MORTGAGE FORECLOSURE SALE
Default having being made in the payment of the indebtedness secured by that certain mortgage dated January 31, 2020 executed by John E. West, surviving joint tenant, unmarried, in favor of Mortgage Electronic Registration Systems, Inc., acting solely as a nominee for Loandepot.com, LLC, said Mortgage being recorded February 26, 2020, in Inst. # 2020011393, in the Office of the Judge of Probate of Mobile County, Alabama; having later been assigned to NewRez LLC d/b/a Shellpoint Mortgage Servicing by instrument recorded in Inst. No. 2024004303, in the Office of the Judge of Probate of Mobile County, Alabama. Said default continues and notice is hereby given that the undersigned, NewRez LLC d/b/a Shellpoint Mortgage Servicing, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash at the main entrance to the County Courthouse, Mobile County, Alabama on 04/25/2024, during the legal hours of sale, the following described real estate situated in Mobile County, Alabama, to-wit:
Lot 1, and a portion of Lot 2 in Block 4 of Bayview Heights, recorded in Map Book 4, pages 135-137, Mobile County, Alabama, more particularly described as follows, to-wit: Commencing at the Southeast comer of Lot 3, Block 4 of Bayview Heights, thence run Westwardly along the North line of First Street (now known as Hawthorne Drive), a distance of 114.67 feet to a crimped top found and the point of beginning; thence continue Westwardly along said North line, a distance of 149.18 feet to a concrete monument found; thence with an interior angle to the left of 108 degrees 53 minutes 57 seconds 22.91feet to a concrete monument found on the South right of way line of Cottage Hill Road; thence with an interior angle to the left of 108 degrees 45 minutes32 seconds along said South right of way line a distance of 200.89 feet to a point; thence with an interior angle to the left of 51 degrees 31 minutes 29seconds, a distance of 144.44 feet to a crimped top found, being the point of beginning.
For informational purposes only, the property address is: 3876 Hawthorne Dr., Mobile, AL 36693. Any property address provided is not part of the legal description of the property sold herein and in the event of any discrepancy, the legal description referenced herein shall control.
THIS PROPERTY WILL BE SOLD ON AN “AS-IS, WHERE-IS” BASIS, SUBJECT TO ANY EASEMENTS, ENCUMBRANCES, AND EXCEPTIONS REFLECTED IN THE MORTGAGE AND THOSE CONTAINED IN THE RECORDS OF THE OFFICE OF THE JUDGE OF PROBATE OF THE COUNTY WHERE THE ABOVE-DESCRIBED PROPERTY IS SITUATED. THIS PROPERTY WILL BE SOLD WITHOUT WARRANTY OR RECOURSE, EXPRESS OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
This sale is made for the purpose of paying the indebtedness secured by mortgage as well as the expenses of foreclosure, including a reasonable attorney’s fees and other purposes set out in said mortgage.
NewRez LLC d/b/a Shellpoint Mortgage Servicing
Paul K. Lavelle, Esq.
Attorney for Mortgagee
Spina, & Lavelle, P.C.
One Perimeter Park South-Suite 400N
Birmingham, Alabama 35243
(205) 298-1800
30-FC-24-01088
Call News March 20, 2024, March 27, 2024 and April 3, 2024
|
NOTICE OF FORECLOSURE SALE
MOBILE COUNTY
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Robert Charles Faggard, originally in favor of Mortgage Electronic Registration Systems, Inc., as mortgagee, as nominee for M&T Bank, its successors and assigns, on April 3, 2014, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, at Book LR7137, Page 297; the undersigned NewRez LLC dba Shellpoint Mortgage Servicing, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash or certified funds, in front of the main entrance of the Courthouse at Mobile County, Alabama, on April 18, 2024, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:
THE PROPERTY LOCATED AT 119 HYLAND AVENUE, MOBILE, ALABAMA 36607, DESCRIBED MORE FULLY AS FOLLOWS:
LOTS 32 & 33, HYLAND PLACE, DEED BOOK 111, PAGE 1, AS RECORDED IN THE OFFICE OF THE JUDGE OF
PROBATE, MOBILE COUNTY, ALABAMA.
SUBJECT TO ALL EASEMENTS, RESERVATIONS, COVENANTS, CONDITIONS, AGREEMENTS OF RECORD, IF ANY.
BEING THE SAME PREMISES AS CONVEYED IN DEED FROM MARLA DENISE FAGGARD, A CURRENTLY MARRIED WOMAN RECORDED 02/16/2000 IN DOCUMENT NUMBER 2000009881, BOOK 4805, PAGE 0668 IN SAID COUNTY AND STATE.
COMMONLY KNOWN AS: 119 HYLAND AVE., MOBILE, AL, 36607
Tax Id: R022907230003179
Property street address for informational purposes: 119 Hyland Avenue Mobile, AL 36607
THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, SUBJECT TO ANY EASEMENTS, ENCUMBRANCES, AND EXCEPTIONS REFLECTED IN THE MORTGAGE AND THOSE CONTAINED IN THE RECORDS OF THE OFFICE OF THE JUDGE OF PROBATE OF THE COUNTY WHERE THE ABOVE-DESCRIBED PROPERTY IS SITUATED. THIS PROPERTY WILL BE SOLD WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender cash or certified funds made payable to Aldridge Pite, LLP at the time and place of the sale. Aldridge Pite, LLP reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. NewRez LLC dba Shellpoint Mortgage Servicing, Mortgagee/Transferee ALDRIDGE PITE, LLP Six Piedmont Center 3525 Piedmont Road, N.E., Suite 700 Atlanta, GA 30305. Attorney for Mortgagee/Transferee.
THIS OFFICE IS ACTING AS A DEBT COLLECTOR AND IS ATTEMPTING TO COLLECT A DEBT. ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
Call News 3/20/2024, 3/27/2024, 4/3/2024
|
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by John Seibert and Jean Seibert husband and wife, originally in favor of New Century Mortgage Corporation, on October 30, 2002, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 5255 Page 0478; the undersigned Deutsche Bank National Trust Company, as Trustee for New Century Home Equity Loan Trust, Series 2003-2, Asset Backed Pass-Through Certificates, Series 2003-2, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on May 1, 2024, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 5, Crestline Subdivision, according to the plat thereof recorded in Map Book 10, Page 258 of the records in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 8021 Docena Dr , Mobile, AL 36619. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Deutsche Bank National Trust Company, as Trustee for New Century Home Equity Loan Trust, Series 2003-2, Asset Backed Pass-Through Certificates, Series 2003-2, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 24-02141-PH-AL
Call News 03/20/2024, 03/27/2024, 04/03/2024
|
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Marlin F. Flowers, A Married Man, originally in favor of Mortgage Electronic Registration Systems, Inc. acting solely as nominee for TMS Mortgages, Inc., on May 8, 2015, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in BK LR7260 Page 891; the undersigned Servbank, SB, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on May 1, 2024, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 79, Pirate’s Cove, (2nd Unit) as recorded in Map Book 16, Page 83, Probate Court Records, Mobile County, Alabama.. Property street address for informational purposes: 202 E Baratara Dr , Chickasaw, AL 36611. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Servbank, SB, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 24-01798-MS-AL
Call News 03/20/2024, 03/27/2024, 04/03/2024
|
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Jean Seibert and John Seibert, husband and wife, originally in favor of New Century Mortgage Corporation, on October 30, 2002, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 5255 Page 0500; the undersigned Deutsche Bank National Trust Company, as Trustee for New Century Home Equity Loan Trust, Series 2003-2, Asset Backed Pass-Through Certificates, Series 2003-2, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on May 1, 2024, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 59, Crestline Subdivision, according to the plat thereof recorded in Map Book 10, Page 258 of the records in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 8016 Docena Drive , Mobile, AL 36619. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Deutsche Bank National Trust Company, as Trustee for New Century Home Equity Loan Trust, Series 2003-2, Asset Backed Pass-Through Certificates, Series 2003-2, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 24-02134-PH-AL
Call News 03/20/2024, 03/27/2024, 04/03/2024
|
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Brenda Sue Wilkerson, An Unmarried Woman, originally in favor of Mortgage Electronic Registration Systems, Inc. as nominee for Fairway Independent Mortgage Corporation its successors and assigns, on January 10, 2020, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Instrument Number 2020002151; with loan modification agreement recorded in Instrument Number 2021082973; the undersigned Lakeview Loan Servicing, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on May 15, 2024, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 13, Quail Run, Unit One as recorded in Map Book 26, Page 122, in the office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 5433 Quail Run E , Theodore, AL 36582. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Lakeview Loan Servicing, LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 24-02042-LC-AL
Call News 03/20/2024, 03/27/2024, 04/03/2024
|
NOTICE OF
MORTGAGE FORECLOSURE SALE
STATE OF ALABAMA
COUNTY OF MOBILE
Default having been made of the terms of the loan documents secured by that certain mortgage executed by David Preston, An Unmarried Man to Mortgage Electronic Registration Systems, Inc., as mortgagee, as nominee for CMG Mortgage Inc dba CMG Financial, #1820, its successors and assigns dated March 21, 2016; said mortgage being recorded on March 30, 2016, in Book 7362, Page 83 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to CMG Mortgage, Inc. in Instrument 2018060309 in the Office of the Judge of Probate of Mobile County, ALABAMA.
The undersigned, CMG Mortgage, Inc., under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 2nd day of May, 2024 the following property, situated in Mobile County, Alabama, to-wit:
Lot 23, Block “O”, Second Addition, Crestview, according to the plat thereof recorded in Map Book 9, Page 324 of the records in the Office of the Judge of Probate Court of Mobile County, Alabama.
Said property is commonly known as 4161 Winchester Dr, Mobile, AL 36693.
Should a conflict arise between the property address and the legal description the legal description will control.
Said property will be sold subject to any outstanding ad valorem taxes (including taxes which are a lien, but not yet due and payable), the right of redemption of any taxing authority, all outstanding liens for public utilities which constitute liens upon the property, any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, easements, rights-of-way, zoning ordinances, restrictions, special assessments, covenants, the statutory right of redemption pursuant to Alabama law, and any matters of record including, but not limited to, those superior to said Mortgage first set out above. Said property will be sold on an “as-is” basis without any representation, warranty or recourse against the above-named or the undersigned. The successful bidder must present certified funds in the amount of the winning bid at the time and place of sale.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The sale will be conducted subject (1) to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and (2) to final confirmation and audit of the status of the loan with the holder of the Mortgage.
CMG MORTGAGE, INC.
as holder of said mortgage
McCalla Raymer Leibert Pierce, LLC
Two North Twentieth
2 20th Street North, Suite 1000
Birmingham, AL 35203
(205) 216-4238
FT21@mccalla.com
File No. 24-05740AL
www.foreclosurehotline.net
Call News 03/20/2024,03/27/2024,04/03/2024
|
NOTICE OF
MORTGAGE FORECLOSURE SALE
STATE OF ALABAMA
COUNTY OF MOBILE
Default having been made of the terms of the loan documents secured by that certain mortgage executed by Daniel F Mclain, III An Unamrried Man to Mortgage Electronic Registration Systems, Inc., as mortgagee, as nominee for Rocket Mortgage, LLC f/k/a Quicken Loans, LLC, its successors and assigns dated August 18, 2021; said mortgage being recorded on August 23, 2021, as Instrument No. 2021054839 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to Rocket Mortgage, LLC, FKA Quicken Loans, LLC in Instrument 2024002350 in the Office of the Judge of Probate of Mobile County, ALABAMA.
The undersigned, Rocket Mortgage, LLC f/k/a Quicken Loans, LLC, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 18th day of April, 2024 the following property, situated in Mobile County, Alabama, to-wit:
Lot 70, Theodore Highlands Subdivision, according to plat thereof recorded in Map Book 9, Page 363, of the records in the Office of the Judge of Probate, Mobile County, Alabama.
EXCEPTING THEREFROM all interests in and to all oil, gas and other minerals in, on and/or under said property and all rights in connection therewith which may have been granted, reserved or leased to others by instruments of record in the Office of the Judge of Probate of Mobile County, Alabama.
Said property is commonly known as 6471 Oaklane Dr, Theodore, AL 36582.
Should a conflict arise between the property address and the legal description the legal description will control.
Said property will be sold subject to any outstanding ad valorem taxes (including taxes which are a lien, but not yet due and payable), the right of redemption of any taxing authority, all outstanding liens for public utilities which constitute liens upon the property, any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, easements, rights-of-way, zoning ordinances, restrictions, special assessments, covenants, the statutory right of redemption pursuant to Alabama law, and any matters of record including, but not limited to, those superior to said Mortgage first set out above. Said property will be sold on an “as-is” basis without any representation, warranty or recourse against the above-named or the undersigned. The successful bidder must present certified funds in the amount of the winning bid at the time and place of sale.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The sale will be conducted subject (1) to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and (2) to final confirmation and audit of the status of the loan with the holder of the Mortgage.
ROCKET MORTGAGE, LLC F/K/A QUICKEN LOANS, LLC
as holder of said mortgage
McCalla Raymer Leibert Pierce, LLC
Two North Twentieth
2 20th Street North, Suite 1000
Birmingham, AL 35203
(205) 216-4238
FT21@mccalla.com
File No. 24-05710AL
www.foreclosurehotline.net
Call News 03/20/2024,03/27/2024,04/03/2024
|
NOTICE OF
MORTGAGE FORECLOSURE SALE
STATE OF ALABAMA
COUNTY OF MOBILE
Default having been made of the terms of the loan documents secured by that certain mortgage executed by Michael E Wilkins Married to National City Mortgage a division of National City Bank of Indiana dated April 18, 2006; said mortgage being recorded on April 25, 2006, in Book 5956, Page 1034 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to Gulf Harbour Investments Corporation in Instrument 2019054727 in the Office of the Judge of Probate of Mobile County, ALABAMA.
The undersigned, Gulf Harbour Investments Corporation, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 18th day of April, 2024 the following property, situated in Mobile County, Alabama, to-wit:
Lot 6, Block E, Ellinor Place Extension, according to the plat thereof recorded in Map Book 4, Page 68-70, of the records in the Office of the Judge of Probate Court, Mobile County, Alabama.
Said property is commonly known as 2310 Taylor Ave, Mobile, AL 36606.
Should a conflict arise between the property address and the legal description the legal description will control.
Said property will be sold subject to any outstanding ad valorem taxes (including taxes which are a lien, but not yet due and payable), the right of redemption of any taxing authority, all outstanding liens for public utilities which constitute liens upon the property, any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, easements, rights-of-way, zoning ordinances, restrictions, special assessments, covenants, the statutory right of redemption pursuant to Alabama law, and any matters of record including, but not limited to, those superior to said Mortgage first set out above. Said property will be sold on an “as-is” basis without any representation, warranty or recourse against the above-named or the undersigned. The successful bidder must present certified funds in the amount of the winning bid at the time and place of sale.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The sale will be conducted subject (1) to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and (2) to final confirmation and audit of the status of the loan with the holder of the Mortgage.
GULF HARBOUR INVESTMENTS CORPORATION
as holder of said mortgage
McCalla Raymer Leibert Pierce, LLC
Two North Twentieth
2 20th Street North, Suite 1000
Birmingham, AL 35203
(205) 216-4238
FT21@mccalla.com
File No. 22-03969AL
www.foreclosurehotline.net
Call News 03/20/2024,03/27/2024,04/03/2024
|
FORECLOSURE NOTICE
Default having been made in the payment of the indebtedness to the River Landing Club Owners Association, Inc. (the “Lienor”), described in and secured by the terms, conditions, restrictions, and limitations set out in the Declaration of Condominium of River Landing Club, a Condominium, and exhibits thereto dated July 29, 1983, and recorded in the office of the Judge of Probate Court of Mobile County, Alabama, Apartment Ownership Book 30, Pages 1-112; as amended by instrument of Rules and Regulations dated July 29, 1983, and recorded in Apartment Ownership Book 30, Pages 113-117; as amended by Amendment to Declaration dated September 1, 1984, and recorded in Miscellaneous Book 51, Pages 207-209, as amended by Certificate of Incremental development dated May 28, 1985, and recorded in Apartment Ownership Book 30, Pages 118 and 119; as amended by instrument dated May 28, 1985 and recorded in Apartment Ownership Book 30, Pages 120-123; as amended by Amendment to Declaration and exhibits thereto dated June 10, 1987 and recorded in Apartment Ownership Book 30, Pages 124-225, and lastly amended by Incremental Certificate of Amendment dated May 10, 1987 and recorded in Apartment Ownership Book 30, Pages 226-241, all of which were recorded in the office of the Judge of Probate Court of Mobile County, Alabama, notice is hereby given that the River Landing Club Owners Association, Inc., and by virtue of the power of sale for foreclosure of a condominium association lien, as provided by Alabama Code § 35-8A-316 (1975); the said Lienor will sell at auction for cash to the highest bidder in front of the main, Government Street entrance of the Mobile County Courthouse in Mobile, Alabama, at 12:00 noon on the 15th day of April, 2024, the following described real estate situated in Mobile County, Alabama, to-wit:
Unit 308, Building 2, Phase II of River Landing Club, a condominium, according to that Declaration and Exhibits thereto dated July 29, 1983 and recorded in Apartment Ownership Book 30, pages 1-112; as amended by instrument of Rules and Regulations dated July 29, 1983 and recorded in Apartment Ownership Book 30, pages 113-117; as amended by Certificate of Incremental Development dated May 28, 1985, and recorded in Apartment Ownership Book 30, pages 118-119; as amended by instrument dated May 28, 1985 and recorded in Apartment Ownership Book 30, pages 120-123; as amended by Amendment to Declaration dated June 10, 1987 and recorded in Apartment Ownership Book 30, pages 125-225; and lastly amended by Incremental Certificate of Amendment dated May 10, 1987, and recorded in Apartment Ownership Book 30, pages 226-241, all recorded in the office of the Judge of Probate, Mobile County, Alabama, together with the undivided percent interest in the common areas and facilities declared in said Declarations and the amendments thereto.
Said sale will be made for the purpose of paying said indebtedness and the expenses incident to this sale, including a reasonable attorney’ s fee.
RIVER LANDING CLUB OWNERS ASSOCIATION, INC., Holder of said Lien
Attorney for Lienor:
Harry V. Satterwhite
Satterwhite Reece Law Firm, LLC
1325 Dauphin Street
Mobile, Alabama 36604
(251) 432-8120
Call News March 20, 27, and April 3, 2024
|
FORECLOSURE NOTICE
Default having been made in the payment of the indebtedness to the River Landing Club Owners Association, Inc. (the “Lienor”), described in and secured by the terms, conditions, restrictions, and limitations set out in the Declaration of Condominium of River Landing Club, a Condominium, and exhibits thereto dated July 29, 1983, and recorded in the office of the Judge of Probate Court of Mobile County, Alabama, Apartment Ownership Book 30, Pages 1-112; as amended by instrument of Rules and Regulations dated July 29, 1983, and recorded in Apartment Ownership Book 30, Pages 113-117; as amended by Amendment to Declaration dated September 1, 1984, and recorded in Miscellaneous Book 51, Pages 207-209, as amended by Certificate of Incremental development dated May 28, 1985, and recorded in Apartment Ownership Book 30, Pages 118 and 119; as amended by instrument dated May 28, 1985 and recorded in Apartment Ownership Book 30, Pages 120-123; as amended by Amendment to Declaration and exhibits thereto dated June 10, 1987 and recorded in Apartment Ownership Book 30, Pages 124-225, and lastly amended by Incremental Certificate of Amendment dated May 10, 1987 and recorded in Apartment Ownership Book 30, Pages 226-241, all of which were recorded in the office of the Judge of Probate Court of Mobile County, Alabama, notice is hereby given that the River Landing Club Owners Association, Inc., and by virtue of the power of sale for foreclosure of a condominium association lien, as provided by Alabama Code § 35-8A-316 (1975); the said Lienor will sell at auction for cash to the highest bidder in front of the main, Government Street entrance of the Mobile County Courthouse in Mobile, Alabama, at 12:00 noon on the 15th day of April, 2024, the following described real estate situated in Mobile County, Alabama, to-wit:
Unit 306, Building 2, Phase II of River Landing Club, a condominium, according to that certain Declaration and Exhibits thereto dated July 29, 1983 and recorded in Apartment Ownership Book 30, pages 1-112; as amended by instrument of Rules and Regulations dated July 29, 1983 and recorded in Apartment Ownership Book 30, pages 113-117; as amended by Certificate of Incremental Development dated May 28, 1985, and recorded in Apartment Ownership Book 30, pages 118-119; as amended by instrument dated May 28, 1985 and recorded in Apartment Ownership Book 30, pages 120-123; as amended by Amendment to Declaration dated June 10, 1987 and recorded in Apartment Ownership Book 30, pages 125-225; and lastly amended by Incremental Certificate of Amendment dated May 10, 1987, and recorded in Apartment Ownership Book 30, pages 226-241, all recorded in the office of the Judge of Probate, Mobile County, Alabama, together with the undivided percent interest in the common areas and facilities declared in said Declarations and the amendments thereto.
Said sale will be made for the purpose of paying said indebtedness and the expenses incident to this sale, including a reasonable attorney’ s fee.
RIVER LANDING CLUB OWNERS ASSOCIATION, INC.,
Holder of said Lien
Attorney for Lienor:
Harry V. Satterwhite
Satterwhite Reece Law Firm, LLC
1325 Dauphin Street
Mobile, Alabama 36604
(251) 432-8120
Call News March 20, 27, and April 3, 2024
|
FORECLOSURE NOTICE
Default having been made in the payment of the indebtedness to the River Landing Club Owners Association, Inc. (the “Lienor”), described in and secured by the terms, conditions, restrictions and limitations set out in the Declaration of Condominium of River Landing Club, a Condominium, and exhibits thereto dated July 29, 1983, and recorded in the office of the Judge of Probate Court of Mobile County, Alabama, Apartment Ownership Book 30, Pages 1-112; as amended by instrument of Rules and Regulations dated July 29, 1983, and recorded in Apartment Ownership Book 30, Pages 113-117; as amended by Amendment to Declaration dated September 1, 1984, and recorded in Miscellaneous Book 51, Pages 207-209; as amended by Certificate of Incremental Development dated May 28, 1985, and recorded in Apartment Ownership Book 30, Pages 118-119; as amended by instrument dated May 28, 1985, and recorded in Apartment Ownership Book 30, Pages 120-123; as amended by Amendment to Declaration and exhibits thereto dated June 10, 1987, and recorded in Apartment Ownership Book 30, Pages 124-225; and lastly as amended by Incremental Certificate of Amendment dated May 10, 1987, and recorded in Apartment Ownership Book 30, Pages 226-241, all of which were recorded in the office of the Judge of Probate Court of Mobile County, Alabama, notice is hereby given that the River Landing Club Owners Association, Inc., and by virtue of the power of sale for foreclosure of a condominium association lien, as provided by Alabama Code § 35-8A-316 (1975); the said Lienor will sell at auction for cash to the highest bidder in front of the main, Government Street entrance of the Mobile County Courthouse in Mobile, Alabama, at 12:00 noon on the 15th day of April, 2024, the following described real estate situated in Mobile County, Alabama, to-wit:
Unit 213, Building 3, Phase II of River Landing Club, a Condominium, according to that certain Declaration and Exhibits thereto dated July 29, 1983 and recorded in Apartment Ownership Book 30, pages 1-112; as amended by instrument of Rules and Regulations dated July 29, 1983 and recorded in Apartment Ownership Book 30, pages 113-117; as amended by Certificate of Incremental Development dated May 28, 1985, and recorded in Apartment Ownership Book 30, pages 118-119; as amended by instrument dated May 28, 1985 and recorded in Apartment Ownership Book 30, pages 120-123; as amended by Amendment to Declaration dated June 10, 1987 and recorded in Apartment Ownership Book 30, pages 125-225; and lastly amended by Incremental Certificate of Amendment dated May 10, 1987, and recorded in Apartment Ownership Book 30, pages 226-241, all recorded in the office of the Judge of Probate, Mobile County, Alabama, together with the undivided percent interest in the common areas and facilities declared in said Declarations and the amendments thereto.
Said sale will be made for the purpose of paying said indebtedness and the expenses incident to this sale, including a reasonable attorney’ s fee.
RIVER LANDING CLUB OWNERS ASSOCIATION, INC., Holder of said Lien
Attorney for Lienor:
Harry V. Satterwhite
Satterwhite Reece Law Firm, LLC
1325 Dauphin Street
Mobile, Alabama 36604
(251) 432-8120
Call News March 20, 27, and April 3, 2024
|
FORECLOSURE NOTICE
Default having been made in the payment of the indebtedness to the River Landing Club Owners Association, Inc. (the “Lienor”), described in and secured by the terms, conditions, restrictions and limitations set out in the Declaration of Condominium of River Landing Club, a Condominium, and exhibits thereto dated July 29, 1983, and recorded in the office of the Judge of Probate Court of Mobile County, Alabama, Apartment Ownership Book 30, Pages 1-112; as amended by instrument of Rules and Regulations dated July 29, 1983, and recorded in Apartment Ownership Book 30, Pages 113-117; as amended by Amendment to Declaration dated September 1, 1984, and recorded in Miscellaneous Book 51, Pages 207-209; as amended by Certificate of Incremental Development dated May 28, 1985, and recorded in Apartment Ownership Book 30, Pages 118-119; as amended by instrument dated May 28, 1985, and recorded in Apartment Ownership Book 30, Pages 120-123; as amended by Amendment to Declaration and exhibits thereto dated June 10, 1987, and recorded in Apartment Ownership Book 30, Pages 124-225; and lastly as amended by Incremental Certificate of Amendment dated May 10, 1987, and recorded in Apartment Ownership Book 30, Pages 226-241, all of which were recorded in the office of the Judge of Probate Court of Mobile County, Alabama, notice is hereby given that the River Landing Club Owners Association, Inc., and by virtue of the power of sale for foreclosure of a condominium association lien, as provided by Alabama Code § 35-8A-316 (1975); the said Lienor will sell at auction for cash to the highest bidder in front of the main, Government Street entrance of the Mobile County Courthouse in Mobile, Alabama, at 12:00 noon on the 15th day of April, 2024, the following described real estate situated in Mobile County, Alabama, to-wit:
Unit 101, Building I, Phase II of River Landing Club, a Condominium, according to that certain Declaration and Exhibits thereto dated July 29, 1983 and recorded in Apartment Ownership Book 30, pages 1-112; as amended by instrument of Rules and Regulations dated July 29, 1983 and recorded in Apartment Ownership Book 30, pages 113-117; as amended by Certificate of Incremental Development dated May 28, 1985, and recorded in Apartment Ownership Book 30, pages 118-119; as amended by instrument dated May 28, 1985 and recorded in Apartment Ownership Book 30, pages 120-123; as amended by Amendment to Declaration dated June 10, 1987 and recorded in Apartment Ownership Book 30, pages 125-225; and lastly amended by Incremental Certificate of Amendment dated May 10, 1987, and recorded in Apartment Ownership Book 30, pages 226-241, all recorded in the office of the Judge of Probate, Mobile County, Alabama, together with the undivided percent interest in the common areas and facilities declared in said Declarations and the amendments thereto.
Said sale will be made for the purpose of paying said indebtedness and the expenses incident to this sale, including a reasonable attorney’ s fee.
RIVER LANDING CLUB OWNERS ASSOCIATION, INC.,
Holder of said Lien
Attorney for Lienor:
Harry V. Satterwhite
Satterwhite Reece Law Firm, LLC
1325 Dauphin Street
Mobile, Alabama 36604
(251) 432-8120
Call News March 20, 27, and April 3, 2024
|
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Kevin Rowe and Pamela L. Rowe, husband and wife, originally in favor of Mortgage Electronic Registration Systems, Inc., as nominee for Southpoint Bank, an Alabama Chartered Bank, on July 27, 2010, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 6682 Page 588; with Home Affordable Modification Agreement recorded April 18, 2018 in BK: LR7625 Page 1881; the undersigned Wells Fargo Bank, N.A., as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on May 16, 2024, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 29, Schutz Property as recorded in Map Book 4, Pages 53-54 in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 1518 Northview Dr , Mobile, AL 36618-1825. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Wells Fargo Bank, N.A., (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 22-40627
Call News 03/20/2024, 03/27/2024, 04/03/2024
|
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Penny P Copeland, Unmarried Woman, originally in favor of Mortgage Electronic Registration Systems, Inc. acting solely as nominee for Whitney Bank DBA Hancock Bank, on June 24, 2016, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book LR7396 Page 362; the undersigned BOKF, N.A., as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on April 11, 2024, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 8, Block B, Tuthill Lane Estates, according to the plat thereof recorded in Map Book 6, Pages 313-314, of the records in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 612 Tuthill Ln , Mobile, AL 36608. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. BOKF, N.A., (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 24-01924-BO-AL
Call News 03/20/2024, 03/27/2024, 04/03/2024
|
MORTGAGE FORECLOSURE NOTICE
Default having been made in the terms of that certain Mortgage, executed on 09/21/2021, by Hoang Huy Nguyen, unmarried man, and Thuy Minh Ta, a married woman, and Loan Thi Huynh, unmarried woman, as joint tenants with full rights of survivorship, as Mortgagors, to Mortgage Electronic Registration Systems, Inc. as nominee for United Wholesale Mortgage, LLC as Mortgagee, which said Mortgage is recorded in the Office of the Judge of Probate, Mobile County, Alabama, in Instrument # 2021063058 on 09/23/2021, and subsequently assigned to CARRINGTON MORTGAGE SERVICES, LLC and recorded in the Office of the Judge of Probate, Mobile County, Alabama on 02/27/2024 in Instrument # 2024010093, and default having continued under the terms of said Mortgage, and by virtue of Alabama Code Section 35-10-3 and 35-10-2, the following described real property will be sold at public outcry, for cash, to the highest bidder, in front of the Courthouse door of said County, during the legal hours of sale, on 04/17/2024.
THE LAND REFERRED TO IN THIS COMMITMENT IS DESCRIBED AS FOLLOWS:
LOT 19, NORTHWOOD OAKS, PHASE 1A, ACCORDING TO PLAT OR MAP THEREOF RECORDED IN MAP BOOK 129, PAGE 18, IN THE RECORDS OF THE OFFICE OF THE JUDGE OF PROBATE OF MOBILE COUNTY.
Subject to all easements, restrictions and reservations appearing of record. Said sale will also be made subject to any Federal Tax Liens and/or Special Assessments of any nature, if any, which might adversely affect the title to the property.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The property is being sold “as is, where is”. Said property is sold without warranty or recourse, expressed or implied as to title, use or enjoyment.
This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure.
This sale is subject to postponement or cancellation.
Kent D. McPhail
McPhail Sanchez, LLC
Counsel for Mortgagee/Transferee
126 Government Street
Mobile, AL 36602
251-438-2333
Call News 03/20/2024, 03/27/2024, and 04/03/2024
|
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Theodore H. Lawson, Jr. A/K/A Theodore Lawson, Jr to Mortgage Electronic Registration Systems, Inc., as nominee for Fairway Independent Mortgage Corporation, dated September 18, 2014 said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book LR7189, Page 828. Said mortgage was subsequently sold, assigned and transferred to Fairway Independent Mortgage Corporation. Under and by virtue of the power of sale contained in said mortgage, the undersigned, Fairway Independent Mortgage Corporation, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse in the City of Mobile, Mobile County, Alabama on April 25, 2024, during the legal hours of sale, all of its right, title, and interest in and to the following describe real estate situated in Mobile County, Alabama, to-wit:
LOT 43, HARBOR HILLS SUBDIVISION, ACCORDING TO PLAT THEREOF RECORDED IN MAP BOOK 8, PAGE 241 OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA.
Property Street Address for Informational Purposes: 1201 Anchor Drive, Mobile, AL 36693
Said property will be sold “AS IS”. NO REPRESENTATION OR WARRANTY, EXPRESSED OR IMPLIED, IS MADE AS TO THE TITLE OF SAID PROPERTY. Said property is subject to any title deficiencies including but not limited to: any outstanding ad valorem taxes – including taxes which are a lien but not yet due and payable, any matters which might be disclosed by an accurate survey and inspection of the property, any assessments liens, encumbrances, zoning ordinances, restrictions, covenants, and matters of record superior to the Mortgage first set out above. Said property will be sold subject to the right of redemption of all parties entitled thereto. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand the rights and programs as a part of the foreclosure process.
This sale will be made for the purpose of paying the same and all expenses of this sale, as provided in said Mortgage and by Alabama law. This sale is subject to postponement or cancellation.
**This is an attempt to collect a debt and any information obtained may be used for that purpose.**
Fairway Independent Mortgage Corporation, Mortgagee or Transferee
Jonathan Smothers, Esq
ALAW
420 North 20th Street, Suite 2249
Birmingham, AL 35203
Attorney for Mortgagee/Transferee
24-004787
Call News March 13, 20, 27, and April 3, 2024
|
NOTICE OF FORECLOSURE SALE
MOBILE COUNTY
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by John Wesley Busby Jr, a married man, originally in favor of Mortgage Electronic Registration Systems, Inc., as mortgagee, as nominee for Caliber Home Loans, Inc., its successors and assigns on July 29, 2021, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, Instrument Number 2021051219, as re-recorded at Instrument Number 2023039639; the undersigned NewRez LLC d/b/a Shellpoint Mortgage Servicing, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash or certified funds, in front of the main entrance of the Courthouse at Mobile County, Alabama, on April 10, 2024, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:
Commencing at the Southwest corner of the Northeast Quarter, Section 4, Township 1 South, Range 3 West, Mobile County, Alabama and run South 89 degrees 40 minutes East along the South line of said Northeast Quarter for 331.05 feet to a Point;
thence run North 0 degrees 40 minutes East for 1710.40 feet to a Point (Said Point being the intersection of said line and the right-of-way line of the Gulfcrest Road); thence run North 89 degrees 36 minutes West along the South right-of-way line of Gulfcrest Road for 22.51 feet to the Point of Beginning; thence continue on said line of North 89 degrees 36 minutes West for 124.00 feet to a Point; thence run South 1 degree 58 minutes West along the existing property line for 175.00 feet to a Point;
thence run South 89 degrees 36 minutes East for 124.00 feet to a point; thence run North 1 degree 58 minutes 20 seconds East for 175.00 feet to the Point of Beginning.
Property street address for informational purposes: 10085-A Gulfcrest Rd Chunchula, AL 36521
THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, SUBJECT TO ANY EASEMENTS, ENCUMBRANCES, AND EXCEPTIONS REFLECTED IN THE MORTGAGE AND THOSE CONTAINED IN THE RECORDS OF THE OFFICE OF THE JUDGE OF PROBATE OF THE COUNTY WHERE THE ABOVE-DESCRIBED PROPERTY IS SITUATED. THIS PROPERTY WILL BE SOLD WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender cash or certified funds made payable to Aldridge Pite, LLP at the time and place of the sale. Aldridge Pite, LLP reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. NewRez LLC d/b/a Shellpoint Mortgage Servicing, Mortgagee/Transferee ALDRIDGE PITE, LLP Six Piedmont Center 3525 Piedmont Road, N.E., Suite 700 Atlanta, GA 30305. Attorney for Mortgagee/Transferee.
THIS OFFICE IS ACTING AS A DEBT COLLECTOR AND IS ATTEMPTING TO COLLECT A DEBT. ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
Call News 3/13/2024, 3/20/2024, 3/27/2024
|
NOTICE OF
MORTGAGE FORECLOSURE SALE
STATE OF ALABAMA
COUNTY OF MOBILE
Default having been made of the terms of the loan documents secured by that certain mortgage executed by Anthony D Turberville, A Married Man to Mortgage Electronic Registration Systems, Inc., as mortgagee, as nominee for Hometown Mortgage Services, Inc., its successors and assigns dated April 23, 2010; said mortgage being recorded on April 29, 2010, in Book 6650, Page 496 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to Lakeview Loan Servicing, LLC in Instrument 2019012221 in the Office of the Judge of Probate of Mobile County, ALABAMA.
The undersigned, Lakeview Loan Servicing, LLC, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 18th day of April, 2024 the following property, situated in Mobile County, Alabama, to-wit:
Lot 6, Saxon Manor, Unit One, according to plat thereof recorded in Map Book 17, Page 46 of the records in the Office of the Judge of Probate of Mobile County, Alabama.
Said property is commonly known as 12634 King Arthur Dr, Grand Bay, AL 36541.
Should a conflict arise between the property address and the legal description the legal description will control.
Said property will be sold subject to any outstanding ad valorem taxes (including taxes which are a lien, but not yet due and payable), the right of redemption of any taxing authority, all outstanding liens for public utilities which constitute liens upon the property, any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, easements, rights-of-way, zoning ordinances, restrictions, special assessments, covenants, the statutory right of redemption pursuant to Alabama law, and any matters of record including, but not limited to, those superior to said Mortgage first set out above. Said property will be sold on an “as-is” basis without any representation, warranty or recourse against the above-named or the undersigned. The successful bidder must present certified funds in the amount of the winning bid at the time and place of sale.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The sale will be conducted subject (1) to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and (2) to final confirmation and audit of the status of the loan with the holder of the Mortgage.
LAKEVIEW LOAN SERVICING, LLC
as holder of said mortgage
McCalla Raymer Leibert Pierce, LLC
Two North Twentieth
2 20th Street North, Suite 1000
Birmingham, AL 35203
(205) 216-4238
FT21@mccalla.com
File No. 24-05615AL
www.foreclosurehotline.net
Call News 03/13/2024,03/20/2024,03/27/2024
|
FORECLOSURE NOTICE
Default having been made in the payment of the indebtedness described in and secured by that certain Vendors Lien Deed executed by Delores Welch, a married woman and Carolyn White, a single woman, to Power Partnership, LLC, an Alabama Limited Liability Company dated June 10th, 2022, and recorded in Instrument No. 2022040542, of the records in the Office of the Judge of Probate, Mobile County, Alabama; and said default continuing; notice is hereby given that the undersigned will, under and by virtue of the power of sale contained in said Vendors Lien Deed, sell at public outcry for cash, at the Government Street entrance of the Mobile County Courthouse at 205 Government Street, Mobile, Alabama, to the highest bidder, on April 11th, 2024, during the legal hours of sale, the following described real property situated in the County of Mobile, State of Alabama, to-wit:
Lot 13, Deer Landing, according to plat thereof recorded in Instrument No. 2021082638 of the records in the Office of the Judge of Probate of Mobile County, Alabama.
– RAW LAND-
SUBJECT:
1. Except therefrom such oil, gas and other minerals in, on and under said real property, together with all rights in connection therewith, as have previously been reserved by or conveyed to others than the grantor.
2. Easements, reservations, restrictions, rights-of-way and setback lines as reserved and shown on record Map of subdivision.
3. All matters of Public record including any utility easement as recorded in the Office of the Judge of Probate, Mobile County, Alabama.
4. Any prior reservations or conveyance of minerals, together with release of damages of minerals of every kind and character, including but not limited to oil and gas in, on and under subject property.
5. Encroachments, overlaps, boundary line disputes and other matters that would be revealed by an accurate survey or inspection of the Property.
6. Utility easements and facilities serving the Property, whether of record or not.
7. Any facts, rights, interest, or claims that are not shown by the Public Records but that could be ascertained by an inspection of the Land or that may be asserted by persons in possession on the Land.
8. Easements, covenants, reservations, conditions and restrictions of record.
9. Easements, liens or encumbrances, or claims thereof, not shown by the Public Records.
10. Any encroachment, encumbrance, violation, variation, or adverse circumstance affecting the Title that would be disclosed by an accurate and complete land survey of the Land and not shown by the Public Records.
11. Any portion of subject property conveyed to The City of Mobile.
12. Restrictive Covenants contained in instrument dated December 16, 2021 and recorded in Instrument # 2021082765; including the Amendment dated April 22, 2022 recorded in Instrument # 2022033369
and all amendments thereto, but deleting any covenant, condition or restriction indicating a preference, limitation or discrimination based on race, color, religion, sex, handicap, familial status, or nation origin to the extend such covenants, conditions, or restrictions violate 42 USC 3604(c).
13. Building setback line; drainage and utility line easements as shown on the recorded plat of said subdivision.
14. Easement granted to Alabama Power Company by instrument recorded in Deed Book 433, Page 1015; Deed Book 515, Page 352; and Real Property Book 5424, Page 1216 of the records in the Office of the Judge of Probate of Mobile Count, Alabama.
15. 50’ Minimum Building Setback Line.
16. Easement for Ingress & Egress and Utilities as noted on recorded plat.
17. 25’ Easement for Ingress & Egress and Utilities.
18. 2023 Taxes are due plus penalty and interest.
Said sale will be made for the purpose of paying said indebtedness and the expenses incidental to said sale, including a reasonable attorney’s fee.
POWER PARTNERSHIP LLC, an Alabama Limited Liability Company as holder of said Vendors Lien Deed
William C. Poole, LLC
Attorneys at Law
William C. Poole
917 Western America Circle, Suite 210
Mobile, AL 36609
(251) 344-5015
THIS IS AN ATTEMPT TO COLLECT A DEBT ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
Call News March 13, 20, 27, 2024
|
NOTICE OF FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by John P. Norris III and Holly W. Norris, Husband and Wife, as joint tenants, to Mortgage Electronic Registration Systems, Inc., as Mortgagee, as nominee for Freedom Mortgage Corporation, its successors and assigns, on August 4, 2015, said mortgage being recorded in the Office of the Judge of Probate of Mobile County, Alabama, on August 20, 2015 at Book LR7295, at Page 249, as Document Number 2015043488. PHH Mortgage Corporation, the current holder, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Mobile County Courthouse, in Mobile, Alabama, on May 16, 2024, during the legal hours of sale, the following described real estate, situated in Mobile County, Alabama, to-wit:
Lot Number Twenty-Three (23) in Block Number Twenty-Four (24) of the Dubroca Tract, according to map thereof recorded in Deed Book 141, N.S., Page 39 of the Probate Court Records of Mobile County, Alabama.
More commonly known as: 103 Glenwood St, Mobile, AL 36606
This Property will be sold on as “as is, where is” basis, without warranty or recourse, expressed or implied as to title, use and/or enjoyment and will be sold subject to the right of redemption of all parties entitled thereto. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expense of foreclosure. The successful bidder must tender certified funds by noon the next business day to Law Office of Halliday, Watkins & Mann, P.C. Certified funds must be in the form of a wire transfer, bank or credit union’s cashier’s check, or bank official check payable to Halliday, Watkins & Mann, P.C. Halliday, Watkins & Mann, P.C. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. If sale is voided, Mortgagee/Transferee shall return the bid amount to the successful purchaser and the Mortgagee/Transferee shall not be liable to the purchase for any damages. If the sale is set aside for any reason, the purchaser at the sale shall be only entitled to a return of the deposit and bid amount, if paid. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit is purchase price against the expenses of sale and indebtedness secured by the real estate. This sale is subject to postponement or cancellation.
PHH Mortgage Corporation (“Transferee”)
Halliday, Watkins & Mann, P.C.
244 Inverness Center Drive
Birmingham, AL 35242
Phone: (801) 355-2886
Call News 03/13/2024, 03/20/2024, and 03/27/2024
|
State of Alabama
County of Mobile
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain Assignment of Mortgage executed by Venetia TJH Investments, to Alabama Capital Corporation on the 10th day of January, 2002, said lien retained in deed from Pemberton Mortgage and Investments, LLC to Arkeya L. Mitchell dated the 15th day of February, 2016 recorded in BK:LR7348, Page 478. Said lien was assigned to Venetia TJH Investments, by Assignment date the 4th day of April,2016 (#4 on the Assignment) in BK: LR7365, Page 464 of the records in the Office of the Judge of Probate, Mobile County, Alabama; this Assignment was subsequently assigned to CSA Investments. and recorded in the Office of the Judge of Probate, Mobile County, Alabama on the 12th day of December,2023 in Instrument #2023071953; said default continuing, notice is hereby given that the undersigned will, under virtue of the power of sale contained in said vendor’s lien deed, sell at public outcry for cash to the highest bidder during the legal hours of sale on Thursday, March 28th, 2024 at the front entrance of the Mobile County Courthouse in City of Mobile, Alabama, the following described real estate situated in Mobile County, Alabama, to-wit:
Lot 41, First Unit, Curtwood Lake Estates, according to the plat thereof recorded in Map Book 9, Page 31 of the records in the Office of the Judge of Probate, Mobile, Alabama.
The property address is known as 709 Walter Circle, Eight Mile, AL 36613.
THIS CONVEYANCE IS SUBJECT TO THE FOLLOWING:
Any and all easements, restrictions applicable to the above described property of record in the Office of the Judge of Probate, Mobile County, Alabama.
This property will be sold on an “as-is, where-is” basis, subject to any easements, encumbrances, and exceptions reflected in the vendor’s lien deed and those contained in the records of the office of the Judge of Probate of the county where the property is situated. This property will be sold without warranty or recourse, expressed or implied as to title, use and/or enjoyment and will be sold subject to the right of redemption of all parties entitled thereto.
Said sale will be made for the purpose of paying said indebtedness and all expenses incident to this sale.
This is sale is subject to postponement or cancellation.
CSA Investments
P. O. Box 7718
Mobile, AL 36670
Call News March 13, 20, 27, 2024
|
NOTICE OF
MORTGAGE FORECLOSURE SALE
STATE OF ALABAMA
COUNTY OF MOBILE
Default having been made of the terms of the loan documents secured by that certain mortgage executed by Landlord 36 Holdings LLC to Commercial Lender, LLC dated June 30, 2022; said mortgage being recorded on July 6, 2022, as Instrument No. 2022045490 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to Toorak Capital Partners LLC in Instrument 2024010555 in the Office of the Judge of Probate of Mobile County, ALABAMA.
The undersigned, Toorak Capital Partners LLC, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 18th day of April, 2024 the following property, situated in Mobile County, Alabama, to-wit:
Lot 6, Block 30, Glendale Park, according to the plat thereof as recorded in Deed Book 61 N.S., pages 316-317 of the Probate Court Records of Mobile County, Alabama.
Said property is commonly known as 510 Dexter Ave, Mobile, AL 36604.
Should a conflict arise between the property address and the legal description the legal description will control.
Said property will be sold subject to any outstanding ad valorem taxes (including taxes which are a lien, but not yet due and payable), the right of redemption of any taxing authority, all outstanding liens for public utilities which constitute liens upon the property, any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, easements, rights-of-way, zoning ordinances, restrictions, special assessments, covenants, the statutory right of redemption pursuant to Alabama law, and any matters of record including, but not limited to, those superior to said Mortgage first set out above. Said property will be sold on an “as-is” basis without any representation, warranty or recourse against the above-named or the undersigned. The successful bidder must present certified funds in the amount of the winning bid at the time and place of sale.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The sale will be conducted subject (1) to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and (2) to final confirmation and audit of the status of the loan with the holder of the Mortgage.
TOORAK CAPITAL PARTNERS LLC
as holder of said mortgage
McCalla Raymer Leibert Pierce, LLC
Two North Twentieth
2 20th Street North, Suite 1000
Birmingham, AL 35203
(205) 216-4238
FT21@mccalla.com
File No. 23-05561AL
www.foreclosurehotline.net
Call News 03/13/2024,03/20/2024,03/27/2024
|
State of Alabama
County of Mobile
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain Mortgage and Assignment of Rents of executed by Shane Sparks to Alabama Mobile Capital Company, LLC on the 12th day of May, 2017, and recorded in Instrument #2017027656. Said lien was assigned to LRA Holdings, by Assignment date the 12th day of May, 2017 in Instrument #2017029159 of the records in the Office of the Judge of Probate, Mobile County, Alabama; this Assignment was subsequently assigned to CSA Investments LLC and recorded in the Office of the Judge of Probate, Mobile County, Alabama on the 28th day of February, 2024 in Instrument #2024010331; said default continuing, notice is hereby given that the undersigned will, under virtue of the power of sale contained in said vendor’s lien deed, sell at public outcry for cash to the highest bidder during the legal hours of sale on Thursday, March 28th, 2024 at the front entrance of the Mobile County Courthouse in City of Mobile, Alabama, the following described real estate situated in Mobile County, Alabama, to-wit:
PARCEL B: Lot Number Fourteen (14), Block Number A of Neese’s Addition to Crichton, of the plat thereof recorded in Map Book 4, Page 168 of the records in the Office of the Judge of Probate, Mobile, Alabama.
The property address is known as 2812 Josephine St., Mobile, AL
THIS CONVEYANCE IS SUBJECT TO THE FOLLOWING:
Any and all easements, restrictions applicable to the above described property of record in the Office of the Judge of Probate, Mobile County, Alabama.
This property will be sold on an “as-is, where-is” basis, subject to any easements, encumbrances, and exceptions reflected in the vendor’s lien deed and those contained in the records of the office of the Judge of Probate of the county where the property is situated. This property will be sold without warranty or recourse, expressed or implied as to title, use and/or enjoyment and will be sold subject to the right of redemption of all parties entitled thereto.
Said sale will be made for the purpose of paying said indebtedness and all expenses incident to this sale.
This is sale is subject to postponement or cancellation.
CSA Investments
P. O. Box 7718
Mobile, AL 36670
Call News March 13, 20, 27, 2024
|
NOTICE OF FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Morris Pope, a married man, to Mortgage Electronic Registration Systems, Inc., as Mortgagee, as nominee for Southwest Funding, LP, its successors and assigns, on April 19, 2018, said mortgage being recorded in the Office of the Judge of Probate of Mobile County, Alabama, on April 25, 2018 at Book LR7628, at Page 1234, as Document Number 2018022619. PHH Mortgage Corporation, the current holder, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Mobile County Courthouse, in Mobile, Alabama, on May 16, 2024, during the legal hours of sale, the following described real estate, situated in Mobile County, Alabama, to-wit:
That real property situated in the County of Mobile, State of Alabama, described as follows, to-wit: Lot 29, Sonia No. Two (2) Subdivision, according to plat thereof, dated February 1, 1955 and recorded March 5, 1955 in Map Book 6, Page 500, of the records in the office of the Judge of Probate of Mobile County, Alabama.
More commonly known as: 3762 E Alta Vista Dr, Mobile, AL 36605
This Property will be sold on as “as is, where is” basis, without warranty or recourse, expressed or implied as to title, use and/or enjoyment and will be sold subject to the right of redemption of all parties entitled thereto. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expense of foreclosure. The successful bidder must tender certified funds by noon the next business day to Law Office of Halliday, Watkins & Mann, P.C. Certified funds must be in the form of a wire transfer, bank or credit union’s cashier’s check, or bank official check payable to Halliday, Watkins & Mann, P.C. Halliday, Watkins & Mann, P.C. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. If sale is voided, Mortgagee/Transferee shall return the bid amount to the successful purchaser and the Mortgagee/Transferee shall not be liable to the purchase for any damages. If the sale is set aside for any reason, the purchaser at the sale shall be only entitled to a return of the deposit and bid amount, if paid. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit is purchase price against the expenses of sale and indebtedness secured by the real estate. This sale is subject to postponement or cancellation.
PHH Mortgage Corporation (“Transferee”)
Halliday, Watkins & Mann, P.C.
244 Inverness Center Drive
Birmingham, AL 35242
Phone: (801) 355-2886
Call News March 13, 2024, March 20, 2024, March 27, 2024
|
NOTICE OF MORTGAGE
FORECLOSURE SALE
STATE OF ALABAMA
MOBILE COUNTY
Default having been made in the payment of indebtedness secured by that certain mortgage executed by Isaac Unger Leigh, II, a single man, the 13th day of June, 2019, to BBVA USA, now known as PNC Bank, N.A., which said mortgage is recorded in the Probate Office of Mobile County, Alabama, as Instrument No. 2019037141 and by reason of such default, having declared all of the indebtedness secured by said mortgage due and payable, and such default continuing, notice is hereby given that, acting under the power of sale contained in said mortgage, PNC Bank, N. A. will sell at public outcry, for cash, to the highest bidder, in front of the Mobile County Courthouse at 205 Government Street in the City of Mobile, Mobile County, Alabama, during the legal hours of sale on April 18, 2024, the following described real estate situated in Mobile County, Alabama, to-wit:
Lot 60, Princeton Woods, Unit 1, according to the Plat thereof recorded in Deed
Book 27, Page 25 of the records in the Office of the Judge of Probate of Mobile
County, Alabama.
Said property is also commonly known as: 6516 Valor Court, Mobile, Alabama 36618.
Any property address provided is not part of the legal description of the property sold herein and in the event of any discrepancy, the legal description referenced herein shall control.
Together with the hereditaments and appurtenances thereunto belonging and all fixtures now attached to and used in connection with the premises herein described.
Said sale will be subject to the right of way easements and restrictions of record in the Probate Office of Mobile County, Alabama, and will be subject to existing special assessments and liens of record, if any, which might adversely affect the title to the subject property.
Said property will be sold on an “As Is, Where Is” basis without warranty or recourse, express or implied as to title, use and/or enjoyment. Said property will also be sold subject to the right(s) of redemption of all parties entitled thereto. Neither the mortgagee, nor the officers, directors, attorneys, employees, agents or authorized representative of the mortgagee make any representation or warranty relating to the title or any physical, environmental, health or safety conditions existing in, on, at or relating to the property offered for sale. Any and all responsibilities or liabilities arising out of or in any way relating to any such condition, including those suggested by Code of Alabama (1975) § 35-4-271, expressly are disclaimed.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
Said sale will be made for the purpose of paying the indebtedness secured by the above-described mortgage, and the proceeds thereof will be applied as provided by the terms of said mortgage and modifications thereof. The Mortgagee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate.
The failure of any high bidders to pay the purchase price and close this sale shall, at the option of the Mortgagee, be cause for rejection of the bid, and if the bid is rejected, Mortgagee shall have the option of making the sale to the next highest bidder who is able, capable and willing to comply with the terms thereof.
The sale will be conducted during lawful hours of sale between 11:00am to 4:00pm. A non-refundable cashier’s check in the amount of $ 10,000.00 is required on auction day from the successful bidder and with the balance of funds within 24 hours both payable to Reynolds, Reynolds & Little, LLC. Balance payable funds may be wired. Wire instructions will be provided by the auctioneer to the successful bidder.
This sale is subject to postponement or cancellation.
PNC BANK, N.A.
Mortgagee
c/o Robert D. Reynolds
Reynolds, Reynolds & Little, L.L.C.
Attorneys for Mortgagee
Post Office Box 1389
Montgomery, Alabama 36102-1389
Telephone: (334) 832-9553
File No.: 3714.015
Call News March 13, 20, and 27, 2024
|
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Amber M. Helveston, an unmarried woman, originally in favor of Mortgage Electronic Registration Systems, Inc., acting solely as nominee for Fairway Independent Mortgage Corporation, on July 17, 2020, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Instrument Number 2020042863; the undersigned Lakeview Loan Servicing, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on April 18, 2024, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 25, Revised Park Place of Satsuma as recorded in Map Book 85, Page 110 of the records in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 209 Gayle Ln , Satsuma, AL 36572. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Lakeview Loan Servicing, LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 24-01580-MT-AL
Call News 03/13/2024, 03/20/2024, 03/27/2024
|
NOTICE OF FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Kenneth O. Chambers an unmarried man, to Mortgage Electronic Registration Systems, Inc., as Mortgagee, as nominee for Trustmark National Bank, its successors and assigns , on July 25, 2022, said mortgage being recorded in the Office of the Judge of Probate of Mobile County, Alabama, on July 27, 2022, as Document Number 2022049869. Freedom Mortgage Corporation, the current holder, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Mobile County Courthouse, in Mobile, Alabama, on April 11, 2024, during the legal hours of sale, the following described real estate, situated in Mobile County, Alabama, to-wit:
From the Northwest corner of Section 29, Township 3 South, Range 2 West, Mobile County, Alabama, run thence South 2710.8 feet to a point; thence East 16.5 feet to an iron marker for the point of beginning; said point being on the South line of a 50 foot roadway; thence East along said roadway 213.5 feet to a point; thence South 105 feet to a point: thence West 213.5 feet to a point on the East line of Section Road, thence North 105 feet to the point of beginning. LESS AND EXCEPT that portion taken for the right-of-way for Ching Dairy Road.
More commonly known as: 3150 Ching Dairy Rd, Mobile, AL 36618
This Property will be sold on as “as is, where is” basis, without warranty or recourse, expressed or implied as to title, use and/or enjoyment and will be sold subject to the right of redemption of all parties entitled thereto. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expense of foreclosure. The successful bidder must tender certified funds by noon the next business day to Law Office of Halliday, Watkins & Mann, P.C. Certified funds must be in the form of a wire transfer, bank or credit union’s cashier’s check, or bank official check payable to Halliday, Watkins & Mann, P.C. Halliday, Watkins & Mann, P.C. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. If sale is voided, Mortgagee/Transferee shall return the bid amount to the successful purchaser and the Mortgagee/Transferee shall not be liable to the purchase for any damages. If the sale is set aside for any reason, the purchaser at the sale shall be only entitled to a return of the deposit and bid amount, if paid. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit is purchase price against the expenses of sale and indebtedness secured by the real estate. This sale is subject to postponement or cancellation.
Freedom Mortgage Corporation (“Transferee”)
Halliday, Watkins & Mann, P.C.
244 Inverness Center Drive
Birmingham, AL 35242
Phone: (801) 355-2886
Call News March 20, 2024, March 27, 2024, April 3, 2024
|
FORECLOSURE NOTICE
Default having been made in the payment of the indebtedness described in and secured by that certain vendor’s lien deed executed by DEXTER L. HART and APRIL T. BEARD, to THAMES, JACKSON, HARRIS COMPANY, INC., dated May 26, 2022 and recorded as Instrument No. 2022041182 of the records in the Office of the Judge of Probate, Mobile County, Alabama; and which vendor’s lien deed was thereafter transferred and assigned to CIRAS, L.L.C. by instrument dated May 27, 2022 and recorded as Instrument No. 2022041183 of the aforesaid Probate Court Records; and which vendor’s lien deed was lastly transferred and assigned to THAMES, JACKSON, HARRIS COMPANY, INC. by instrument which is presently being recorded in the aforesaid Probate Court Records, and the undersigned holder of said vendor’s lien deed having declared the entire indebtedness due and payable notice is hereby given that the undersigned, under and by virtue of the powers contained in said vendor’s lien deed, will sell at public outcry for cash to the highest bidder during the legal hours of sale on the 3rd day of April, 2024, in front of the front or main door of the Courthouse of Mobile County Alabama, Government Plaza, in Mobile, Alabama, the following described real property lying and being situated in the County of Mobile, State of Alabama, to-wit:
Lot 11, Block 1, Tropical Place, according to plat thereof recorded in Deed Book 117, Page 81 of the records in the Office of the Judge of Probate, Mobile County, Alabama.
Said sale is made for the purpose of paying the indebtedness secured by said vendor’s lien deed and all charges as provided therein and the expense incident thereto, including a reasonable attorney’s fee.
Said property will be sold on an “as is, where is” basis subject to any easements, encumbrances, and exceptions contained in said vendor’s lien deed and those contained in the records of the Office of the Judge of Probate where the above-described property is situated. Said property will be sold without warranty or recourse, expressed or implied as to title, use and/or enjoyment, and will be sold subject to the right of redemption of all parties entitled thereto.
ALABAMA LAW GIVES SOME PERSONS WHO HAVE AN INTEREST IN PROPERTY THE RIGHT TO REDEEM THE PROPERTY UNDER CERTAIN CIRCUMSTANCES. PROGRAMS MAY ALSO EXIST THAT HELP PERSONS AVOID OR DELAY THE FORECLOSURE PROCESS. AN ATTORNEY SHOULD BE CONSULTED TO HELP YOU UNDERSTAND THESE RIGHTS AND PROGRAMS AS A PART OF THE FORECLOSURE PROCESS.
THAMES, JACKSON, HARRIS COMPANY, INC.
Holder of said Vendor’s Lien Deed
JIM H. FERNANDEZ
FERNANDEZ, CRANE & COMBS, L.L.C.
Attorneys for Holder of said Vendor’s Lien Deed
Post Office Box 162
Mobile, Alabama 36601
(251) 433-0738
Call News March 13, March 20 and March 27, 2024
|
NOTICE OF
MORTGAGE FORECLOSURE SALE
STATE OF ALABAMA
COUNTY OF MOBILE
Default having been made of the terms of the loan documents secured by that certain mortgage executed by Jacqueline Chambers An Unmarried Person to ERA Mortgage dated September 30, 2003; said mortgage being recorded on October 14, 2003, in Book 5474, Page 1785 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to NewRez LLC d/b/a Shellpoint Mortgage Servicing in Instrument 2024001926 in the Office of the Judge of Probate of Mobile County, ALABAMA.
The undersigned, NewRez LLC d/b/a Shellpoint Mortgage Servicing, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 11th day of April, 2024 the following property, situated in Mobile County, Alabama, to-wit:
Lot 2, Fillingim Subdivision, according to plat thereof recorded in Map Book 27, page 24 in the records in the office of the Judge of Probate, Mobile County, Alabama.
Said property is commonly known as 2700 Clubhouse Road, Mobile, AL 36605.
Should a conflict arise between the property address and the legal description the legal description will control.
Said property will be sold subject to any outstanding ad valorem taxes (including taxes which are a lien, but not yet due and payable), the right of redemption of any taxing authority, all outstanding liens for public utilities which constitute liens upon the property, any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, easements, rights-of-way, zoning ordinances, restrictions, special assessments, covenants, the statutory right of redemption pursuant to Alabama law, and any matters of record including, but not limited to, those superior to said Mortgage first set out above. Said property will be sold on an “as-is” basis without any representation, warranty or recourse against the above-named or the undersigned. The successful bidder must present certified funds in the amount of the winning bid at the time and place of sale.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The sale will be conducted subject (1) to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and (2) to final confirmation and audit of the status of the loan with the holder of the Mortgage.
NEWREZ LLC D/B/A SHELLPOINT MORTGAGE SERVICING
as holder of said mortgage
McCalla Raymer Leibert Pierce, LLC
Two North Twentieth
2 20th Street North, Suite 1000
Birmingham, AL 35203
(205) 216-4238
FT21@mccalla.com
File No. 24-05717AL
www.foreclosurehotline.net
Call News 03/13/2024,03/20/2024,03/27/2024
|
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Catherine Hall, an unmarried female, originally in favor of Mortgage Electronic Registration Systems, Inc. acting solely as nominee for Embrace Home Loans, Inc., on April 15, 2022, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Instrument Number 2022028328; the undersigned Nationstar Mortgage, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on May 1, 2024, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 6, Block 78, North Mobile, as recorded in Deed Book 145, Page 252-263 of the records in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 71 6th Ave , Chickasaw, AL 36611. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Nationstar Mortgage, LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 24-01475-NS-AL
Call News 03/13/2024, 03/20/2024, 03/27/2024
|
FORECLOSURE NOTICE
Default having been made in the payment of the indebtedness described in and secured by that certain vendor’s lien deed conveyed from GERALD P. SMITH to MILFORD W YEAGER, III and LESLEY YEAGER, recorded in Mobile County, AL Probate Ct. records Instrument No. 2013017261 said default continuing notice is hereby given that the undersigned will, under and by virtue of the power of sale contained in said vendor’s lien deed, sell at public outcry for cash to the highest bidder at 12:00 noon on April 3, 2024, at the front door of the Mobile County Courthouse the following described property to wit:
Parcel 1: Commencing at the Northwest corner of Southwest Quarter of Northeast Quarter of Section 18, Township 3 South, Range 3 West, run East 625 feet to point of beginning, continue East 1330 feet; thence South 45 feet; thence West 1330 feet; thence North 55 feet, Section 18, Township 3 South, Range 3 West.
Parcel 2: Parcel A: Beginning at the Southwest corner of Northeast Quarter of Northeast Quarter of Section 18, Township 3 South, Range 3 West; thence North 00 degrees, 07 minutes, 12 seconds West 444.8 feet to a point on South line of 30 foot access road, said point being 30 feet South of South line of property conveyed in Real Property Book 2706, page 997; thence run South 89 degrees, 50 minutes, 04 seconds East along South line of said access road and along South line of property of Lord as described in aforesaid deed 638.55 feet to old fence line; thence South 02 degrees, 10 minutes, 28 seconds East along said fence line 444.73 feet; thence North 89 degrees, 52 minutes, 20 seconds West 654.49 feet to point of beginning.
Parcel B: Beginning at Northwest corner of above described Parcel A of land and run North 89 degrees, 50 minutes, 04 seconds West 296.88 feet, more or less, to point on East line of right-of-way of Carr Road; thence run North 26 degrees, 15 minutes West along East right-of-way of Carr Road 33.5 feet; thence run South 89 degrees, 50 minutes, 04 seconds East along the South line of the property of Lord, 414.9 feet to a point; thence run South 00 degrees, 09 minutes, 56 seconds West 30 feet to point on South line of Lord property and the North line of the above described parcel of land; thence run North 89 degrees, 50 minutes, 04 seconds West 103.12 feet to point of beginning.
Alabama Law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as part of the foreclosure process.
Said sale will be made for the purpose of paying said indebtedness and expenses incident to said sale, including a reasonable attorney’s fee.
CLIFFORD C. SHARPE
Attorney for Lienholder
307 Morgan Ave.
Mobile, AL 36606
Call News March 13, 20, 27, 2024
|
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Carmin R Mark, An Unmarried Woman, originally in favor of National City Mortgage a division of National City Bank Of Indiana, on April 10, 2006, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 5950 Page 755; the undersigned Ally Bank, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on April 17, 2024, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 19, Woodland Hills, Unit Five as recorded in Map Book 105, Page 57 in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 8326 Woodspointe , Semmes, AL 36575. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. Ally Bank, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 24-01910-CE-AL
Call News 03/13/2024, 03/20/2024, 03/27/2024
|
FORECLOSURE NOTICE
Default having been made by the herein referenced Grantee in the terms of that certain Vendor’s Lien Deed executed on June 3rd 2023, by Cora M. Williams as Grantee, to Iras Development Company Inc., Profit-Sharing Plan, as Grantor, which said Vendor’s Lien Deed was recorded in the Office of the Judge of Probate, Mobile County, Alabama, in Instrument #2023035096; and default continuing under said Vendor’s Lien Deed, by virtue of and pursuant to the power of sale contained in said Vendor’s Lien Deed, the following described real property will be sold at public outcry, for cash, to the highest bidder, in front of the north entrance of the Mobile County Government Plaza Courthouse Building located at 205 Government Street, Mobile, Alabama 36602, during the legal hours of sale, on March 3rd , 2024.
Lot 55 GRAND FARMS, 5TH ADDITION, as recorded on that certain plat recorded in Map Book 65, Page 92, in the Office of the Judge of Probate of Mobile County, Alabama; including a 1977 Fleetwood Mobile Home(2) Bedroom (2) Baths, AS IS, WHERE IS, WITHOUT ANY WARRANTY WHATSOEVER.
IRAS DEVELOPMENT COMPANY INC., PROFIT-SHARING PLAN, Grantor and Holder of said Vendor’s Lien
WILLIAM B. JACKSON, II
STOKES & CLINTON, P.C.
Attorneys for Vendor’s Lien Holder
Post Office Box 991801
Mobile, Alabama 36691
(251) 460-2400
23-00733 JL
Call News March 6, 13, 20, 2024
|
NOTICE OF FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Bruce M. Snider, JR, an unmarried man, to Mortgage Electronic Registration Systems, Inc., as Mortgagee, as nominee for Mortgage Team 1, Inc., its successors and assigns, on December 23, 2021, said mortgage being recorded in the Office of the Judge of Probate of Mobile County, Alabama, on December 27, 2021, as Document Number 2021084459. Freedom Mortgage Corporation, the current holder, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Mobile County Courthouse, in Mobile, Alabama, on April 17, 2024, during the legal hours of sale, the following described real estate, situated in Mobile County, Alabama, to-wit:
Lot 1, Block A, Havenwood West, Unit One, according to plat thereof recorded in Map Book 22, page 24, of the records in the Office of the Judge of Probate of Mobile County, Alabama.
More commonly known as: 6510 Sharon Way, Theodore, AL 36582
This Property will be sold on as “as is, where is” basis, without warranty or recourse, expressed or implied as to title, use and/or enjoyment and will be sold subject to the right of redemption of all parties entitled thereto. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expense of foreclosure. The successful bidder must tender certified funds by noon the next business day to Law Office of Halliday, Watkins & Mann, P.C. Certified funds must be in the form of a wire transfer, bank or credit union’s cashier’s check, or bank official check payable to Halliday, Watkins & Mann, P.C. Halliday, Watkins & Mann, P.C. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. If sale is voided, Mortgagee/Transferee shall return the bid amount to the successful purchaser and the Mortgagee/Transferee shall not be liable to the purchase for any damages. If the sale is set aside for any reason, the purchaser at the sale shall be only entitled to a return of the deposit and bid amount, if paid. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit is purchase price against the expenses of sale and indebtedness secured by the real estate. This sale is subject to postponement or cancellation.
Freedom Mortgage Corporation (“Transferee”)
Halliday, Watkins & Mann, P.C.
244 Inverness Center Drive
Birmingham, AL 35242
Phone: (801) 355-2886
Call News March 20, 2024, March 27, 2024, April 3, 2024
|
NOTICE OF
MORTGAGE FORECLOSURE SALE
STATE OF ALABAMA
COUNTY OF MOBILE
Default having been made of the terms of the loan documents secured by that certain mortgage executed by Detris L Franklin, A Single Woman to Mortgage Electronic Registration Systems, Inc., as mortgagee, as nominee for Branch Banking and Trust Company, its successors and assigns dated December 19, 2012; said mortgage being recorded on December 20, 2012, in Book 6969, Page 1027, as having been modified by an agreement recorded on and recorded in Book 7461, Page 125 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to Truist Bank in Instrument 2022057330 in the Office of the Judge of Probate of Mobile County, ALABAMA.
The undersigned, Truist Bank, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 4th day of April, 2024 the following property, situated in Mobile County, Alabama, to-wit:
Lot 28, GRANATO ESTATES, according to the map thereof recorded in the Office of the Judge of Probate of Mobile County, Alabama at Map Book 24, Page 27.
Said property is commonly known as 7870 Pauline Ct, Semmes, AL 36575.
Should a conflict arise between the property address and the legal description the legal description will control.
Said property will be sold subject to any outstanding ad valorem taxes (including taxes which are a lien, but not yet due and payable), the right of redemption of any taxing authority, all outstanding liens for public utilities which constitute liens upon the property, any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, easements, rights-of-way, zoning ordinances, restrictions, special assessments, covenants, the statutory right of redemption pursuant to Alabama law, and any matters of record including, but not limited to, those superior to said Mortgage first set out above. Said property will be sold on an “as-is” basis without any representation, warranty or recourse against the above-named or the undersigned. The successful bidder must present certified funds in the amount of the winning bid at the time and place of sale.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The sale will be conducted subject (1) to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and (2) to final confirmation and audit of the status of the loan with the holder of the Mortgage.
TRUIST BANK
as holder of said mortgage
McCalla Raymer Leibert Pierce, LLC
Two North Twentieth
2 20th Street North, Suite 1000
Birmingham, AL 35203
(205) 216-4238
FT21@mccalla.com
File No. 24-05647AL
www.foreclosurehotline.net
Call News 03/13/2024,03/20/2024,03/27/2024
|
MORTGAGE FORECLOSURE SALE
Default having being made in the payment of the indebtedness secured by that certain mortgage dated March 21, 2022 executed by Amanda Nicole Thomas aka Amanada N. Thomas a married woman, and Wayne Lacy, Jr. her husband, in favor of Mortgage Electronic Registration Systems, Inc., solely as a nominee for Trustmark National Bank, said Mortgage being recorded March 28, 2022, in Inst. No. 2022023117, in the Office of the Judge of Probate of Mobile County, Alabama; having later been assigned to Trustmark National Bank by instrument recorded in Inst. # 2024010793, in the Office of the Judge of Probate of Mobile County, Alabama. Said default continues and notice is hereby given that the undersigned, Trustmark National Bank, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash at the main entrance to the County Courthouse, Mobile County, Alabama on 04/03/2024, during the legal hours of sale, the following described real estate situated in Mobile County, Alabama, to-wit:
Lot 25, Brantley Park, according to plat thereof recorded in Map Book 12, page 35, of the records in the Office of the Judge of Probate of Mobile County, Alabama.
For informational purposes only, the property address is: 1271 Yale Ct, Mobile, AL 36618. Any property address provided is not part of the legal description of the property sold herein and in the event of any discrepancy, the legal description referenced herein shall control.
THIS PROPERTY WILL BE SOLD ON AN “AS-IS, WHERE-IS” BASIS, SUBJECT TO ANY EASEMENTS, ENCUMBRANCES, AND EXCEPTIONS REFLECTED IN THE MORTGAGE AND THOSE CONTAINED IN THE RECORDS OF THE OFFICE OF THE JUDGE OF PROBATE OF THE COUNTY WHERE THE ABOVE-DESCRIBED PROPERTY IS SITUATED. THIS PROPERTY WILL BE SOLD WITHOUT WARRANTY OR RECOURSE, EXPRESS OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
This sale is made for the purpose of paying the indebtedness secured by mortgage as well as the expenses of foreclosure, including a reasonable attorney’s fees and other purposes set out in said mortgage.
Trustmark National Bank
Paul K. Lavelle, Esq.
Attorney for Mortgagee
Spina, & Lavelle, P.C.
One Perimeter Park South-Suite 400N
Birmingham, Alabama 35243
(205) 298-1800
40-FC-24-01054
Call News March 6, 2024, March 13, 2024 and March 20, 2024
|
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by David G. Franklin to Mortgage Electronic Registration Systems, Inc., as nominee for Bank of America, N.A., dated December 30, 2021 said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Instrument Number 2022001158 . Said mortgage was subsequently sold, assigned and transferred to BANK OF AMERICA, N.A.. Under and by virtue of the power of sale contained in said mortgage, the undersigned, BANK OF AMERICA, N.A., will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse in Mobile County, Alabama on April 25, 2024, during the legal hours of sale, all of its right, title, and interest in and to the following describe real estate situated in Mobile County, Alabama, to-wit:
LOT 3, BLOCK 6, DEVONSHIRE SUBDIVISION, SECOND UNIT, ACCORDING THE MAP THEREOF RECORDED IN MAP BOOK 11, PAGE 198, OF THE RECORDS IN THE OFFICE OF THE JUDGE OF THE PROBATE COURT OF MOBILE COUNTY, ALABAMA.
Property Street Address for Informational Purposes: 6687 Lincolnshire Rd Mobile AL 36619
Said property will be sold “AS IS”. NO REPRESENTATION OR WARRANTY, EXPRESSED OR IMPLIED, IS MADE AS TO THE TITLE OF SAID PROPERTY. Said property is subject to any title deficiencies including but not limited to: any outstanding ad valorem taxes – including taxes which are a lien but not yet due and payable, federal tax liens any matters which might be disclosed by an accurate survey and inspection of the property, any assessments liens, encumbrances, zoning ordinances, restrictions, covenants, and matters of record superior to the Mortgage first set out above. Said property will be sold subject to the right of redemption of all parties entitled thereto. The highest bidder must tender the total amount of the winning bid in certified funds at the time and place of sale. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand the rights and programs as a part of the foreclosure process.
This sale will be made for the purpose of paying the same and all expenses of this sale, as provided in said Mortgage and by Alabama law. This sale is subject to postponement or cancellation.
**This is an attempt to collect a debt and any information obtained may be used for that purpose.**
BANK OF AMERICA, N.A., Mortgagee or Transferee
Jonathan Smothers, Esq
ALAW
420 North 20th Street, Suite 2249
Birmingham, AL 35203
Attorney for Mortgagee/Transferee
24-004205
Call News 3/06/2024, 3/13/2024, 3/20/2024, 3/27/2024
|
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Adrianne Fisher and George Seko, Wife and Husband, originally in favor of Mortgage Electronic Registration Systems, Inc., acting solely as nominee for RBC Bank (USA), on May 26, 2010, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 6659 Page 1690; the undersigned PNC Bank, National Association, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on April 11, 2024, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 4, according to the Survey of Pecan Grove Place, Phase One, as recorded in Map Book 109, Page 87, in the Office of the Judge of Probate of Mobile County, Alabama.. Property street address for informational purposes: 3730 Harvest Court , Mobile, AL 36695. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. PNC Bank, National Association, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 24-01415-PN-AL
Call News 03/06/2024, 03/13/2024, 03/20/2024
|
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Candice Mason, a married woman, and Phillip Mason, her husband, originally in favor of Mortgage Electronic Registration Systems, Inc. as nominee for Challenge Financial Investors, Corp., on May 18, 2006, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book-5974 Page-1485; the undersigned U.S. Bank Trust National Association, not in its individual capacity but solely as owner trustee for RCF2 Acquisition Trust, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on April 17, 2024, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 79, Brighton Estates, Phase Two, according to the plat thereof recorded in Map Book 98, Page 17 of the records in the Office of the Judge of Probate, Mobile County, Alabama, together with the retention pond as shown on the record plat of subdivision.. Property street address for informational purposes: 9810 Brighton Court , Chunchula, AL 36521. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. U.S. Bank Trust National Association, not in its individual capacity but solely as owner trustee for RCF2 Acquisition Trust, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 24-00740-SF-AL
Call News 03/06/2024, 03/13/2024, 03/20/2024
|
FORECLOSURE NOTICE
Default having been made in the payment of the indebtedness described in and secured by that certain mortgage executed by CHADWICK PATRONAS, unmarried, as Mortgagor(s) to Regions Bank, as Mortgagee, dated the 10th day of July, 2020, and recorded in Instrument No. 2020045205 et seq. of the records in the Office of the Judge of Probate Court of Mobile County, Alabama; said default continuing, notice is hereby given that the undersigned will, under and by virtue of the power of sale contained in said mortgage sell at public outcry for cash to the highest bidder during legal hours of sale, on the 5th day of April, 2024, in the city of Mobile, at the front door of the Court House of Mobile County, Alabama, the following described real property situated in the County of Mobile, State of Alabama, to-wit:
ALL OF THEIR INTEREST IN AND TO THAT CERTAIN REAL PROPERTY SITUATED IN THE COUNTY OF MOBILE, STATE OF ALABAMA, MORE PARTICULARLY DESCRIBED AS FOLLOWS: LOT 109, UNIT NO. 3, CROMWELL PLACE, ACCORDING TO THE PLAT THEREOF RECORDED IN MAP BOOK 5. PAGES 665-666 OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE, MOBILE COUNTY, ALABAMA. THIS CONVEYANCE SUBJECT TO THE FOLLOWING EXCEPTIONS: 1. BUILDING SETBACK LINE, DRAINAGE AND UTILITY LINE EASEMENTS AND NOTES OR RESTRICTIONS AS SHOWN ON RECORDED PLAT OF SAID SUBDIVISION. 2. RESTRICTIVE COVENANTS CONTAINED IN INSTRUMENT RECORDED IN DEED BOOK 563, PAGE 43. SUBJECT TO RESTRICTIONS, RESERVATIONS, EASEMENTS, COVENANTS, OIL, GAS, OR MINERAL RIGHTS OF RECORD, IF ANY.
Subject to that certain mortgage dated May 30, 2019 and recorded in Instrument No. 2019030375 in said Probate Court records.
This property will be sold on an “as is, where is” basis, subject to any easements, encumbrances, reservations and exceptions reflected in the mortgage and/or those contained in the records of the office of the Judge of Probate of the county where the above-described property is situated. This property will be sold without warranty or recourse, expressed or implied as to title, use and/or enjoyment and will be sold subject to the right of redemption of all parties entitled thereto. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
Said sale will be made for the purpose of paying said indebtedness and the expenses incident to this sale, including a reasonable attorney’s fee, and the other purposes set out in said mortgage. The sale will be conducted subject to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and also to final confirmation and audit of the status of the loan with the Mortgagee.
REGIONS BANK
Holder of said Mortgage
Goodman G. Ledyard
PIERCE LEDYARD JOHNSTON, P.C.
Attorneys for Mortgagee
Post Office Box 161389
Mobile, Alabama 36616
(251) 338-1300
Call News March 6, 13, 20, 2024
|
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Joe C Trent and Millie M Trent, as joint tenants, originally in favor of Mortgage Electronic Registration Systems, Inc. acting solely as nominee for Primelending, A Plainscapital Company, on October 22, 2010, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 6720 Page 1625; the undersigned GITSIT Solutions LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on April 17, 2024, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 30, Vista Ridge, Unit Four, according to plat thereof recorded in Map Book 40, Page 79 of the records in the Office of the Judge of Probate, Mobile County, Alabama.. Property street address for informational purposes: 3852 Isabel Way West , Mobile, AL 36693. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. GITSIT Solutions LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 24-01237-KO-AL
Call News 03/06/2024, 03/13/2024, 03/20/2024
|
NOTICE OF
MORTGAGE FORECLOSURE SALE
STATE OF ALABAMA
COUNTY OF MOBILE
Default having been made of the terms of the loan documents secured by that certain mortgage executed by Kristen Leigh Rozar An Unmarried Person to Mortgage Electronic Registration Systems, Inc., as mortgagee, as nominee for Primary Residential Mortgage, Inc., its successors and assigns dated July 24, 2020; said mortgage being recorded on August 12, 2020, as Instrument No. 2020048408 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to Lakeview Loan Servicing, LLC by assignment recorded in Deed Book 2023074336, Page 1 in the Office of the Judge of Probate of Mobile County, ALABAMA.
The undersigned, Lakeview Loan Servicing, LLC, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 4th day of April, 2024 the following property, situated in Mobile County, Alabama, to-wit:
The land referred to in this Commitment is described as follows:
Lot 1, Homestead Hills, Unit Two, according to map or plat thereof as recorded in Map Book 22, Page 106, of the records in the Office of the Judge of Probate, Mobile County, Alabama.
Said property is commonly known as 12310 Oakdale Ave, Grand Bay, AL 36541.
Should a conflict arise between the property address and the legal description the legal description will control.
Said property will be sold subject to any outstanding ad valorem taxes (including taxes which are a lien, but not yet due and payable), the right of redemption of any taxing authority, all outstanding liens for public utilities which constitute liens upon the property, any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, easements, rights-of-way, zoning ordinances, restrictions, special assessments, covenants, the statutory right of redemption pursuant to Alabama law, and any matters of record including, but not limited to, those superior to said Mortgage first set out above. Said property will be sold on an “as-is” basis without any representation, warranty or recourse against the above-named or the undersigned. The successful bidder must present certified funds in the amount of the winning bid at the time and place of sale.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The sale will be conducted subject (1) to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and (2) to final confirmation and audit of the status of the loan with the holder of the Mortgage.
LAKEVIEW LOAN SERVICING, LLC
as holder of said mortgage
McCalla Raymer Leibert Pierce, LLC
Two North Twentieth
2 20th Street North, Suite 1000
Birmingham, AL 35203
(205) 216-4238
FT21@mccalla.com
File No. 23-05549AL
www.foreclosurehotline.net
Call News 03/06/2024,03/13/2024,03/20/2024
|
VENDOR’S LIEN FORECLOSURE NOTICE
Default having been made in the terms of that certain Vendor’s Lien, executed on 7/8/2020, by Xavier Moore, as Mortgagor, to ZDA, LLC as Mortgagee, which said Mortgage is recorded in the Office of the Judge of Probate, Mobile County, Alabama, as Inst. # 2020043404 on 7/22/2020, and ZDA, LLC is currently the holder of the Vendor’s Lien, and underlying promissory note secured thereby, and ZDA, LLC is authorized to enforce the terms of the Vendor’s Lien secured by said promissory note; and default having continued under the terms of said Vendor’s Lien, and by virtue of Alabama Code Section 35-10-3 and 35-10-2, the following described real property will be sold at public outcry, for cash, to the highest bidder, in front of the Courthouse door of said County, during the legal hours of sale, on 4/3/2024
Parcel One:
All that certain lot of land situated in the Northeast corner of Lot 32 in Range 1 West of the Owens Division of the Saint Louis Tract, said lot having a frontage of 50 feet on the West side of the Saint Stephens Road, with a depth Westward of One Hundred and Ninety Five (195) feet, with the same width in the rear as in front; being part of the same property conveyed to Emmette W. Smith and wife by Ethel M. Calhoun, by deed dated February 20, 1926, and recorded in Deed Book 208, Pages 566-7 of the Probate Court Records of Mobile, County, Alabama.
Parcel Two:
Commencing at a point on the present West boundary line of the right-of-way of St. Stephens Road 375-1/4 feet distant Southwardly from the point where the South boundary line of Alley No. 11 (as shown on the map of the Owen Division of the St. Louis Tract on file in the Chancery Court of Mobile County, Alabama, in Chancery Case No. 2066) intersects the present West boundary line of the right-of-way of said St. Stephens Road, and from said Point of Beginning run Westwardly along a line parallel to and 375-1/4 feet distance Southwardly from the South boundary line of said Alley No. 11 for a distance of 200 feet to a point, thence run Southwardly along a line parallel to said West boundary line of said right-of-way of St. Stephens Road 53 feet, more or less, to the North boundary line of the Lot 32 as shown by said Map of the Owen Division of the St. Louis Tract, thence run Eastwardly along said North boundary line of said Lot 32, a distance of 200 feet, more or less, to the West boundary line of said right-of-way of St. Stephens Road, thence run Northwardly along said West boundary line of said right-of-way of St. Stephens Road, 53 feet, more or less, to the point of beginning, said property being a part of Lot 33 as shown by said Map of the Owen Division of the St. Louis Tract, and being now or formerly bounded on the East by St. Stephens Road, on the North and West by the property of John Cheeseman, and on the South by the property of Alton Glenwood Moore and Evie D. Moore.
Subject to all easements, restrictions and reservations appearing of record. Said sale will also be made subject to any Federal Tax Liens and/or Special Assessments of any nature, if any, which might adversely affect the title to the property.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The property is being sold “as is, where is”. Said property is sold without warranty or recourse, expressed or implied as to title, use or enjoyment.
This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure.
This sale is subject to postponement or cancellation.
Kent D. McPhail
McPhail Sanchez, LLC
Attorney for Mortgagee/Transferee
126 Government Street
Mobile, AL 36602
251-438-2333
Call News 3/6/2024, 3/13/2024, 3/20/2024 and 3/27/2024
|
MORTGAGE FORECLOSURE SALE
Default having being made in the payment of the indebtedness secured by that certain mortgage dated October 20, 2003 executed by Jaydee E. Johnson, an unmarried man, in favor of Mortgage Electronic Registration Systems, Inc. solely as nominee for First Federal Bank, FSB, said Mortgage being recorded October 22, 2003, in Book 5480, Page 0364, in the Office of the Judge of Probate of Mobile County, Alabama; having later been assigned to U.S. Bank Trust National Association, not in its individual capacity but solely as owner trustee for RCF 2 Acquisition Trust by instrument recorded in Inst. #20240000602, in the Office of the Judge of Probate of Mobile County, Alabama. Said default continues and notice is hereby given that the undersigned, U.S. Bank Trust National Association, not in its individual capacity but solely as owner trustee for RCF 2 Acquisition Trust c/o U.S. Bank Trust National Association, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash at the main entrance to the County Courthouse, Mobile County, Alabama on 04/17/2024, during the legal hours of sale, the following described real estate situated in Mobile County, Alabama, to-wit:
Lot D resubdivision of Lots 28, 29, 30, Natchez Highway Estates Subdivision, according to plat thereof recorded in map book 99, page 43 of the Records in the Office of the Judge of Probate, Mobile County, Alabama.
Together with a non-exclusive permanent easement for ingress and egress described as follows: beginning at the northwest corner of Lot 1, Natchez Highway Estates Subdivision, as recorded in map book 44, page 24, and revised in map book 54, page 76, thence run north 01 degrees 31 minutes east 547.89 feet; thence run north 89 degrees 54 minutes 20 seconds west 165.0 feet to the east line of Natchez Highway; thence run north along said east line of Natchez Highway 60 feet; thence run south 89 degrees 54 minutes 20 seconds east 225 feet; thence run south 0 degrees 31 minutes west 607.89 feet to the north line of said Lot I, Natchez Highway Estates Subdivision; thence run north 89 degrees 23 minutes 20 seconds west 60 feet to the point of beginning. Being known as a portion of Randy Road.
For informational purposes only, the property address is: 13915 Willow Branch Ln, Wilmer, AL 36587. Any property address provided is not part of the legal description of the property sold herein and in the event of any discrepancy, the legal description referenced herein shall control.
THIS PROPERTY WILL BE SOLD ON AN “AS-IS, WHERE-IS” BASIS, SUBJECT TO ANY EASEMENTS, ENCUMBRANCES, AND EXCEPTIONS REFLECTED IN THE MORTGAGE AND THOSE CONTAINED IN THE RECORDS OF THE OFFICE OF THE JUDGE OF PROBATE OF THE COUNTY WHERE THE ABOVE-DESCRIBED PROPERTY IS SITUATED. THIS PROPERTY WILL BE SOLD WITHOUT WARRANTY OR RECOURSE, EXPRESS OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
This sale is made for the purpose of paying the indebtedness secured by mortgage as well as the expenses of foreclosure, including a reasonable attorney’s fees and other purposes set out in said mortgage.
U.S. Bank Trust National Association, not in its individual capacity but solely as owner trustee for RCF 2 Acquisition Trust c/o U.S. Bank Trust National Association
Paul K. Lavelle, Esq.
Attorney for Mortgagee
Spina, & Lavelle, P.C.
One Perimeter Park South-Suite 400N
Birmingham, Alabama 35243
(205) 298-1800
37-FC-22-01169
Call News March 6, 2024, March 13, 2024 and March 20, 2024
|
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by George D. Jones and Janis P. Jones, husband and wife, originally in favor of AmSouth Bank, on March 16, 2006, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Book 5953 Page 1378; the undersigned PNC Bank, National Association, successor by merger to RBC Bank (USA), formerly known as RBC Centura Bank , as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on May 15, 2024, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot(s) 41, The Dominion, Unit One, according to the map or plat thereof recorded in Map Book 60 Page 124, in the Office of the Judge of Probate, Mobile County, Alabama. The hereinabove described property being one and the same as described in mortgage recorded in Book 5963 Page 1378.. Property street address for informational purposes: 1145 Dominion Dr E , Mobile, AL 36695. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. PNC Bank, National Association, successor by merger to RBC Bank (USA), formerly known as RBC Centura Bank , (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 24-00675-PN-AL
Call News 03/06/2024, 03/13/2024, 03/20/2024
|
MORTGAGE FORECLOSURE SALE
Default having being made in the payment of the indebtedness secured by that certain mortgage dated August 16, 2021 executed by Austin Jacob Collins an unmarried person, in favor of Mortgage Electronic Registration Systems, Inc., acting solely as a nominee for Trustmark National Bank, said Mortgage being recorded August 17, 2021, in Inst. # 2021053783, in the Office of the Judge of Probate of Mobile County, Alabama; having later been assigned to Trustmark National Bank by instrument recorded in Inst. # 2024009462, in the Office of the Judge of Probate of Mobile County, Alabama. Said default continues and notice is hereby given that the undersigned, Trustmark National Bank, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash at the main entrance to the County Courthouse, Mobile County, Alabama on 05/01/2024, during the legal hours of sale, the following described real estate situated in Mobile County, Alabama, to-wit:
Lot 49 of Briargrove, Phase One, according to plat thereof recorded in Map Book 122, Page 107 of the records in the Office of the Judge of Probate of Mobile County, Alabama.
For informational purposes only, the property address is: 2509 Hedgerow Dr., Mobile, AL 36695. Any property address provided is not part of the legal description of the property sold herein and in the event of any discrepancy, the legal description referenced herein shall control.
THIS PROPERTY WILL BE SOLD ON AN “AS-IS, WHERE-IS” BASIS, SUBJECT TO ANY EASEMENTS, ENCUMBRANCES, AND EXCEPTIONS REFLECTED IN THE MORTGAGE AND THOSE CONTAINED IN THE RECORDS OF THE OFFICE OF THE JUDGE OF PROBATE OF THE COUNTY WHERE THE ABOVE-DESCRIBED PROPERTY IS SITUATED. THIS PROPERTY WILL BE SOLD WITHOUT WARRANTY OR RECOURSE, EXPRESS OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
This sale is made for the purpose of paying the indebtedness secured by mortgage as well as the expenses of foreclosure, including a reasonable attorney’s fees and other purposes set out in said mortgage.
Trustmark National Bank
Paul K. Lavelle, Esq.
Attorney for Mortgagee
Spina, & Lavelle, P.C.
One Perimeter Park South-Suite 400N
Birmingham, Alabama 35243
(205) 298-1800
40-FC-24-01052
Call News March 6, 2024, March 13, 2024 and March 20, 2024
|
NOTICE OF SALE UNDER POWER
FORECLOSURE NOTICE
WHEREAS, default has occurred in the performance of the covenants, terms and conditions of a mortgage from 3 FIVES, LLC to MORTGAGE ELECTRONIC REGISTRATION SYSTEMS INC. AS MORTGAGEE, AS NOMINEE FOR LIMA ONE CAPITAL, LLC, on the 30th day of July, 2021, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, on September 23, 2021, at Instrument Number 2021063185, Mobile County, Alabama Records, said Mortgage having subsequently been transferred and assigned to Wilmington Savings Fund Society, FSB, not in its individual capacity, but solely as Owner Trustee of MFA 2022-RTL1 Trust, by instrument recorded in the aforesaid Probate Office; notice is hereby given that the undersigned Wilmington Savings Fund Society, FSB, not in its individual capacity, but solely as Owner Trustee of MFA 2022-RTL1 Trust, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash in front of the main entrance of the Courthouse in Mobile, Mobile County, Alabama, on April 3, 2024, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:
LOTS 19 AND 20, RESUBDIVISION OF LOTS 1, 2, 3 AND 4, BLOCK 6, ISLAND FARMS, ACCORDING TO PLAT THEREOF RECORDED IN THE OFFICE OF THE JUDGE OF PROBATE COURT OF MOBILE COUNTY,
ALABAMA IN MAP BOOK 6, PAGE 290.
Said legal description being controlling, however the property is more commonly known as 2430 ILA DRIVE, MOBILE, AL 36605.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
This property will be sold on an “as is, where is” basis, subject to any easements, encumbrances, and exceptions reflected in the mortgage and those contained in the records of the Office of the Judge of Probate in the county where the above-described property is situated. This property will be sold subject to the right of redemption of all parties entitled thereto and subject to any outstanding ad valorem taxes (including taxes which are a lien, whether or not now due and payable). This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation.
Wilmington Savings Fund Society, FSB, not in its individual capacity, but solely as Owner Trustee of MFA 2022-RTL1 Trust, Mortgagee/Transferee
THE BELOW LAW FIRM MAY BE HELD TO BE ACTING AS A DEBT COLLECTOR, UNDER FEDERAL LAW. IF SO, ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
Rubin Lublin, LLC, Attorney for Mortgagee/Transferee
3145 Avalon Ridge Place, Suite 100, Peachtree Corners, GA 30071
Telephone Number: (877) 813-0992 Case No. LMA-24-00356-1
rlselaw.com/property-listing
Call News 03/06/2024, 03/13/2024, 03/20/2024
|
NOTICE OF SALE UNDER POWER
FORECLOSURE NOTICE
WHEREAS, default has occurred in the performance of the covenants, terms and conditions of a mortgage from Terrica Pugh and Marion Pugh, Wife & Husband to MORTGAGE ELECTRONIC REGISTRATION SYSTEMS INC. AS MORTGAGEE, AS NOMINEE FOR SYNOVUS BANK , on the 10th day of March, 2022, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, on March 11, 2022, at Instrument Number 2022018805, Mobile County, Alabama Records, said Mortgage having subsequently been transferred and assigned to CITIZENS BANK NA f/k/a RBS CITIZENS NA, by instrument recorded in the aforesaid Probate Office; notice is hereby given that the undersigned CITIZENS BANK NA f/k/a RBS CITIZENS NA, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash in front of the main entrance of the Courthouse in Mobile, Mobile County, Alabama, on April 17, 2024, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:
LOT 21, ACCORDING TO THE MAP OF FIGURES WAY SUBDIVISION, AS RECORDED IN THE OFFICE OF THE JUDGE OF PROBATE OF MOBILE COUNTY, ALABAMA, IN MAP BOOK 85, PAGE 116.
Said legal description being controlling, however the property is more commonly known as 4709 AUGUSTA DR, EIGHT MILE, AL 36613.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
This property will be sold on an “as is, where is” basis, subject to any easements, encumbrances, and exceptions reflected in the mortgage and those contained in the records of the Office of the Judge of Probate in the county where the above-described property is situated. This property will be sold subject to the right of redemption of all parties entitled thereto and subject to any outstanding ad valorem taxes (including taxes which are a lien, whether or not now due and payable). This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation.
CITIZENS BANK NA f/k/a RBS CITIZENS NA, Mortgagee/Transferee
THE BELOW LAW FIRM MAY BE HELD TO BE ACTING AS A DEBT COLLECTOR, UNDER FEDERAL LAW. IF SO, ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
Rubin Lublin, LLC, Attorney for Mortgagee/Transferee
3145 Avalon Ridge Place, Suite 100, Peachtree Corners, GA 30071
Telephone Number: (877) 813-0992 Case No. CBN-24-00454-1
rlselaw.com/property-listing
Call News 03/13/2024, 03/20/2024, 03/27/2024
|
NOTICE OF SALE UNDER POWER
FORECLOSURE NOTICE
WHEREAS, default has occurred in the performance of the covenants, terms and conditions of a mortgage from Reuben Thomas Gulley a/k/a Reuben Gulley, a married man to Mortgage Electronic Registration Systems, Inc., as mortgagee, as nominee for Fairway Independent Mortgage Corporation, on the 3rd day of January, 2018, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, on January 8, 2018, in Deed/Mortgage Book LR7592, Page 1599, Mobile County, Alabama Records, said Mortgage having subsequently been transferred and assigned to Lakeview Loan Servicing, LLC, by instrument recorded in the aforesaid Probate Office; notice is hereby given that the undersigned Lakeview Loan Servicing, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash at the main entrance to the Mobile county courthouse located at 205 Government Street, Mobile, AL 36652 in Mobile, Mobile County, Alabama, on May 1, 2024, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:
LOT 76, BRIDGE MILL, PHASE TWO, ACCORDING TO THE PLAT THEREOF RECORDED IN MAP BOOK 111, PAGE 89, OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE OF MOBILE COUNTY, ALABAMA.
Said legal description being controlling, however the property is more commonly known as 4065 FENWICK LOOP W, MOBILE, AL 36619.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
This property will be sold on an “as is, where is” basis, subject to any easements, encumbrances, and exceptions reflected in the mortgage and those contained in the records of the Office of the Judge of Probate in the county where the above-described property is situated. This property will be sold subject to the right of redemption of all parties entitled thereto and subject to any outstanding ad valorem taxes (including taxes which are a lien, whether or not now due and payable). This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation.
Lakeview Loan Servicing, LLC, Mortgagee/Transferee
THE BELOW LAW FIRM MAY BE HELD TO BE ACTING AS A DEBT COLLECTOR, UNDER FEDERAL LAW. IF SO, ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
Rubin Lublin, LLC, Attorney for Mortgagee/Transferee
3145 Avalon Ridge Place, Suite 100, Peachtree Corners, GA 30071
Telephone Number: (877) 813-0992 Case No. FLB-24-00594-1
rlselaw.com/property-listing
Call News 03/20/2024, 03/27/2024, 04/03/2024
|
NOTICE OF SALE UNDER POWER
FORECLOSURE NOTICE
WHEREAS, default has occurred in the performance of the covenants, terms and conditions of a mortgage from LAWANDA FAYE FIELDS to AHP SERVICING LLC, on the 17th day of December, 2021, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, on December 27, 2021, at Instrument Number 2021084461, Mobile County, Alabama Records, said Mortgage having subsequently been transferred and assigned to Madhu J Pallath, by instrument recorded in the aforesaid Probate Office; notice is hereby given that the undersigned Madhu J Pallath, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash in front of the main entrance of the Courthouse in Mobile, Mobile County, Alabama, on April 3, 2024, during the legal hours of sale, all of its right, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit:
LOT NUMBER TWENTY (20) IN BLOCK “D” NEESE`S SECOND ADDITION TO PRICHARD, ACCORDING TO THE MAP RECORDED IN THE MAP BOOK 3, PAGE 339-340 IN THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE COURT OF MOBILE COUNTY, ALABAMA.
Said legal description being controlling, however the property is more commonly known as 136 S WILLIAMS AVE NKA 142 S WILLIAMS AVE, PRICHARD, AL 36610.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
This property will be sold on an “as is, where is” basis, subject to any easements, encumbrances, and exceptions reflected in the mortgage and those contained in the records of the Office of the Judge of Probate in the county where the above-described property is situated. This property will be sold subject to the right of redemption of all parties entitled thereto and subject to any outstanding ad valorem taxes (including taxes which are a lien, whether or not now due and payable). This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation.
Madhu J Pallath, Mortgagee/Transferee
THE BELOW LAW FIRM MAY BE HELD TO BE ACTING AS A DEBT COLLECTOR, UNDER FEDERAL LAW. IF SO, ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
Rubin Lublin, LLC, Attorney for Mortgagee/Transferee
3145 Avalon Ridge Place, Suite 100, Peachtree Corners, GA 30071
Telephone Number: (877) 813-0992 Case No. ASC-23-06257-1
rlselaw.com/property-listing
Call News 03/06/2024, 03/13/2024, 03/20/2024
|
POSTPONEMENT
FORECLOSURE NOTICE
Default having been made in the payment of the indebtedness described in and secured by that certain Mortgage executed by Donald E. Richard, a single man, to Acceptance Loan Company, Inc. dated September 19th, 2011, and recorded in Real Property Book 6820, Page 1523 and transferred to FIRST US BANK by Instrument dated
October 2nd, 2023 and recorded in Instrument No. 2023063781, and said default continuing; notice is hereby given that the undersigned will, under and by virtue of the power of sale contained in said Mortgage, sell at public outcry for cash, at the Government Street entrance of the Mobile County Courthouse at 205 Government Street, Mobile, Alabama, to the highest bidder, on March 7th, 2024, during the legal hours of sale, the following described real property situated in the County of Mobile, State of Alabama, to-wit:
Lot No. 7, Block 55D, of the Land Disposal Map Unit 12, Map 4, Central Texas Street Area, Project Ala-R-38 as recorded in Map Book 29, Page 73, Probate Court Records, Mobile County, Alabama.
SUBJECT TO:
1. Except therefrom such oil, gas and other minerals in, on and under said real property, together with all rights in connection therewith, as have previously been reserved by or conveyed to others than the grantor.
2. Easements, reservations, restrictions, rights-of-way and setback lines as reserved and shown on record Map of subdivision.
3. All matters of Public record including any utility easement as recorded in the Office of the Judge of Probate, Mobile County, Alabama.
4. Any prior reservations or conveyance of minerals, together with release of damages of minerals of every kind and character, including but not limited to oil and gas in, on and under subject property.
THE REFERENCED FORECLOSURE SALE ABOVE IS CONTINUED TO APRIL 11TH, 2024, DURING LEGAL HOURS OF SALE AT THE MOBILE COUNTY COURTHOUSE, MOBILE, ALABAMA
Said sale will be made for the purpose of paying said indebtedness and the expenses incidental to said sale, including a reasonable attorney’s fee.
FIRST US BANK as holder of said first Mortgage
William C. Poole, LLC
Attorneys at Law
917 Western America Circle
Suite 210
Mobile, Alabama 36609
(251) 344-5015
THIS IS AN ATTEMPT TO COLLECT A DEBT ANY INFORMATION OBTAINED WILL BE USED FOR THAT PURPOSE.
Call News March 20, 2024
|
MORTGAGE FORECLOSURE SALE
Default having been made in the payment of the indebtedness secured by that certain mortgage executed by Charles E. Osborne an unmarried man, originally in favor of Mortgage Electronic Registration Systems, Inc., as nominee for Envoy Mortgage, LTD, on June 12, 2020, said mortgage recorded in the Office of the Judge of Probate of Mobile County, Alabama, in Instrument No. 2020036211; the undersigned Lakeview Loan Servicing, LLC, as Mortgagee/Transferee, under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash, in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama, on January 31, 2024, during the legal hours of sale, all of its rights, title, and interest in and to the following described real estate, situated in Mobile County, Alabama, to-wit: Lot 36, Theodore Highlands, Sixth Addition according to Plat thereof recorded in Map Book 19, Page 126, of the records in the Office of the Judge of Probate of Mobile County, Alabama.. Property street address for informational purposes: 6851 Sandra Drive , Theodore, AL 36582. THIS PROPERTY WILL BE SOLD ON AN “AS IS, WHERE IS” BASIS, WITHOUT WARRANTY OR RECOURSE, EXPRESSED OR IMPLIED AS TO TITLE, USE AND/OR ENJOYMENT AND WILL BE SOLD SUBJECT TO THE RIGHT OF REDEMPTION OF ALL PARTIES ENTITLED THERETO. Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process. This sale is made for the purpose of paying the indebtedness secured by said mortgage, as well as the expenses of foreclosure. The successful bidder must tender a non-refundable deposit of Five Thousand Dollars ($5,000.00) in certified funds made payable to Tiffany & Bosco, P.A. at the time and place of the sale. The balance of the purchase price plus any deed recording costs and transfer taxes must be paid in certified funds by noon the next business day at the Law Office of Tiffany & Bosco, P.A. at the address indicated below. Tiffany & Bosco, P.A. reserves the right to award the bid to the next highest bidder should the highest bidder fail to timely tender the total amount due. The Mortgagee/Transferee reserves the right to bid for and purchase the real estate and to credit its purchase price against the expenses of sale and the indebtedness secured by the real estate. This sale is subject to postponement or cancellation. The above mortgage foreclosure sale has been postponed from January 31, 2024 until March 13, 2024, during the legal hours of sale in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama. The above mortgage foreclosure sale has been postponed from March 13, 2024 until May 15, 2024, during the legal hours of sale in front of the main entrance of the Courthouse at Mobile, Mobile County, Alabama. Lakeview Loan Servicing, LLC, (“Transferee”) Tiffany & Bosco, P.A., 2501 20th Place South, Suite 300, Homewood, AL 35223
www.tblaw.com
TB File Number: 23-08786
Call News January 3, 2024, January 10, 2024, January 17, 2024, February 7, 2024, March 20, 2024
|
POSTPONEMENT FORECLOSURE NOTICE
Default having been made in the payment of the indebtedness described in and secured by that certain mortgage from DEBORAH NETTLES to SIXTY ST. FRANCIS STREET, INC. dated August 14, 2008 and recorded in in Real Property Book 6427, Page 1997 of the records in the Office of the Judge of Probate, Mobile County, Alabama; and which mortgage thereafter transferred and assigned to TRUST BANK OF OLNEY, IL AS CUSTODIAN FOR JOHN C. GRAY, IRA, by instrument dated September 19, 2022 and recorded as Instrument No. 2022064845 of the aforesaid Probate Court Records; and which mortgage was lastly transferred and assigned to TRUST BANK OF OLNEY, IL AS CUSTODIAN FOR LINDA DAVIS GRAY, IRA, by instrument dated June 1, 2023 and recorded as Instrument No. 2023040516 of the aforesaid Probate Court Records, and the undersigned holder of said mortgage having declared the entire indebtedness due and payable notice is hereby given that the undersigned, under and by virtue of the powers contained in said mortgage, will sell at public outcry for cash to the highest bidder during the legal hours of sale on the 3rd day of APRIL, 2024, in front of the front or main door of the Courthouse of Mobile County Alabama, Government Plaza, in Mobile, Alabama, the following described real property lying and being situated in the County of Mobile, State of Alabama, to-wit:
Lot G-7, Pine Springs Farm, First Extension, according to the plat thereof recorded in map Book 10, Page 277 in the Office of the Judge of Probate, Mobile County, Alabama.
Said sale is made for the purpose of paying the indebtedness secured by said mortgage and all charges as provided therein and the expense incident thereto, including a reasonable attorney’s fee.
Said property will be sold on an “as is, where is” basis subject to any easements, encumbrances, and exceptions contained in said mortgage and those contained in the records of the Office of the Judge of Probate where the above-described property is situated. Said property will be sold without warranty or recourse, expressed or implied as to title, use and/or enjoyment, and will be sold subject to the right of redemption of all parties entitled thereto.
ALABAMA LAW GIVES SOME PERSONS WHO HAVE AN INTEREST IN PROPERTY THE RIGHT TO REDEEM THE PROPERTY UNDER CERTAIN CIRCUMSTANCES. PROGRAMS MAY ALSO EXIST THAT HELP PERSONS AVOID OR DELAY THE FORECLOSURE PROCESS. AN ATTORNEY SHOULD BE CONSULTED TO HELP YOU UNDERSTAND THESE RIGHTS AND PROGRAMS AS A PART OF THE FORECLOSURE PROCESS.
THIS NOTICE IS FOR THE EXPRESS PURPOSE OF PUBLICIZING THE POSTPONEMENT OF THE SCHEDULED FORECLOSURE SALE FROM THE LEGAL HOURS OF SALE ON MARCH 6, 2024 UNTIL THE LEGAL HOURS OF SALE ON APRIL 3, 2024, WHICH POSTPONEMENT WAS ANNOUNCED ON MARCH 6, 2024.
TRUST BANK OF OLNEY, IL AS CUSTODIAN FOR LINDA DAVIS GRAY, IRA
Holder of said Mortgage
JIM H. FERNANDEZ
FERNANDEZ, CRANE & COMBS, L.L.C.
Attorneys for Holder of said Mortgage
Post Office Box 162
Mobile, Alabama 36601
(251) 433-0738
Call News March 20, 2024
|
POSTPONEMENT FORECLOSURE NOTICE
Default having been made in the payment of the indebtedness described in and secured by that certain mortgage executed by ADLEAN BONITA JOHNSON dated October 27, 1995 and recorded in Book 4304, Page 1217, Probate Records of Mobile County, Alabama to bhf contracting, inc.; and thereafter said mortgage was assigned to SIXTY ST. FRANCIS STREET, INC. by instrument dated October 27, 1995 and recorded in Real Property Book 4304, Page 1222 of the aforesaid probate court records; and thereafter said mortgage was assigned unto First Community Bank by instrument dated July 24, 2015 and recorded in Book LR7286, Page 521 of the aforesaid probate court records; and thereafter said mortgage was assigned unto SNAPPER POOL I, LLC, by instrument recorded May 25, 2018 in Book LR 7639, Page 1462 of the aforesaid probate court records (specifically reference is made to item 20 of said Assignment); and which mortgage was thereafter transferred to CIRAS, LLC by instrument dated October 6, 2021 and recorded as Instrument No. 2021066464 of the aforesaid Probate court records; and which mortgage was thereafter transferred to SIXTY ST. FRANCIS STREET, INC. by instrument presently being recorded in the aforesaid Probate Court Records; and the undersigned holder of said mortgage having declared the entire indebtedness due and payable notice is hereby given that the undersigned, under and by virtue of the powers contained in said mortgage will sell at public outcry for cash to the highest bidder during the legal hours of sale on the 3rd day of April, 2024, at the front or main door of the Government Street entrance of Government Plaza, the Courthouse of Mobile County Alabama, , the following described real property lying and being situated in the County of Mobile, State of Alabama, to-wit:
Lot 15 of Park Court Subdivision, First Addition, according to the plat thereof recorded in Map Book 8, Page 99 of the records in the Office of the Judge of Probate, Mobile County, Alabama.
Said sale is made for the purpose of paying the indebtedness secured by said mortgage and all charges as provided therein and the expense incident thereto, including a reasonable attorney’s fee.
Said property will be sold on an “as is, where is” basis subject to any easements, encumbrances, and exceptions contained in said mortgage and those contained in the records of the Office of the Judge of Probate where the above-described property is situated. Said property will be sold without warranty or recourse, expressed or implied as to title, use and/or enjoyment, and will be sold subject to the right of redemption of all parties entitled thereto.
ALABAMA LAW GIVES SOME PERSONS WHO HAVE AN INTEREST IN PROPERTY THE RIGHT TO REDEEM THE PROPERTY UNDER CERTAIN CIRCUMSTANCES. PROGRAMS MAY ALSO EXIST THAT HELP PERSONS AVOID OR DELAY THE FORECLOSURE PROCESS. AN ATTORNEY SHOULD BE CONSULTED TO HELP YOU UNDERSTAND THESE RIGHTS AND PROGRAMS AS A PART OF THE FORECLOSURE PROCESS.
THIS NOTICE IS FOR THE EXPRESS PURPOSE OF PUBLICIZING THE POSTPONEMENT OF THE SCHEDULED FORECLOSURE SALE FROM THE LEGAL HOURS OF SALE ON MARCH 6, 2024 UNTIL THE LEGAL HOURS OF SALE ON APRIL 3, 2024, WHICH POSTPONEMENT WAS ANNOUNCED ON MARCH 6, 2024.
SIXTY ST. FRANCIS STREET, INC.
Holder of said Vendor’s Lien Deed
JIM H. FERNANDEZ
FERNANDEZ, CRANE & COMBS, L.L.C.
Attorneys for Holder of said Vendor’s Lien Deed
Post Office Box 162
Mobile, Alabama 36601 / (251) 433-0738
Call News March 20, 2024
|
NOTICE OF
MORTGAGE FORECLOSURE SALE
STATE OF ALABAMA
COUNTY OF MOBILE
Default having been made of the terms of the loan documents secured by that certain mortgage executed by Ashlon G James An Unmarried Man to Mortgage Electronic Registration Systems, Inc., as mortgagee, as nominee for First Federal Bank, its successors and assigns dated October 29, 2014; said mortgage being recorded on November 3, 2014, in Book LR7203, Page 582 in the Office of the Judge of Probate of Mobile County, Alabama. Said Mortgage was last sold, assigned and transferred to U.S. BANK NATIONAL ASSOCIATION in Instrument 2023057992 in the Office of the Judge of Probate of Mobile County, ALABAMA.
The undersigned, U.S. BANK NATIONAL ASSOCIATION under and by virtue of the power of sale contained in said mortgage, will sell at public outcry to the highest bidder for cash before the main entrance of the Court House in Mobile County, Alabama during the legal hours of sale (between 11am and 4pm), on the 1st day of February, 2024 the following property, situated in Mobile County, Alabama, to-wit:
Lot 22, Block A, Rosswood, according to plat thereof recorded in Map Book 8, page 248 of the records in the office of the Judge of Probate, Mobile County, Alabama.
Said property is commonly known as 501 Farnell Ln, Mobile, AL 36606.
Should a conflict arise between the property address and the legal description the legal description will control.
Said property will be sold subject to any outstanding ad valorem taxes (including taxes which are a lien, but not yet due and payable), the right of redemption of any taxing authority, all outstanding liens for public utilities which constitute liens upon the property, any matters which might be disclosed by an accurate survey and inspection of the property, any assessments, liens, encumbrances, easements, rights-of-way, zoning ordinances, restrictions, special assessments, covenants, the statutory right of redemption pursuant to Alabama law, and any matters of record including, but not limited to, those superior to said Mortgage first set out above. Said property will be sold on an “as-is” basis without any representation, warranty or recourse against the above-named or the undersigned. The successful bidder must present certified funds in the amount of the winning bid at the time and place of sale.
Alabama law gives some persons who have an interest in property the right to redeem the property under certain circumstances. Programs may also exist that help persons avoid or delay the foreclosure process. An attorney should be consulted to help you understand these rights and programs as a part of the foreclosure process.
The sale will be conducted subject (1) to confirmation that the sale is not prohibited under the U.S. Bankruptcy Code and (2) to final confirmation and audit of the status of the loan with the holder of the Mortgage.
U.S. BANK NATIONAL ASSOCIATION
as holder of said mortgage
McCalla Raymer Leibert Pierce, LLC
Two North Twentieth
2 20th Street North, Suite 1000
Birmingham, AL 35203
(205) 216-4238
FT21@mccalla.com
File No. 23-05471AL
www.foreclosurehotline.net
AMENDMENT TO NOTICE OF MORTGAGE FORECLOSURE SALE
The sale date under the above mentioned Notice of Mortgage Foreclosure Sale has been postponed until April 4, 2024, and public notice thereof having been given, the above notice is hereby republished with this amendment.
Call News 12/27/2023,01/03/2024,01/10/2024,03/20/2024
|
Estate Administration
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of LAURA LEA MCELDERRY
Case No. 2024-0106
Take notice that Letters of Administration have been granted to the below named party on the 14th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred
VALERIE MCLEAN as Administratrix of the estate of LAURA LEA MCELDERRY, deceased
Attorney of Record
RON PEARMAN, Esq.
Call News March 20, 27, and April 3, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of CARRIE L. JAMES, Deceased
Case No. 2024-0422
Take notice that Letters Testamentary have been granted to the below named party on the 13th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
VALENCIA RENITA LOWEN as Executrix under the last will and testament of CARRIE L. JAMES, Deceased
Attorney of Record:
Christopher Luke Nixon, Esq.
P. O. Box 2727
Mobile, AL 36652
Call News March 20, 27, and April 3, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of MAE JOYCE BELCHER, Deceased
Case No. 2024-0079
Take notice that Letters Testamentary have been granted to the below named party on the 13th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
GAIL BAILEY as Executrix under the last will and testament of MAE JOYCE BELCHER, Deceased
Attorney of Record:
Douglas R. Martin, Esq.
P. O. Box 132
Coden, AL 36523
Call News March 20, 27, and April 3, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of LUCILLE B. BOYLES, Deceased
Case No. 2024-0424
Take notice that Letters Testamentary have been granted to the below named party on the 13th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
GEORGE H. BOYLES JR. as Executor under the last will and testament of LUCILLE B. BOYLES, Deceased
Attorney of Record:
Michael R. Holberg, Esq.
P. O. Box 47
Mobile, AL 36601
Call News March 20, 27, and April 3, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of RANDOLPHE O SAFFORD
Case No. 2023-2488
Take notice that Letters of Administration have been granted to the below named party on the 18th day of January, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANTHONY M. HOFFMAN, as Administrator of the estate of RANDOLPHE O SAFFORD, Deceased
Attorney of Record:
ANTHONY M. HOFFMAN
Call News March 20, 27, and April 3, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of TERRY SCHRIMPSHER
Case No. 2023-2419
Take notice that Letters of Administration have been granted to the below named party on the 18th day of January, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANTHONY M. HOFFMAN, as Administrator
of the estate of TERRY SCHRIMPSHER, Deceased
Attorney of Record:
ANTHONY M. HOFFMAN
Call News March 20, 27, and April 3, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of MAVIS FLOURNOY JONES
Case No. 2023-0204
Take notice that Letters of Administration on the Annexed Will have been granted to the below named party on the 17th day of January, 2024, by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANTHONY M. HOFFMAN, as Administrator CTA under the last will and testament of MAVIS FLOURNOY JONES, Deceased
Attorney of Record:
ANTHONY M. HOFFMAN
P.O. BOX 11
MOBILE, AL 36601
Call News March 20, 27, and April 3, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of WILLIE JOHNSON
Case No. 2023-2403
Take notice that Letters of Administration have been granted to the below named party on the 18th day of January, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANTHONY M. HOFFMAN, as Administrator of the estate of WILLIE JOHNSON, Deceased
Attorney of Record:
ANTHONY HOFFMAN, ESQ.
Call News March 20, 27, and April 3, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of QUINTIN EUGENE TAYLOR, Deceased
Case No. 2023-2526
Take notice that Letters Testamentary have been granted to the below named party on the 4th day of January, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
MICHAEL HOUSTON TAYLOR as Executor under the last will and testament of QUINTIN EUGENE TAYLOR, Deceased
Attorney of Record:
Brenda J. Pierce, Esq.
P. O. Box 1084
Mobile, AL 36633
Call News March 20, 27, and April 3, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of RUBY PATTERSON BENJAMIN GRISSETT, Deceased
Case No. 2024-0055
Take notice that Letters Testamentary have been granted to the below named party on the 6th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
HOWARD POMPEY JR as Executor under the last will and testament of RUBY PATTERSON BENJAMIN GRISSETT, Deceased
Attorney of Record:
WILLIAM C. POOLE
917 Western America Circle, Suite 210
MOBILE, AL 36606
Call News March 20, 27, and April 3, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of MARY BELLE MCLAUGHLIN, Deceased
Case No. 2023-2269
Take notice that Letters Testamentary have been granted to the below named party on the 6th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
NOEL WILLIAM MCLAUGHLIN JR as Executor under the last will and testament of MARY BELLE MCLAUGHLIN, Deceased
Attorney of Record:
William C. Poole, Esq.
917 Western America Circle, Suite 210
Mobile, AL 36609
Call News March 20, 27, and April 3, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of SAMUEL L. WILLIAMSON JR., Deceased
Case No. 2024-0344
Take notice that Letters Testamentary have been granted to the below named party on the 7th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ROBERT HACKBARTH as Executor under the last will and testament of SAMUEL L. WILLIAMSON JR., Deceased
Attorney of Record:
B. Vaughan Drinkard, Esq.
1070 Government Street
Mobile, AL 36604
Call News March 20, 27, and April 3, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of LYNDA WADE
Case No. 2024-0215
Take notice that Letters of Administration have been granted to the below named party on the 11th day of March, . 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
MICHAEL W. WADE JR as Administrator of the estate of LYNDA WADE, deceased
Attorney of Record:
CAMILLE R. FORD, Esq.
Call News March 20, 27, and April 3, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of GEORGE W. SHIRES, Deceased
Case No. 2023-2133
Take notice that Letters Testamentary have been granted to the below named party on the 6th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
DEBORAH DIANE PRAYTOR as Executrix under the last will and testament of GEORGE W. SHIRES, Deceased
Attorney of Record:
J. Michael Newton, Esq.
605 Bel Air Blvd, Suite 22
Mobile, AL 36606
Call News March 20, 27, and April 3, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of EULA ROSEMARY SNYDER
Case No. 2024-0222
Take notice that Letters of Administration have been granted to the below named party on the 11th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
CHARLES A. SNYDER JR as Administrator of the estate of EULA ROSEMARY SNYDER, deceased
Attorney of Record:
HALEY H CARTER, Esq., Esq.
GILBERT DUKES III, Esq.
Call News March 20, 27, and April 3, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of WINSTON CHURCHILL BLANKS
Case No. 2023-2206
Take notice that Letters of Administration have been granted to the below named party on the 2nd day of January, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
CHERYL A BLANKS as Administratrix of the estate of WINSTON CHURCHILL BLANKS, deceased
Attorney of Record:
MELVIN W. BRUNSON, Esq.
900 WESTERN AMERICA CIRCLE
SUITE 201
MOBILE, AL 36609
Call News March 20, 27, and April 3, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of ALMA MAE CLEMENTS, Deceased
Case No. 2024-0348
Take notice that Letters Testamentary have been granted to the below named party on the 7th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred
LILLIAN C LINCOLN as Executrix under the last will and testament of ALMA MAE CLEMENTS, Deceased
Attorney of Record
Vivian G. Johnston, III, Esq.
813-E Downtowner Blvd
Mobile, AL 36609
Call News March 20, 27, and April 3, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JAMES RONALD POTTER, Deceased
Case No. 2024-0190
Take notice that Letters Testamentary have been granted to the below named party on the 7th day of February, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
CLARA D. POTTER as Executrix under the last will and testament of JAMES RONALD POTTER, Deceased
Attorney of Record:
Richard R. Williams, Esq.
160 S Cedar Street
Mobile, AL 36602
Call News March 13, 20, 27, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of ANNIE MOLETTE
Case No. 2024-0397
Take notice that Letters of Administration have been granted to the below named party on the 8th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANTHONY M. HOFFMAN, as Administrator of the estate of ANNIE MOLETTE, Deceased
Attorney of Record:
ANTHONY M. HOFFMAN
Call News March 13, 20, 27, 2027
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of SHIRLEY L. STEELE, Deceased
Case No. 2024-0377
Take notice that Letters Testamentary have been granted to the below named party on the 7th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
STEPHANIE L. BUSH as Executrix under the last will and testament of SHIRLEY L. STEELE, Deceased
Attorney of Record:
Gilbert F. Dukes, Ill, Esq.
Haley H. Carter, Esq.
2610-B Dauphin Street, Suite 101
Mobile, AL 36606
Call News March 13, 20, 27, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of HAROLD M. HAWKINS II, Deceased
Case No. 2024-0345
Take notice that Letters Testamentary have been granted to the below named party on the 7th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
RENE G. HAWKINS as Executrix under the last will and testament of HAROLD M. HAWKINS II, Deceased
Attorney of Record:
Kenneth A Watson, Esq.
11 North Water Street, Suite 1200
Mobile, AL 36602
Call News March 13, 20, 27, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of FR. PHILIP MCKENNA, Deceased
Case No. 2024-0173
Take notice that Letters Testamentary have been granted to the below named party on the 7th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
CLARE MCKENNA as Executrix under the last will and testament of FR. PHILIP MCKENNA, Deceased
Attorney of Record:
F. Grey Redditt, Jr., Esq.
11 North Water Street, Suite 24290
Mobile, AL 36602
Call News March 13, 20, 27, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of BILLY CHARLES BEDSOLE, Deceased
Case No. 2024-0081
Take notice that Letters Testamentary have been granted to the below named party on the 6th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
MAMIE D. BEDSOLE as Executrix under the last will and testament of BILLY CHARLES BEDSOLE, Deceased
Attorney of Record:
MAMIE D. BEDSOLE, PRO SE
308 SPRINGHILL WOODS DRIVE EAST
MOBILE, AL 36608
Call News March 13, 20, 27, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of LILLIAN ODESSA WOODS, Deceased
Case No. 2024-0350
Take notice that Letters Testamentary have been granted to the below named party on the 7th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
MARK GREGGS as Executor under the last will and testament of LILLIAN ODESSA WOODS, Deceased
Attorney of Record:
Robert M. Galloway, Esq.
P. O. Box 16629
Mobile, AL 36616
Call News March 13, 20, 27, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of KIMBERLY AVERY GARCIA, Deceased
Case No. 2023-2439
Take notice that Letters Testamentary have been granted to the below named party on the 7th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
AMANDA AVERY HILL as Executrix under the last will and testament of KIMBERLY AVERY GARCIA, Deceased
Attorney of Record:
John J. Crowley, Jr., Esq
2610-B Dauphin Street Suite 101
Mobile, AL 36608
Call News March 13, 20, 27, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of CHARLES BENNETT LONG, Deceased
Case No. 2024-0087
Take notice that Letters Testamentary have been granted to the below named party on the 6th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
JANE DONWEN LONG as Executrix under the last will and testament of CHARLES BENNETT LONG, Deceased
Attorney of Record:
John J. Crowley, Jr., Esq
2610-B Dauphin Street Suite 101
Mobile, AL 36608
Call News March 13, 20, 27, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of LINDA NEALY LANGSTON, Deceased
Case No. 2024-0347
Take notice that Letters Testamentary have been granted to the below named party on the 7th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
JULIUS JOHNSTON IV as Executor under the last will and testament of LINDA NEALY LANGSTON, Deceased
Attorney of Record:
Michael S. McNair, Esq.
2151 Government Street
Mobile, AL 36606
Call News March 13, 20, 27, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JOHN T. HEWETT, Deceased
Case No. 2024-0230
Take notice that Letters Testamentary have been granted to the below named party on the 29th day of February, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
JOHN E. HEWETT as Executor under the last will and testament of JOHN T. HEWETT, Deceased
Attorney of Record:
Janet Thornton, Esq.
P. O. Box 40446
Mobile, AL 36640
Call News March 13, 20, 27, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of ELMER ROGER LOLLEY, Deceased
Case No. 2024-0353
Take notice that Letters Testamentary have been granted to the below named party on the 7th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
MARGARET ROSE LOLLEY as Executrix under the last will and testament of ELMER ROGER LOLLEY, Deceased
Attorney of Record:
Jessica L. Welch, Esq.
P. O. Box 1988
Mobile, AL 36633
Call News March 13, 20, 27, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of WALTER L. BATTLES JR, Deceased
Case No. 2024-0084
Take notice that Letters Testamentary have been granted to the below named party on the 6th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
TAMARA M. BENNING as Executrix under the last will and testament of WALTER L. BATTLES JR, Deceased
Attorney of Record:
Creole G. Ruffin, Esq.
P. O. Box 40404
Mobile, AL 36640
Call News March 13, 20, 27, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of LAYMON PUCKETT
Case No. 2023-1972
Take notice that Letters of Administration have been granted to the below named party on the 2nd day of January, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
MARISSA PUCKETT as Administratrix of the estate of LAYMON PUCKETT, Deceased
Attorney of Record:
CODY S POE, ESQ.
507 CHURCH ST.
MOBILE, AL 36602
Call News March 13, 20, 27, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of RUTHIE MAE BOLDEN AKA RUTHIE M. BOLDEN, Deceased
Case No. 2023-2272
Take notice that Letters Testamentary have been granted to the below named party on the 27th day of February, 2024 by the HONORABLE EDWARD G. HAWKINS, Temporary Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
PAMELA BUFFORD as Executrix under the last will and testament of RUTHIE MAE BOLDEN AKA RUTHIE M. BOLDEN, Deceased
Attorney of Record:
WILLIAM C. POOLE
917 WESTERN AMERICA CIRCLE, SUITE 210
MOBILE, AL 36609
Call News March 13, 20, 27, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of RANDALL HENRY ADJESSOM
Case No. 2024-0093
Take notice that Letters of Administration have been granted to the below named party on the 6th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
AKOUVI ADJESSOM as Administratrix of the estate of RANDALL HENRY ADJESSOM, deceased
Attorney of Record:
R. MARK KIRKPATRICK, Esq.
Call News March 13, 20, 27, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of NORMA JEAN HENDRICKSON PERIGO AKA JEAN H. PERIGO, Deceased
Case No. 2023-2507
Take notice that Letters Testamentary have been granted to the below named parties on the 22nd day of February, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
TIFFANY M. MCCOY and DEBRA-MCCOY MCNICKLE as Co-Executrices under the last will and testament of NORMA JEAN HENDRICKSON PERIGO AKA JEAN H. PERIGO, Deceased
Attorney of Record:
A. EVANS CROWE
P. O. BOX 655
MOBILE, AL 36601
Call News March 13, 20, 27, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JULIE AVINGER PEREZ, Deceased
Case No. 2024-0291
Take notice that Letters Testamentary have been granted to the below named party on the 29th day of February, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
CHARLES F. PEREZ Jr. as Executor under the last will and testament of JULIE AVINGER PEREZ, Deceased
Attorney of Record:
Wesley H. Blacksher, Esq.
917 Western America Circle, Ste. 210
Mobile, AL 36609
Call News March 13, 20, 27, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of DAVID BRUCE EDMONDS, Deceased
Case No. 2024-0226
Take notice that Letters Testamentary have been granted to the below named party on the 15th day of February, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
DAVID B. EDMONDS JR as Executor under the last will and testament of DAVID BRUCE EDMONDS, Deceased
Attorney of Record:
Ron Pearman, Esq.
555-A Iroquois Street
Chickasaw, AL 36611
Call News March 13, 20, 27, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of HEATHER LORELEI CADWELL
Case No. 2023-1498
Take notice that Letters of Administration have been granted to the below named party on the 18th day of January, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANTHONY M. HOFFMAN, as Administrator of the estate of HEATHER LORELEI CADWELL, Deceased
Attorney of Record:
ANTHONY HOFFMAM, Esq.
Call News March 13, 20, 27, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of SIDNEY R. BOYKIN, Deceased
Case No. 2023-2117
Take notice that Letters Testamentary have been granted to the below named party on the 27th day of February, 2024 by the HONORABLE EDWARD G. HAWKINS, Temporary Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
JEANETTE CARLETTA WILSON as Executrix under the last will and testament of SIDNEY R. BOYKIN, Deceased
Attorney of Record:
CAMILLE R. FORD
P. O. BOX 2529
DAPHNE, AL 36526
Call News March 13, 20, 27, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JOANN MCLANEY, Deceased
Case No. 2023-2434
Take notice that Letters Testamentary have been granted to the below named party on the 27th day of February, 2024 by the HONORABLE EDWARD G. HAWKINS. Temporary Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
GREGORY A. MCLANEY as Executor under the last will and testament of JOANN MCLANEY, Deceased
Attorney of Record:
PATRICIA WINSTON HALL
4055 COTTAGE HILL ROAD SUITE 103-D
MOBILE, AL 36609
Call News March 6, 13, 20, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JULIA D CORLEY, Deceased
Case No. 2023-0759
Take notice that Letters Testamentary have been granted to the below named party on the 22nd day of February, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
PHYLLIS POYTHRESS as Executrix under the last will and testament of JULIA D. CORLEY, Deceased
Attorney of Record:
WESLEY H. BLACKSHER
917 WESTERN AMERICA CIRCLE, SUITE. 210
MOBILE, AL 36609
Call News March 6, 13, 20, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JEPTHA BLACKSHER WHITE-SPUNNER, Deceased
Case No. 2024-0332
Take notice that Letters Testamentary have been granted to the below named party on the 29th day of February, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
JOHN WHITE-SPUNNER as Executor under the last will and testament of JEPTHA BLACKSHER WHITE-SPUNNER, Deceased
Attorney of Record:
Gilbert F. Dukes, Ill, Esq.
Haley H. Carter, Esq.
2610-B Dauphin Street, Suite 101
Mobile, AL 36606
Call News March 6, 13, 20, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of THELES SUTTON WOODFIN, Deceased
Case No. 2024-0331
Take notice that Letters Testamentary have been granted to the below named party on the 29th day of February, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
LESLIE EDWARD WOODFIN as Executor under the last will and testament of THELES SUTTON WOODFIN, Deceased
Attorney of Record:
John C Brutkiewicz, Esq.
61 St. Joseph Street, Suite 210
Mobile, AL 36602
Call News March 6, 13, 20, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of CLYDINE E DOWNEY, Deceased
Case No. 2023-2440
Take notice that Letters Testamentary have been granted to the below named party on the 27th day of February, 2024 by the HONORABLE EDWARD a HAWKINS, Temporary Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
DARREL DOWNEY as Executor under the last will and testament of CLYDINE E DOWNEY, Deceased
Attorney of Record:
ROBERT M. GALLOWAY
P.O. BOX 16629
MOBILE, AL 36616
Call News March 6, 13, 20, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of MARY L. MCCALL, Deceased
Case No. 2023-2121
Take notice that Letters Testamentary have been granted to the below named party on the 23rd day of February, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
MICHELL BOND as Executrix under the last will and testament of MARY L. MCCALL, Deceased
Attorney of Record:
James Paul Clinton, Esq.
P. O. Box 991801
Mobile, AL 36691
Call News March 6, 13, 20, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of STEPHEN E. TILLMAN, Deceased
Case No. 2023-2371
Take notice that Letters Testamentary have been granted to the below named party on the 27th day of February, 2024 by the HONORABLE EDWARD G. HAWKINS, Temporary Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
STACY M. SUDDARTH as Executrix under the last will and testament of STEPHEN E. TILLMAN, Deceased
Attorney of Record:
MICHAEL R HOLBERG
P. O. BOX 47
MOBILE, AL 36601
Call News March 6, 13, 20, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of HARRIET FAYE HODGE AKA FAYE HALE HODGE AKA FAYE H. HODGE, Deceased
Case No. 2023-2229
Take notice that Letters Testamentary have been granted to the below named party on the 27th day of February, 2024 by the HONORABLE EDWARD G. HAWKINS, Temporary Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ROY BRUCE HODGE JR as Executor under the last will and testament of HARRIET FAYE HODGE’AKA FAYE HALE HODGE AKA FAYE H. HODGE, Deceased
Attorney of Record:
CHRISTOPHER A. TOMLINSON
724 N DEAN ROAD, SUITE 100
AUBURN, AL 36830
Call News March 6, 13, 20, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of ALVIN ALEXANDER SAWYER
Case No. 2023-2209
Take notice that Letters of Administration have been granted to the below named party on the 27th day of February, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
PAUL WORTHEY SR as Administrator of the estate of ALVIN ALEXANDER SAWYER, deceased
Attorney of Record:
ROBERT M. GALLOWAY, Esq.
Call News March 6, 13, 20, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of LINDA GUTERMUTH
Case No. 2024-0092
Take notice that Letters of Administration have been granted to the below named party on the 27th day of February, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
DAVID GUTERMUTH as Administrator of the estate of LINDA GUTERMUTH, deceased
Attorney of Record:
NEIL CHUNN JOHNSTON JR., Esq.
Call News March 6, 13, 20, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JAMES WARNER RAMEY JR, Deceased
Case No. 2024-0191
Take notice that Letters Testamentary have been granted to the below named party on the 23rd day of February, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANNIE ESTHER RAMEY as Executrix under the last will and testament of JAMES WARNER RAMEY JR, Deceased
Attorney of Record:
Andrew M. Jones, Esq.
P. O. Box 1746
Mobile, AL 36633
Call News March 6, 13, 20, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of DOROTHY MAE GREEN
Case No. 2024-0113
Take notice that Letters of Administration have been granted to the below named party on the 27th day of February, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
VERONICA BRYANT GWIN as Administratrix of the estate of DOROTHY MAE GREEN, deceased
Attorney of Record:
RONNIE L WILLIAMS, Esq.
Call News March 6, 13, 20, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of KENNETH WAYNE FORSYTH
Case No. 2024-0218
Take notice that Letters of Administration have been granted to the below named party on the 21st day of February, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANTHONY M. HOFFMAN, as Administrator of the estate of KENNETH WAYNE FORSYTH, Deceased
Attorney of Record:
ANTHONY M. HOFFMAN
Call News March 6, 13, 20, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of BOOKER T WILLIAMS
Case No. 2018-0268
Take notice that Letters of Administration have been granted to the below named party on the 21st day of February, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
NAPOLEON WILLIAMS as Administrator of the estate of BOOKER T WILLIAMS, deceased
Attorney of Record:
CYNTHIA PARRIS SMITH, Esq.
Call News March 6, 13, 20, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JAMES MICHAEL MATHENEY, Deceased
Case No. 2023-0991
Take notice that Letters Testamentary have been granted to the below named party on the 22nd day of February, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
PAMELA MICHELLE LEWIS as Executrix under the last will and testament of JAMES MICHAEL MATHENEY, Deceased
Attorney of Record:
Robert E. Clute, Esq.
P. O. Box 3125
Mobile, AL 36652
Call News March 6, 13, 20, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of RAY G. JOHNSTON
Case No. 2024-0209
Take notice that Letters of Administration have been granted to the below named party on the 20th day of February, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANTHONY M. HOFFMAN, as Administrator of the estate of RAY G. JOHNSTON, Deceased
Attorney of Record:
ROBERT M. GALLOWAY, Esq.
ANTHONY M. HOFFMAN, Esq.
Call News March 6, 13, 20, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of NOLAN SANDERS MIMS, Deceased
Case No. 2023-0666
Take notice that Letters of Administration on the Annexed Will have been granted to the below named party on the 22nd day of February, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
ANTHONY M. HOFFMAN
Administrator CTA under the last will and testament of NOLAN SANDERS MIMS, Deceased
Attorney of Record:
ANTHONY M. HOFFMAN
P. O. BOX 11
MOBILE, AL 36601
Call News March 6, 13, 20, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of MARY DUNNAM, Deceased
Case No. 2009-2665
Take notice that Letters Testamentary have been granted to the below named party on the 5th day of January, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
HAROLD W. POSTON I as Executor under the last will and testament of MARY DUNNAM, Deceased
Attorney of Record:
AMANDA J MILLER
Call News March 6, 13, 20, 2024
|
Court Proceeding
NOTICE OF COURT PROCEEDING
March 18, 2024
Case No. 2013-2225-6
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of CHRISTOPHER THOMAS SMITH, Deceased
On to-wit the 22nd day of April, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT BY SURETY as filed by WESTERN SURETY COMPANY. NOTICE is hereby given to all parties in interest, specifically KELLY D SMITH A/K/A KELLY HAWKINS, who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
JAMES J. DUFFY III
P.O. BOX 1109
MOBILE, AL 36633
Call News March 20, 27, and April 3, 2024
|
NOTICE OF COURT PROCEEDING
March 18, 2024
Case No. 2022-1942-2
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of ROBERT D HICKMAN Sr., Deceased
On to-wit the 10th day of June, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by JAMES GRESSETT HICKMAN III. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney: MICHAEL S. MCNAIR
2151 GOVERNMENT STREET
MOBILE, AL 36606
Call News March 20, 27, and April 3, 2024
|
NOTICE OF COURT PROCEEDING
March 15, 2024
Case No. 2022-1923-1
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of BETTY JEAN HENSLEY, Deceased
On to-wit the 3rd day of June, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by ALBERT CHARLES HENSLEY. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
BRIAN K. SMITHWECK
11 N. WATER STREET,
SUITE 23200
MOBILE, AL 36602
Call News March 20, 27, and April 3, 2024
|
NOTICE OF COURT PROCEEDING
March 18, 2024
Case No. 2013-0738-13
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of ELLA WILSON CONAWAY, Deceased
On to-wit the 22nd day of April, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by ERMA TAYLOR. NOTICE is hereby given to all parties in interest, specifically DOMINIC QUENTIN DANIEL, who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
BRENDA J PIERCE
P.O. BOX 1084
Mobile, AL 36633
Call News March 20, 27, and April 3, 2024
|
NOTICE OF ESTATE ADMINISTRATION
PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of LAURA L. MATTHEWS, Deceased
Case No. 2023-1584
Take notice that Letters Testamentary have been granted to the below named party on the 13th day of March, 2024 by the HONORABLE DON DAVIS, Judge of Probate of Mobile County Probate Court, Alabama and that all parties having claims against said estate should file the same with the Probate Court of said county within the time allowed by law, or they will be barred.
DEBRA A. MCCASKILL as Executrix under the last will and testament of LAURA L. MATTHEWS, Deceased
Attorney of Record:
Debra A. McCaskill, Pro Se
5679 County Road 49
Lower Peach Tree, AL 36751
Call News March 20, 27, and April 3, 2024
|
NOTICE OF COURT PROCEEDING
March 15, 2024
Case No. 2022-2120-5
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JANE FAYE COONER,
Deceased
On to-wit the 3rd day of June, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by WILLIAM DAVID COONER. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
PAMELA KIRKWOOD MILLSAPS
1809 OLD SHELL RD
Mobile, AL 36607
Call News March 20, 27, and April 3, 2024
|
NOTICE OF COURT PROCEEDING
March 14, 2024
Case No. 2021-2047-2
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of ALFREDO ALONSO
ESCOBEDO HERRERA, Deceased
On to-wit the 3rd day of June, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by ANTHONY M. HOFFMAN. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
MICHAEL R HOLBERG
P O. BOX 47
MOBILE, AL 36601
Call News March 20, 27, and April 3, 2024
|
NOTICE OF COURT PROCEEDING
March 13, 2024
Case No. 2021-1115-3
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of BARRY LEJOSEPH HARRIS SR, Deceased
On to-wit the 3rd day of June, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT BY SURETY as filed by WESTERN SURETY COMPANY. NOTICE is hereby given to all parties in interest, specifically TWANNA CARTER, who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
JAMES J. DUFFY III
P.O. BOX 1109
MOBILE, AL 36633
Call News March 20, 27, and April 3, 2024
|
NOTICE OF COURT PROCEEDING
March 12, 2024
Case No. 2013-1443-2
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of STEPHEN LANKFORD, Deceased
On to-wit the 22nd day of April, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Final Settlement and Petition to Determine Heirs as filed by WESTERN SURETY COMPANY. NOTICE is hereby given to all parties in interest, specifically TYESE M. WINSTON, KENNESHIA WINSTON, COURTNEY JOHNSON, who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
JAMES J. DUFFY III
P.O. BOX 1109
MOBILE, AL 36633
Call News March 20, 27, and April 3, 2024
|
NOTICE OF COURT PROCEEDING
March 01, 2024
Case No. 2022-1832-3
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JERRY WAYNE DAILEY, Deceased
On to-wit the 3rd day of June, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by ANTHONY M. HOFFMAN. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, DAVIS, Judge of Probate
Attorney:
ANTHONY M. HOFFMAN
P. O. BOX 11
Mobile, AL 36601
Call News March 20, 27, and April 3, 2024
|
NOTICE OF COURT PROCEEDING
March 13, 2024
Case No. 2022-0243-3
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of VIOLA SMALL, Deceased
On to-wit the 3rd day of June, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT AND REPORT OF INSOLVENCY as filed by ANTHONY M HOFFMAN. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
ANTHONY M. HOFFMAN
P. O. BOX 11
Mobile, AL 36601
Call News March 20, 27, and April 3, 2024
|
NOTICE OF COURT PROCEEDING
March 11, 2024
Case No. 2022-1877-1
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of ARTEMAS RODERICK HOUSTON, Deceased
On to-wit the 20th day of May, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by DEBRA ZOE HOUSTON. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
MELVIN W. BRUNSON
900 WESTERN AMERICA CIR STE 201
MOBILE, AL 36609
Call News March 20, 27, and April 3, 2024
|
NOTICE OF COURT PROCEEDING
March 11, 2024
Case No. 2023-0939-1
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of CHARLY GENE BUSCH, Deceased
On to-wit the 20th day of May, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by COURTNEY C. BUSCH SR. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
MICHAEL R HOLBERG
P.O. BOX 47
MOBILE, AL 36601
Call News March 13, 20, 27, 2024
|
NOTICE OF COURT PROCEEDING
March 08, 2024
Case No. 2021-2048-2
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of MIGUEL ANGEL COSSIO TORRES, Deceased
On to-wit the 3rd day of June, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by ANTHONY M. HOFFMAN. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
MICHAEL R HOLBERG
P. O. BOX 47
MOBILE, AL 36601
Call News March 13, 20, 27, 2024
|
NOTICE OF COURT PROCEEDING
March 08, 2024
Case No. 2021-2049-2
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of CESAR FRANCISCO LOERA PULIDO, Deceased
On to-wit the 3rd day of June, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by ANTHONY M. HOFFMAN. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
MICHAEL R HOLBERG
P.O. BOX 47
MOBILE, AL 36601
Call News March 13, 20, 27, 2024
|
NOTICE OF COURT PROCEEDING
March 08, 2024
Case No. 2021-2046-2
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of ADOLFO ANANDA PALMAS ESPINOSA, Deceased
On to-wit the 3rd day of June, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by ANTHONY M. HOFFMAN. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
MICHAEL R HOLBERG
P. O. BOX 47
MOBILE, AL 36601
Call News March 13, 20, 27, 2024
|
NOTICE OF COURT PROCEEDING
March 08, 2024
Case No. 2021-2044-2
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of EDUARDO CONTRERAS SEGOVIA, Deceased
On to-wit the 3rd day of June, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by ANTHONY M. HOFFMAN. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
Anthony Hoffman
PO BOX 11
MOBILE, AL 36601
Call News March 13, 20, 27, 2024
|
NOTICE OF COURT PROCEEDING
March 08, 2024
Case No. 2023-0309-2
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of ROBERT BRYANT, Deceased
On to-wit the 22nd day of April, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the DETERMINE HEIRS as filed by ANTHONY M. HOFFMAN. NOTICE is hereby given to all parties in interest, specifically ROBERT E BRYANT JR, who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
ANTHONY M. HOFFMAN
P. O. BOX 11
Mobile, AL 36601
Call News March 13, 20, 27, 2024
|
NOTICE OF COURT PROCEEDING
March 04, 2024
Case No. 2023-0918-2
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JERRY LEE AGEE SR, Deceased
On to-wit the 1st day of April, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Sale of Real Property as filed by JADA LEANNE AGEE. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
IVAN LYNN PARKER
5605 REGENCY OAKS DR S.
MOBILE, AL 36609
Call News March 13, 20, 27, 2024
|
NOTICE OF COURT PROCEEDING
March 01, 2024
Case No. 2023-1989
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JIMMY WAYNE WRIGHT, Deceased
On to-wit the 1st day of April, 2024 at 9:30 AM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the PROBATE OF WILL as filed by JAMIE LOU WRIGHT. NOTICE is hereby given to all parties in interest, specifically KIMBERLY C. CONWAY, who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
R. JEFFREY PERLOFF, PC
Call News March 13, 20, 27, 2024
|
NOTICE OF COURT PROCEEDING
March 04, 2024
Case No. 2021-0783-4
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JOHN LEE WATSON A/K/A JOHN LEE WATSON JR, Deceased
On to-wit the 3rd day of June, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by ANTHONY M. HOFFMAN. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
ANTHONY M. HOFFMAN
P. O. BOX 11
Mobile, AL 36601
Call News March 13, 20, 27, 2024
|
NOTICE OF COURT PROCEEDING
March 01, 2024
Case No. 2022-1832-3
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of JERRY WAYNE DAILEY, Deceased
On to-wit the 3rd day of June, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by ANTHONY M. HOFFMAN. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, DAVIS, Judge of Probate
Attorney:
ANTHONY M. HOFFMAN
P. O. BOX 11
Mobile, AL 36601
Call News March 6, 13, 20, 2024
|
NOTICE OF COURT PROCEEDING
March 01, 2024
Case No. 2020-0117-6
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of MICHAEL WAYNE MILLER, Deceased
On to-wit the 20th day of May, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT AND REPORT OF INSOLVENCY as filed by BOBBIE GAYLE FERGUSON. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
PAGE STANLEY ELLIS
169 DAUPHIN STREET, SUITE 304
MOBILE, AL 36602
Call News March 6, 13, 20, 2024
|
NOTICE OF COURT PROCEEDING
February 29, 2024
Case No. 2022-1491-1
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of NATHANIEL WILLIAMS, Deceased
On to-wit the 20th day of May, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT as filed by MARIO PORTER. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
MICHAEL S. MCNAIR
2151 GOVERNMENT STREET
MOBILE, AL 36606
Call News March 6, 13, 20, 2024
|
NOTICE OF COURT PROCEEDING
February 27, 2024
Case No. 2019-1715-4
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of WILLIE JAMES CADE SR, Deceased
On to-wit the 29th day of April, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT BY SURETY as filed by WESTERN SURETY COMPANY. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
JAMES J. DUFFY III
P.O. BOX 1109
MOBILE, AL 36633
Call News March 6, 13, 20, 2024
|
NOTICE OF COURT PROCEEDING
February 28, 2024
Case No. 2021-2155-2
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of FESTUS CHARLOTTE HICKS, Deceased
On to-wit the 20th day of May, 2024 at 2:00 PM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT AND REPORT OF INSOLVENCY as filed by JOHN G. BAYLOR JR. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
MARK E HARRIS
PO BOX 1988
MOBILE, AL 36633
JESSICA L WELCH
P.O. BOX 1988
MOBILE, AL 36633
Call News March 6, 13, 20, 2024
|
NOTICE OF COURT PROCEEDING
February 27, 2024
Case No. 2020-1122-4
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of NEVA GRAY RAPER, Deceased
On to-wit the 8th day of April, 2024 at 11:00 AM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the FINAL SETTLEMENT BY SURETY OF FORMER ADMINISTRATRIX as filed by WESTERN SURETY COMPANY. NOTICE is hereby given to all parties in interest who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney
JAMES J. DUFFY III
P.O. BOX 1109
MOBILE, AL 36633
Call News March 6, 13, 20, 2024
|
NOTICE OF COURT PROCEEDING
February 14, 2024
Case No. 2021-1943-3
IN THE PROBATE COURT OF
MOBILE COUNTY, ALABAMA
Estate of KENNETH DOYLE BRUHL, Deceased
On to-wit the 25th day of March, 2024 at 11:00 AM in COURTROOM 1, THIRD FLOOR, Mobile County Government Center Annex, 151 Government Street the court will proceed to consider the Petition for Annual Settlement and Motion for DNA Testing as filed by DEBORAH SULLIVAN. NOTICE is hereby given to all parties in interest, specifically ROBERT EMILE BRUHL JR, JAMES W BRUHL JR, who may appear and contest same or file a proper responsive pleading thereto if they then think proper.
DON DAVIS, Judge of Probate
Attorney:
BARRY A. FRIEDMAN
P.O. BOX 2394
MOBILE, AL 36652
Call News February 28, and March 6, 13, 20, 2024
|
Completion Notice
NOTICE OF COMPLETION OF
CONTRACT
Playworld Preferred, Inc. has completed the work, turnkey playground project at Holloway Elementary, BCS #23-17, in Mobile County, AL. ANY PERSONS HAVING A CLAIM AGAINST THE PROJECT SHOULD NOTIFY Playworld Preferred, Inc. 11515 Vanstory Drive, Suite 100, Huntersville NC 28262. All claims should be filed within 30 days of the final publication of this notice.
Call News March 20, 27, and April 3, 10, 2024
|
NOTICE OF COMPLETION
In accordance with Chapter 1, Title 39, Code of Alabama, 1975, notice is hereby given that Ben M. Radcliff Contractor, Inc., Contractor, has completed the Contract for the Alabama Department of Veterans Affairs, Owner(s), Ten Year Cemetery Expansion Project: Alabama State Veterans Memorial Cemetery at Spanish Fort AL FAI Project # AL-20-04, and have made request for final settlement of said Contract. All persons having any claim for labor, materials, or otherwise in connection with this project should immediately notify Walcott Adams Verneuille Architects, One S. School Street, Fairhope, AL 36532.
Ben M. Radcliff Contractor, Inc.
P. O. Box 8368
Mobile, AL 36689-0368
Call News March 13, 20, 27 and April 3, 2024
|
Advertisement for Completion
For Barton Academy Turf Project
Barton Academy for World Studies, Mobile, AL
Contractor: Stewart Environmental Construction, Inc.
All persons having any claim for labor, materials or otherwise in connection with this project should immediately notify Allred Stolarski Architects.
605 Bel Air Blvd. Suite 11
Mobile, AL 36606
Call News March 13, 20, 27, 2024
|
LEGAL NOTICE OF COMPLETION
Pursuant to Ala. Code 39-1-1 (1975), notice is hereby given that Nordan Contracting Company, Inc. has completed its contract for the GOMESA Bellingrath Force Main Ext Phase C – Lift Stations, Project No. 448923C, for Mobile County Water, Sewer, and Fire Protection Authority and has requested final settlement of said contract. All persons having claims on said project for materials or labor should immediately contact Mobile County Water, Sewer, and Fire Protection Authority, 5780 Theodore Dawes Road, Theodore, AL 36582 in the time and manner as required by law.
Call News March 6, 13, 20, 27, 2024
|
LEGAL NOTICE
Ozark Striping Company, LLC herby gives notice of completion of contract with the State of Alabama for construction of Project No. IM-I165(304) in Mobile County. This notice
will appear for four consecutive weeks beginning on March 6 and ending on March 27, 2024. All claims should be filed at P.O. Box 847, Ozark, AL 36361 during this period.
Ozark Striping Company, LLC
Call News March 6, 13, 20, 27, 2024
|
NOTICE OF COMPLETION
In accordance with Chapter 1, Title 39, Code of Alabama 1975, notice is hereby given that Max Foote Construction Co. LLC, Contractor, has completed the Contract for Myers WTP Solids Handling Improvements for MAWSS, Owner(s), and has made request for final settlement of said contract. All persons having any claim for labor, materials or otherwise in connection with this project should immediately notify Max Foote Construction Co. LLC at 225 Antibes St. West, Mandeville, LA 70448.
Call News February 28, and March 6, 13, 20, 2024
|
PUBLIC NOTICE
PUBLIC NOTICE
Notice is hereby given that at its meeting at 6:00 p.m. on March 28, 2024, the Saraland City Council will consider a resolution to enter into an Agreement with the Board of Water and Sewer Commissioners of the City of Saraland, Alabama. This Agreement will assist the Board in providing sewer service on the south side of State Road 158 west of Shelton Beach Road. Said Agreement will benefit the public by upgrading and improving sewer infrastructure on a public right of way. Said Agreement will also have the initial impact of benefiting property being developed by Saraland 158 Partners, LLC for the development of Chick-fil-A restaurant, a full service restaurant and a hotel. Pursuant to the term of the Agreement between the City and the Board, the City proposes to assist the Board in the costs of constructing water and sewer infrastructure in an amount not to exceed $125,000. Copies of the sewer development agreement are available for inspection at Saraland City Hall located at 943 Saraland Boulevard South, Saraland, Alabama. The meeting will take place in the city council chambers, 937 Saraland Boulevard South, Saraland, Alabama.
Judi Smith, Saraland City Clerk
Call News March 20, 2024
|
PUBLIC Notice
On behalf of the U.S. Army Environmental Command (USAEC), Cherokee Nation Environmental Solutions (CNES), along with Conti Federal Services (CFS), has been contracted to provide an updated Community Involvement Plan (CIP). The Army requests public engagement in the development of the Alabama Army National Guard (ALARNG) Mobile Organization Maintenance Shops (OMS) 28 & 29 CIP as required by the environmental restoration program.
Communication has evolved. We would like to know how to get information to members of the community, so that the public has an active voice in the environmental actions associated with the installation. We would like to interview people like you to identify your concerns, preferred communication methods, and desired involvement levels in the Army Cleanup Process at ALARNG Mobile OMS 28 & 29. Your answers to the interview questions will be incorporated anonymously into the CIP.
Your opinion matters. Please reach out to this contact to express interest and gain more information: Carla Avery at (848)-327-4448 or cavery@contifederal.com. We can complete interviews via phone, email, or through online communication such as MS Teams through April 19, 2024.
ALARNG Mobile OMS 28 & 29 is located in the logistics/manufacturing district of the Brookley Field Aeroplex and occupies approximately 7.3 acres in Mobile County, Alabama. The installation’s federal mission is to provide properly trained and equipped units for the prompt mobilization for war, national emergencies, or as otherwise needed. The installation’s state mission is to provide trained and disciplined forces for domestic emergencies or as otherwise provided by state law. Environmental concerns are identified as contaminants of concern which impact the groundwater at the installation.
Call News March 20, 2024
|
STORAGE SALE
In accordance with the provisions of State law, there being due and unpaid charges for which the undersigned is entitled to satisfy an owner and/or manager’s lien of the goods stored at The Storage Center location(s) listed below.
The Storage Center #8059
3641 Government Blvd.
Mobile, AL 36693
251-219-0608
Unit 1094 Reginald Rayford P.O. Box 850092 Mobile, Al 36685, Unit 1220 Tonia Broaders, Unit 3110 Nuala McCool 608 Azalea Rd Apt 707 Mobile, Al 36609, Unit 3111 Mallan Edwards 2825 Rebecca Dr E 36618
And, due notice having been given, to the owner of said property and all parties known to claim an interest therein, and the time specified in such notice for payment of such having expired, the goods will be sold to the highest bidder or otherwise disposed of at public auction to be held at www.storagetreasure.com, which will end Thursday, March 21, 2024 @ 10 A.M. Any questions regarding the above information are to be addressed to the manager of this facility at the phone number shown above.
Call News March 13, 20, 2024
|
In accordance with the provisions of State law, there being due and unpaid charges for which the undersigned is entitled to satisfy an owner and/or manager’s lien of the goods stored at The Storage Center location(s) listed below.
The Storage Center #8071
5951 Grelot Rd.
Mobile, AL 36609
251.706.7202
Unit 3083, Arcus Bryan 8600 Valhalla Dr. Eight Mile, AL 36613
And, due notice having been given, to the owner of said property and all parties known to claim an interest therein, and the time specified in such notice for payment of such having expired, the goods will be sold to the highest bidder or otherwise disposed of at public auction to be held at www.storagetreasure.com, which will end Thursday, February 22, 2024 @ 10 A.M. Any questions regarding the above information are to be addressed to the manager of this facility at the phone number shown above.
Call News March 13, 20, 2024
|
In accordance with the provisions of State law, there being due and unpaid charges for which the undersigned is entitled to satisfy an owner and/or manager’s lien of the goods stored at The Storage Center location(s) listed below.
The Storage Center #8071
5951 Grelot Rd.
Mobile, AL 36609
251.706.7202
Unit 3012, Arcus Bryan 8600 Valhalla Dr. Eight Mile, AL 36613
And, due notice having been given, to the owner of said property and all parties known to claim an interest therein, and the time specified in such notice for payment of such having expired, the goods will be sold to the highest bidder or otherwise disposed of at public auction to be held at www.storagetreasure.com, which will end Thursday, March 21, 2024 @ 10 A.M. Any questions regarding the above information are to be addressed to the manager of this facility at the phone number shown above.
Call News March 13, 20, 2024
|
Personal property of the following tenants will be sold at public sale to the highest bidder to satisfy the landlord’s lien. All units are assumed to contain general household goods unless otherwise indicated. Viewing of photos will be available on storagetreasures.com, up to 14 days prior to each scheduled sale. The owners and their agents reserve the right to bid on any unit and also to refuse any bid. All items or units may not be available on the day of sale. The auction will take place online at storagetreasures.com on: Friday, March 22, 2024 at 10 a.m. Unit 12 Deltonio Seals 3816 Torrington Dr. E Semmes, AL 36575 Unit 7 Gunther Reynolds 9751 Jeremy dr. Semmes, AL 36575 Unit 37 Rebecca Anderson 8550 Valhalla Dr. Eight mile AL, 36613 Unit 47 Crystal Payne 5920 Windy Hill Circle S Mobile, AL, Unit 65 Trent Shepard 7051 Joe Ching Rd W Semmes AL 36575.
Call News March 20, 27, 2024
|
Extra Space Storage will hold a public auction to sell personal property described below belonging to those individuals listed below at the location indicated:
7997: 5441 US-90, Mobile, AL 36619
Auction Date: 04/05/2024 at 1:15 PM
Units: 1054
Auction will be listed and advertised on www.storagetreasures.com. Purchases must be made with cash only and paid at the above referenced facility in order to complete the transaction. Extra Space Storage may refuse any bid and may rescind any purchase up until the winning bidder takes possession of the personal property.
Call News March 20, 2024
|
Extra Space Storage will hold a public auction to sell personal property described below belonging to those individuals listed below at the location indicated:
7403: 429 Bel Air Blvd, Mobile, AL 36606
Auction Date: 04/05/2024 at 12:00 PM
Units: 15, 113
Auction will be listed and advertised on www.storagetreasures.com. Purchases must be made with cash only and paid at the above referenced facility in order to complete the transaction. Extra Space Storage may refuse any bid and may rescind any purchase up until the winning bidder takes possession of the personal property.
Call News March 20, 2024
|
Extra Space Storage will hold a public auction to sell personal property described below belonging to those individuals listed below at the location indicated:
7926: 3679 Airport Blvd, Mobile, AL 36608
Auction Date: 04/05/2024 at 12:30 PM
Units: 1163, 2129, 2202, 3008
Auction will be listed and advertised on www.storagetreasures.com. Purchases must be made with cash only and paid at the above referenced facility in order to complete the transaction. Extra Space Storage may refuse any bid and may rescind any purchase up until the winning bidder takes possession of the personal property.
Call news March 20, 2024
|
Life Storage will hold a public auction to sell personal property described below belonging to those individuals listed below at the location indicated:
3259: 8781 Airport Blvd, Mobile, AL 36608
Auction Date: 04/05/2024 at 11:30 AM
Units: C156, E249, E274, E278, K830
Auction will be listed and advertised on www.storagetreasures.com. Purchases must be made with cash only and paid at the above referenced facility in order to complete the transaction. Extra Space Storage may refuse any bid and may rescind any purchase up until the winning bidder takes possession of the personal property.
Call News March 20, 2024
|
BILL
NOTICE is hereby given that a bill substantially as follows will be introduced in the 2024 Regular Session of the Legislature of Alabama and application for its passage and enactment will be made:
STATE OF ALABAMA
COUNTY OF MOBILE
LEGAL NOTICE
Notice is hereby given in accordance with Section 106 of the Constitution of Alabama of 2022, that a bill, the substance of which is as follows, will be introduced in the 2024 Regular Session of the Legislature of Alabama and application for its passage and enactment will be made:
A bill to alter and rearrange the boundary lines and corporate limits of the City of Prichard in Mobile County to remove all property owned by the University of Mobile in the City of Prichard from the corporate limits of the city. A copy of the entire bill contains a legal description of the property to be removed from the City of Prichard by this bill and a map showing the location of the property is on file in the Office of the Judge of Probate of Mobile County.
Call News February 28, and March 6, 13, 20, 2024
|
SHERIFF’S SALE
SHERIFF’S SALE
CASE NO. SM 2022 905419
STATE OF ALABAMA
COUNTY OF MOBILE
All In Credit Union
VS
Catherine Randolph
Under and by virtue of a Writ of Fieri Facias issued out of the Small Claims Court of Mobile County in the above styled case, I will proceed to sell to the highest and best bidder, for cash, on April 15, 2024 at the hour of 12:00 NOON, at the courthouse, Government Street Entrance to the North Tower of Government Plaza, all the right, title and interest of Catherine Randolph, in and to the following described Real property, to-wit:
THE E 1/2 OF LOT 2 ALL OF LOT 3 & W 1/2 OF LOT 4 BLK 125, NORTH MOBILE, AS PER PLAT THEREOF RECORDED IN DBK 145 PP 252-264 #SEC 44 T3S R1W #MP22 08 44 0 005 Sold subject to existing liens, if any.
PAUL BURCH JR SHERIFF,
MOBILE COUNTY
Call News March 20, 27, and April 3, 2024
|
SHERIFF’S SALE
CASE NO. CV 2023 901956
STATE OF ALABAMA
COUNTY OF MOBILE
Lee & Hughes, LLC
VS
Bayou Bend Bridge AL, LLC.
Under and by virtue of a Writ of Fieri Facias issued out of the Circuit Court of Mobile County in the above styled case, I will proceed to sell to the highest and best bidder, for cash, on April 8, 2024 at the hour of
12:20 p.m., at the courthouse, Government Street entrance to the North Tower of Government Plaza, all the right, title and interest of Bayou Bend Bridge AL, LLC, in and to the following described Real property, to-wit:
LOT 32, IN BLOCK B, OF THE REVISED SURVEY AND PLAT OF RIVERSIDE SUBDIVISION, ACCORDING TO THE PLAT THEREOF RECORDED IN MAP BOOK 3, PAGES 299-302, OF THE RECORDS IN THE OFFICE OF THE JUDGE OF PROBATE COURT, MOBILE COUNTY, ALABAMA. LESS AND EXCEPT THE NORTH 240 FEET OF THE EAST 220 FEET; SAID PROPERTY MORE PARTICULARLY DESCRIBED AS THAT CERTAIN LOT OF LAND ON THE SOUTH SIDE OF BRILL ROAD BOUNDED BY A LINE AS FOLLOWS, TO WIT: BEGIN AT THE NORTHWEST CORNER OF SAID LOT 32 AT A POINT ON THE SOUTH RIGHT OF WAY LINE OF BRILL ROAD; THENCE RUN ON A BEARING OF NORTH 89°52’45” EAST ALONG THE SOUTH RIGHT OF WAY LINE OF BRILL ROAD A DISTANCE OF 160.0 FEET TO A POINT; THENCE RUN ON A BEARING OF SOUTH 00°00’39” WEST A DISTANCE OF 240.0 FEET TO A POINT; THENCE RUN ON A BEARING OF NORTH 89°52’45” EAST A DISTANCE OF 220.0 FEET TO A POINT ON THE EAST LINE OF SAID LOT 32; RUN ON A BEARING OF SOUTH 00°00’39” WEST ALONG THE EAST LINE OF SAID LOT 32 AND ALONG A FENCE LINE A DISTANCE OF 315.5 FEET TO THE SOUTHEAST CORNER OF SAID LOT 32; THENCE RUN ON A BEARING OF SOUTH 89°44’03” WEST ALONG THE SOUTH LINE OF SAID LOT 32 A DISTANCE OF 379.33 FEET TO A POINT WHICH IS THE SOUTHWEST CORNER OF SAID LOT 32; THENCE RUN ON A BEARING OF NORTH 00°03’15” WEST ALONG THE WEST LINE OF SAID LOT 32 A DISTANCE OF 556.45 FEET TO A POINT AND THE POINT OF BEGINNING. Sold subject to existing liens, if any.
PAUL BURCH JR SHERIFF,
MOBILE COUNTY
Call News March 13, 20, 27, 2024
|
SHERIFF’S SALE
CASE NO. CV 2023 901958
STATE OF ALABAMA
COUNTY OF MOBILE
Lee & Hughes, LLC.
VS
Summit Village Green, Ltd.
Under and by virtue of a Writ of Fieri Facias issued out of the Circuit Court of Mobile County in the above styled case, I will proceed to sell to the highest and best bidder, for cash, on April 8, 2024 at the hour of
12:10 p.m., at the courthouse, Government Street entrance to the North Tower of Government Plaza, all the right, title and interest of Summit Village Green, Ltd., in and to the following described Real property, to-wit:
COMMENCING AT THE NORTHEAST CORNER OF SECTION 35, T4S-R2W, MOBILE COUNTY, ALABAMA, RUN S 01° 17’ 00” W 40 FEET TO THE NORTHEAST CORNER OF EL MONTE SUBDIVISION, AS PER PLAT RECORDED IN MAP BOOK 11, PAGE 61 OF THE PROBATE COURT RECORDS OF MOBILE COUNTY, ALABAMA; THENCE CONTINUING S 01° 17’ 00” W ALONG THE EAST BOUNDARY OF SAID EL MONTE SUBDIVISION, RUN 429.00 FEET TO THE SOUTHEAST CORNER OF SAID EL MONTE SUBDIVISION; SAID POINT BEING THE NORTHEAST CORNER OF VILLAGE GREEN EAST, AS PER PLAT RECORDED IN MAP BOOK 26, PAGE 62 OF SAID PROBATE COURT RECORDS OF MOBILE COUNTY, ALABAMA; THENCE ALONG THE SOUTH BOUNDARY OF SAID EL MONTE SUBDIVISION AND THE NORTH BOUNDARY OF SAID VILLAGE GREEN EAST AND A WESTWARD EXTENSION THEREOF, RUN N 89° 43’ 00” W 817.90 FEET TO A POINT ON THE WEST RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE; SAID POINT BEING THE POINT OF BEGINNING OF THE PROPERTY HEREIN DESCRIBED; THENCE ALONG SAID WEST RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE, RUN S 00° 16’ 40” W 617.47 FEET TO THE P.C. OF A CURVE TO THE RIGHT HAVING A CENTRAL ANGLE OF 68° 44’ 27” AND A RADIUS OF 121.20 FEET; THENCE CONTINUING ALONG SAID WEST RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE AND ALONG THE ARC OF SAID CURVE, RUN SOUTHWESTWARDLY 145.42 FEET TO THE P.T. OF SAID CURVE; THENCE ALONG THE NORTH RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE, RUN S 69° 01’ 07” W 224.66 FEET TO THE P.C. OF A CURVE TO THE RIGHT HAVING A CENTRAL ANGLE OF 20° 49’ 23” AND A RADIUS OF 178.98 FEET; THENCE CONTINUING ALONG SAID NORTH RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE AND ALONG THE ARC OF SAID CURVE, RUN SOUTHWESTWARDLY 65.05 FEET TO THE P.T. OF SAID CURVE; THENCE CONTINUING ALONG SAID NORTH RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE, RUN S 89° 50’ 30”W 113.25 FEET TO THE P.C. OF A CURVE TO THE RIGHT HAVING A CENTRAL ANGLE OF 23° 07’ 08” AND A RADIUS OF 210.32 FEET; THENCE CONTINUING ALONG SAID NORTH RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE AND ALONG THE ARC OF SAID CURVE, RUN NORTHWESTWARDLY 84.86 FEET TO THE P.T. OF SAID CURVE; THENCE ALONG THE NORTH RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE WEST, RUN N 67° 02’ 22” W 16.09 FEET TO THE P.C. OF A CURVE TO THE LEFT HAVING A CENTRAL ANGLE OF 23°07’ 08” AND A RADIUS OF 465.03 FEET; THENCE ALONG SAID NORTH RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE WEST AND ALONG THE ARC OF SAID CURVE, RUN NORTHWESTWARDLY 187.64 FEET TO THE P.T. OF SAID CURVE; THENCE CONTINUING ALONG SAID NORTH RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE WEST, RUN S 89° 50’ 30” W 54.93 FEET TO A POINT ON THE EAST BOUNDARY OF GLEN VALLEYAPARTMENTS, AS PER PLAT RECORDED IN MAP BOOK 26, PAGE 63 OF THE AFOREMENTIONED PROBATE COURT RECORDS OF MOBILE COUNTY, ALABAMA; THENCE ALONG SAID EAST BOUNDARY OF GLEN VALLEY APARTMENTS, RUN N 00° 01’ 39” E 601.50 FEET TO THE NORTHEAST CORNER OF SAID GLEN VALLEY APARTMENTS;SAID POINT BEING ON THE SOUTH BOUNDARY OF THE AFOREMENTIONED EL MONTE SUBDIVISION; THENCE ALONG SAID SOUTH BOUNDARY OF EL MONTE SUBDIVISION, RUN AS FOLLOWS: S 89° 43’ 00” E 361.30 FEET, N 01° 08’ 58” E 165.50 FEET, S 89° 43’ 00” E 437.50 FEET TO THE POINT OF BEGINNING. BEING LOT 1, VILLAGE GREEN, UNIT ONE, AS PER PLAT RECORDED IN MAP BOOK 23, PAGE 93 OF THE PROBATE COURT RECORDS OF MOBILE COUNTY, ALABAMA. CONTAINING 566,313 SQUARE FEET OR 13.0008 ACRES.
ALSO: COMMENCING AT THE NORTHEAST CORNER OF SECTION 35, T4S-R2W, MOBILE COUNTY, ALABAMA. RUN S 01° 17’ 00” W 40 FEET TO THE NORTHEAST CORNER OF EL MONTE SUBDIVISION, AS PER PLAT RECORDED IN MAP BOOK 11, PAGE 61 OF THE PROBATE COURT RECORDS OF MOBILE COUNTY, ALABAMA; THENCE CONTINUING S 01° 17’ 00” W ALONG THE EAST BOUNDARY OF SAID EL MONTE SUBDIVISION, RUN 429.00 FEET TO THE SOUTH EAST CORNER OF SAID EL MONTE SUBDIVISION; SAID POINT BEING THE NORTHEAST CORNER OF VILLAGE GREEN EAST, AS PER PLAT RECORDED IN MAP BOOK 26, PAGE 62 OF SAID PROBATE COURT RECORDS OF MOBILE COUNTY, ALABAMA; THENCE ALONG THE SOUTH BOUNDARY OF SAID EL MONTE SUBDIVION AND THE NORTH BOUNDARY OF SAID VILLAGE GREEN EAST, RUN N 89°43’ 00” W 767.90 FEET TO THE NORTHWEST CORNER OF SAID VILLAGE GREEN EAST; SAID POINT BEING ON THE EAST RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE;THENCE ALONG SAID EAST RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE AND THE WEST BOUNDARY OF SAID VILLAGE GREEN EAST AND ALONG THE WEST BOUNDARY OF VILLAGE GREEN SOUTHEAST, AS PER PLAT RECORDED IN MAP BOOK 27, PAGE 67 OF SAID PROBATE COURT RECORDS OF MOBILE COUNTY, ALABAMA, RUN S 00° 16’ 40” W 617.47 FEET TO THE POINT OF BEGINNING OF THE PROPERTY HEREIN DESCRIBED; THENCE CONTINUING S 00° 16’ 40” W ALONG SAID WEST BOUNDARY OF VILLAGE GREEN SOUTHEAST, RUN A DISTANCE OF 270.00 FEET TO THE SOUTHWEST CORNER OF SAID VILLAGE GREEN SOUTHEAST; SAID POINT BEING ON THE NORTH BOUNDARY OF LOT 3, AZALEA ROAD EXECUTIVE PARK, UNIT ONE, AS PER PLAT RECORDED IN MAP BOOK 30, PAGE 122 OF SAID PROBATE COURT RECORDS OF MOBILE COUNTY, ALABAMA; THENCE ALONG SAID NORTH BOUNDARY OF LOT 3, AZALEA ROAD EXECUTIVE PARK, UNIT ONE AND ALONG THE NORTH BOUNDARY OF LOT 3, VILLAGE GREEN, UNIT ONE, AS PER PLAT RECORDED IN MAP BOOK 23, PAGE 93 OF SAID PROBATE COURT RECORDS OF MOBILE COUNTY, ALABAMA, RUN S 89° 50’ 30” W 372.41 FEET TO A POINT ON THE SOUTH RIGHT OF WAY LINE OF SAID VILLAGE GREEN DRIVE; SAID POINT BEING ON THE ARC OF A 193.62 FOOT RADIUS CURVE CONCAVE SOUTHEASTWARDLY; THENCE ALONG SAID SOUTH RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE AND SAID ARC OF CURVE, RUN NORTHEASTWARDLY 62.85 FEET TO THE P.T. OF SAID CURVE; SAID POINT BEARS N 59° 43’ 09” E 62.57 FROM THE LAST DESCRIBED POINT; THENCE CONTINUING ALONG SAID SOUTH RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE, RUN N 69° 01’ 07” E 224.66 FEET TO THE P.C. OF A CURVE TO THE LEFT HAVING A CENTRAL ANGLE OF 68° 44’ 27” AND A RADIUS OF 171.20 FEET; THENCE ALONG THE AFOREMENTIONED EAST RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE AND THE ARC OF SAID CURVE, RUN NORTHEASTWARDLY 205.41 FEET TO THE P.T. OF SAID CURVE; SAID POINT BEING THE POINT OF BEGINNING. BEING LOT 1-A, VILLAGE GREEN, UNIT ONE, A PER PLAT RECORDED IN MAP BOOK 23, PAGE 93 OF THE PROBATE COURT RECORDS OF MOBILE COUNTY, ALABAMA. CONTAINING 32,770 SQUARE FEET OR 0.7523 ACRE.
ALSO: COMMENCING AT THE NORTHEAST CORNER OF SECTION 35, T4S-R2W, MOBILE COUNTY, ALABAMA, RUN S 01° 17’ 00” W 40 FEET TO THE NORTHEAST CORNER OF EL MONTE SUBDIVISION, AS PER PLAT RECORDED IN MAP BOOK 11, PAGE 61 OF THE PROBATE COURT RECORDS OF MOBILE COUNTY, ALABAMA; THENCE CONTINUING S 01° 17’ 00” W ALONG THE EAST BOUNDARY OF SAID EL MONTE SUBDIVISION, RUN 429.00 FEET TO THE SOUTHEAST CORNER OF SAID EL MONTE SUBDIVISION; SAID POINT BEING THE NORTHEAST CORNER OF VILLAGE GREEN EAST, AS PER PLAT RECORDED IN MAP BOOK 26, PAGE 62 OF SAID PROBATE COURT RECORDS OF MOBILE COUNTY, ALABAMA; THENCE ALONG THE SOUTH BOUNDARY OF SAID EL MONTE SUBDIVISION AND THE NORTH BOUNDARY OF SAID VILLAGE GREEN EAST, RUN N 89° 43’ 00” W 767.90 FEET TO THE NORTHWEST CORNER OF SAID VILLAGE GREEN EAST; SAID POINT BEING ON THE EAST RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE; THENCE ALONG SAID EAST RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE AND THE WEST BOUNDARY OF SAID VILLAGE GREEN EAST AND ALONG THE WEST BOUNDARY OF VILLAGE GREEN SOUTHEAST, AS PER PLAT RECORDED IN MAP BOOK 27, PAGE 67 OF SAID PROBATE COURT RECORDS OF MOBILE COUNTY, ALABAMA, RUN S 00° 16’ 40”W 887.47 FEET TO THE SOUTHWEST CORNER OF SAID VILLAGE GREEN SOUTHEAST;SAID POINT BEING ON THE NORTH BOUNDARY OF LOT 3, AZALEA ROAD EXECUTIVE PARK, UNIT ONE, AS PER PLAT RECORDED IN MAP BOOK 30, PAGE 122 OF SAID PROBATE COURT RECORDS OF MOBILE COUNTY, ALABAMA; THENCE ALONG SAID NORTH BOUNDARY OF LOT 3, AZALEA ROAD EXECUTIVE PARK, UNIT ONE AND ALONG THE NORTH BOUNDARY OF LOT 3, VILLAGE GREEN , UNIT ONE, AS PER PLAT RECORDED IN MAP BOOK 23, PAGE 93 OF SAID PROBATE COURT RECORDS OF MOBILE COUNTY, ALABAMA, AND A WESTWARD EXTENSION THEREOF, RUN S 89° 50’ 30” W 557.53 FEET TO THE NORTHEAST CORNER OF LOT B, VILLAGE GREEN, UNIT ONE, RESUBDIVISION OF LOT 2, AS PER PLAT RECORDED IN MAP BOOK 25, PAGE 4 OF SAID PROBATE COURT RECORDS OF MOBILE COUNTY, ALABAMA; SAID POINT BEING THE POINT OF BEGINNING OF THE PROPERTY HEREIN DESCRIBED; THENCE ALONG THE NORTH BOUNDARY OF SAID LOT B, VILLAGE GREEN, UNIT ONE, RESUBDIVISION OF LOT 2, RUN S 89° 50’ 30” W 290.65 FEET TO THE SOUTHEAST CORNER OF GLEN VALLEYAPARTMENTS , AS PER PLAT RECORDED IN MAP BOOK 26, PAGE 63 OF SAID PROBATE COURT RECORDS OF MOBILE COUNTY, ALABAMA; THENCE ALONG THE EAST BOUNDARY OF SAID GLEN VALLEY APARTMENTS, RUN N 00° 01’ 39” E 77.00 FEET TO A POINT ON THE SOUTH RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE WEST; THENCE ALONG SAID SOUTH RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE WEST, RUN N 89° 50’ 30” E 55.07 FEET TO THE P.C. OF A CURVE TO THE RIGHT HAVING A CENTRAL ANGLE OF 23° 07’ 08” AND A RADIUS OF 415.03 FEET; THENCE CONTINUING ALONG SAID SOUTH RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE WEST AND THE ARC OF SAID CURVE, RUN SOUTHEASTWARDLY 167.46 FEET TO THE P.T. OF SAID CURVE; THENCE CONTINUING ALONG SAID SOUTH RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE WEST, RUN S 67° 02’ 22” E 16.09 FEET TO THE P.C. OF A CURVE TO THE RIGHT HAVING A CENTRAL ANGLE OF 19° 40’ 11” AND A RADIUS OF 200.99 FEET; THENCE CONTINUING ALONG SAID SOUTH RIGHT OF WAY LINE OF VILLAGE GREEN DRIVE WEST AND THE ARC OF SAID CURVE, RUN SOUTHEASTWARDLY 69.00 FEET TO THE P.T. OF SAID CURVE; SAID POINT BEING THE POINT OF BEGINNING. BEING LOT 1-B, VILLAGE GREEN, UNIT ONE, AS PER PLAT RECORDED IN MAP BOOK 23, PAGE 93 OF THE PROBATE COURT RECORDS OF MOBILE COUNTY, ALABAMA. CONTAINING 16,828 SQUARE FEET OR 0.3863 ACRE. Sold subject to existing liens, if any.
PAUL BURCH JR
SHERIFF, MOBILE COUNTY
Call News March 13, 20, 27, 2024
|
SHERIFF’S SALE
CASE NO. CV 2023 900053
STATE OF ALABAMA
COUNTY OF MOBILE
Thames, Jackson, Harris Company Inc
VS
Dexter L; April T Beard
Under and by virtue of a Writ of Fieri Facias issued out of the Circuit Court of Mobile County in the above styled case, I will proceed to sell to the highest and best bidder, for cash, on April 8, 2024 at the hour of 12:00 NOON, at the courthouse, Government Street entrance to the North Tower of Government Plaza, all the right, title and interest of April T Beard, in and to the following described Real property, to-wit:
BEG AT SE COR OF GROVE AVE & MICHIGAN AVE EXT LEADING TO BROOKLEY FIELD RUN ELY ALG S/L OF GROVE AVE 15.0 FT TO PT TH SLY WITH INT ANG OF 78 DEG 31 MIN & PAR WITH MICHIGAN AVE EXT 50.0 FT TO PT TH WLY & PAR WITH GROVE AVE 15.0 FT TO PT ON E/L OF MICHIGAN AVE EXT TH NLY ALG SD E/L 50.0 FT TO POB BEING PT OF LOT 1 BLK 9 MELROSE PLACE DBK 134 NS P 562 #SEC 27 T4S R1W #MP29 10 27 3 003 (KEY NO. 915754). Sold subject to existing liens, if any.
PAUL BURCH JR SHERIFF,
MOBILE COUNTY
Call News March 13, 20, 27, 2024
|
SHERIFF’S SALE
CASE NO. CV 2015 902474
STATE OF ALABAMA
COUNTY OF MOBILE
Spring Hill Insurance Company, Inc.
VS
Ernest A. Shaw Et Al
Under and by virtue of a Writ of Fieri Facias issued out of the Circuit Court of Mobile County in the above styled case, I will proceed to sell to the highest and best bidder, for cash, on April 1, 2024 at the hour of 12:00 NOON, at the courthouse, Government Street entrance to the North Tower of Government Plaza, all the right, title and interest of Ernest A Shaw, in and to the following described Real property, to-wit:
Lot 4, Block 6, FOREST HIGHLANDS, according to the plat thereof recorded in Map Book 5, Pages 623-626 of the records in the office of the Judge of Probate, Mobile County, Alabama. Sold subject to existing liens, if any.
PAUL BURCH JR SHERIFF,
MOBILE COUNTY
Call News March 6, 13, 20, 2024
|
PUBLIC HEARING
NOTICE OF PUBLIC HEARING
BOARD OF ZONING ADJUSTMENT
MOBILE, ALABAMA
PURSUANT TO THE UNIFIED DEVELOPMENT CODE OF THE CITY OF MOBILE, adopted the 12th day of July 2022, as amended, the City of Mobile’s Board of Zoning Adjustment will hold a Public Hearing on April 1, 2024, at 2:00 p.m. to consider a request at 6109 Howells Ferry Road for a Use Variance to amend a previously approved Use Variance to allow a commercial daycare to operate in a R-1, Single-Family Residential Suburban District; the Unified Development Code (UDC) does not allow commercial daycares to operate in a R-1, Single-Family Residential Suburban District.
|
The meeting will be held in the Auditorium at 205 Government Street, Mobile, Alabama.

This notice is to advise you of the public hearing so that you may attend the meeting or otherwise present your views to the Board concerning this request. Board of Zoning Adjustment meetings are live streamed at https://www.cityofmobile.org/government/city-council/livestream/. Email your comments to planning@cityofmobile.org or upload your comments to the web portal at https://www.buildmobile.org/board-of-adjustment/.
|
All comments must be submitted by 2 p.m. on Friday, March 29, 2024, to provide adequate time for Board members to review the information.
|
Dated this 8th day of March 2024.
|
BOARD OF ZONING ADJUSTMENT
Call News on March 20, 2024, and March 27, 2024
|
NOTICE OF PUBLIC HEARING
BOARD OF ZONING ADJUSTMENT
MOBILE, ALABAMA
PURSUANT TO THE UNIFIED DEVELOPMENT CODE OF THE CITY OF MOBILE, adopted the 12th day of July 2022, as amended, the City of Mobile’s Board of Zoning Adjustment will hold a Public Hearing on April 1, 2024, at 2:00 p.m. to consider a request at 250 Dogwood Lane for a Setback Variance to allow an addition to a dwelling to be less than 25-feet from a side street side yard property line in a R-1, Single-Family Residential Suburban District; the Unified Development Code (UDC) does not allow an addition to a dwelling to be less than 25-feet from a side street side yard property line in a R-1, Single-Family Residential Suburban District.
|
The meeting will be held in the Auditorium at 205 Government Street, Mobile, Alabama.

This notice is to advise you of the public hearing so that you may attend the meeting or otherwise present your views to the Board concerning this request. Board of Zoning Adjustment meetings are live streamed at https://www.cityofmobile.org/government/city-council/livestream/. Email your comments to planning@cityofmobile.org or upload your comments to the web portal at https://www.buildmobile.org/board-of-adjustment/.
|
All comments must be submitted by 2 p.m. on Friday, March 29, 2024, to provide adequate time for Board members to review the information.
|
Dated this 8th day of March 2024.
|
BOARD OF ZONING ADJUSTMENT
Call News on March 20, 2024, and March 27, 2024
|
NOTICE OF PUBLIC HEARING
BOARD OF ZONING ADJUSTMENT
MOBILE, ALABAMA
PURSUANT TO THE UNIFIED DEVELOPMENT CODE OF THE CITY OF MOBILE, adopted the 12th day of July 2022, as amended, the City of Mobile’s Board of Zoning Adjustment will hold a Public Hearing on April 1, 2024, at 2:00 p.m. to consider a request at 556 Shady Oak Drive for a Setback Variance to allow an eight-foot (8’) tall privacy fence within a recorded 25-foot rear yard setback in an R-1, Single Family Residential Suburban District; the Unified Development Code (UDC) does not allow privacy fences exceeding three-feet (3’) tall within a recorded rear yard setback in an R-1, Single Family Residential Suburban District.
|
The meeting will be held in the Auditorium at 205 Government Street, Mobile, Alabama.

This notice is to advise you of the public hearing so that you may attend the meeting or otherwise present your views to the Board concerning this request. Board of Zoning Adjustment meetings are live streamed at https://www.cityofmobile.org/government/city-council/livestream/. Email your comments to planning@cityofmobile.org or upload your comments to the web portal at https://www.buildmobile.org/board-of-adjustment/.
|
All comments must be submitted by 2 p.m. on Friday, March 29, 2024, to provide adequate time for Board members to review the information.
|
Dated this 8th day of March 2024.
|
BOARD OF ZONING ADJUSTMENT
Call News on March 20, 2024, and March 27, 2024
|
NOTICE OF PUBLIC HEARING
BOARD OF ZONING ADJUSTMENT
MOBILE, ALABAMA
PURSUANT TO THE UNIFIED DEVELOPMENT CODE OF THE CITY OF MOBILE, adopted the 12th day of July 2022, as amended, the City of Mobile’s Board of Zoning Adjustment will hold a Public Hearing on April 1, 2024, at 2:00 p.m. to consider a request at 664 Schillinger Road South for a Sign Variance to allow a total of three (3) wall signs and two (2) freestanding signs for a single business site in a B-3, Community Business Suburban District; the Unified Development Code (UDC) limits single business sites site in a B-3, Community Business Suburban District to a total of three (3) signs, with no more than one (1) freestanding sign.
|
The meeting will be held in the Auditorium at 205 Government Street, Mobile, Alabama.
|
This notice is to advise you of the public hearing so that you may attend the meeting or otherwise present your views to the Board concerning this request. Board of Zoning Adjustment meetings are live streamed at https://www.cityofmobile.org/government/city-council/livestream/. Email your comments to planning@cityofmobile.org or upload your comments to the web portal at https://www.buildmobile.org/board-of-adjustment/.
|
All comments must be submitted by 2 p.m. on Friday, March 29, 2024, to provide adequate time for Board members to review the information.
|
Dated this 8th day of March 2024.
|
BOARD OF ZONING ADJUSTMENT
Call News on March 20, 2024, and March 27, 2024
|
Abandoned Vehicle Auction
In accordance with Section 32-13-1, Code of Alabama 1975, notice is hereby given to the owner. Lienholders, and other interested parties that the following described abandoned vehicle will be sold at public auction for cash to the highest bidder 9:00 a.m., June 11, 2024, at Mobile Police Impound, 1251 Virginia Street, Lot B, Mobile, AL 36604. Everyone entering has to register. For more information about vehicles and registration go to: https://www.mobilepd.org/auction/.
2000 FORD CROWN VICTORIA
2FAFP73W2YX155120
2004 NISSAN TITAN
1N6AA07AX4N550683
2005 JEEP LIBERTY
1J4GL58K95W711705
1996 FORD EXPLORER
1FMDU34X8TUA75004
2011 NISSAN ALTIMA
1N4AL2AP0BN503509
2005 NISSAN MURANO
JN8AZ08T75W304430
2019 DODGE CHARGER
2C3CDXGJ7KH678367
2005 TOYOTA TACOMA
5TEJU62N55Z017209
2003 LEXUS RX 300
JTJHF10U030304229
2006 FORD MUSTANG
1ZVFT80NX65102717
2011 MITSUBISHI GALANT
4A32B3FFXBE029945
2003 HONDA ACCORD
1HGCM56673A096347
2004 DODGE NEON
1B3ES56C94D509504
2007 NISSAN ALTIMA
1N4AL2AP7BN493853
1999 CHEVROLET SILVERADO
2GCEC19V1X1244174
BLACK TRAILER HOME MADE
NO VIN
2020 FORD F350 SUPER DUTY
1FD8W3HT7LED12661
2007 HONDA CRV
JHLRE38357C056665
2008 DODGE RAM 1500
1D7HA16N18J185454
2012 INFINITI M37
JN1BY1AP4CM334731
2010 HONDA ACCORD
1HGCP2F35AA161740
2008 JEEP GRAND CHEROKEE
1J8GS48K78C121049
Call News March 20, 27, 2024
|
The following vehicles have been abandoned and will be auctioned April 26, 2024 at 10 a.m. at 5685 Joyce Ave Eight Mile, AL 36613.
1993 Buick Roadmaster White
1G4BT5374PR406404
2001 GMC YUKON XL 1500 Orange
1GKEC16TX1J293314
2004 Hyundai SONATA Silver
KMHWF35H04A033262
2005 Toyota RAV4 Silver
JTEGD20V950059187
2006 Ford Escape Silver
1FMYU03136KB58403
2006 Ford Expedition Brown
1FMPU17506LB00774
2006 Nissan Maxima White
1N4BA41E16C821175
2008 Audi A3 White
WAUNF78P38A051364
2008 BMW 5 Series Silver
WBANU53508CT08081
2008 Chevrolet Impala Silver
2G1WT58NX89138931
2008 Ford Focus Black
1FAHP33N88W108226
2008 Lexus RX 350 Maroon
JTJGK31U589851212
2012 Hyundai ACCENT Blue
KMHCU4AE4CU087607
2012 Toyota Camry Silver
4T1BF1FK7CU131554
2014 Ford Transit Connect White
NM0LS7F75E1150513
2015 Nissan Altima
1N4AL3AP7FC197688
2015 Nissan Versa Black
3N1CN7AP3FL878541
2016 Hyundai ELANTRA White
5NPDH4AE6GH673514
2017 Jeep Compass White
1C4NJCBA8HD123866
2019 Audi A3 White
WAUAUGFF1K1011287
2022 Toyota Camry White
4T1C11AK2NU065086
2023 Chevrolet Silverado 1500 White
3GCNAAED2PG307891
Call News March 20, 27, 2024
|
The following abandoned vehicles will be auctioned April 29 at 9 a,m. at 5681 Katherine Hankins Dr Theodore, AL 36582.
2007 INFINITI FX35
JNRAS08W27X202105
2013 MAZDA 5
JM1CW2CL2D0152770
2007 TOYOTA SIENNA
5TDZK23C87S021527
2016 FORD E SIERS
1FDWE3F68KDC29638
2003 JAGUAR X TPYE
SAJEA51D53XD29648
2003 FORD ESCAPE
1FMYU03113KA69165
2003 BUICK LESABRE
1G4HP53K03U152895
2016 MAZDA 6
JM1GJ1V51G1418531
2014 TOYOTA YARIS
JTDKTUD3XED592664
2007 TOYOTA SIENNA
5TDZK23C87S02152
2005 LIN LS
1LNHM86S25Y628077
2004 JEEP CHEROKEE
1J4GX48S94C210795
2016 NISSAN VERSA
3N1CN7AP9GL835923
1999 LAND ROVER
SALPV1444XA413474
0000 UTILTY TRAILER
102215B002083
2020 BMW 330I
3MW5R1J05L8B20948
Call News March 20, 27, 2024
|
The following vehicles will be auctioned May 3rd, 2024 at 5385 Barry Dr Theodore, AL 36582 at 10:00 a.m.
2013 Ford Edge
2FMDK3JCDBC02341
2019 NISSAN SENTRA
3N1AB7APXKY264213
2015 KIA SOUL
KNDJN2A22F7804740
Call News March 20, 27, 2024
|
The following abandoned vehicle(s) will be sold at public auction on 04/26/2024 at 9:00 A.M. at 1816 Pallister PL W Mobile, AL 36618-2256
2011 Toyota Camry
VIN#4T1BF3EK4BU122810
Call News March 20, 27, 2024
|
In accordance with Section 32-13-1, Code of Alabama 1975, notice is hereby given to the owner. Lienholders, and other interested parties that the following described abandoned vehicle will be sold at public auction for cash to the highest bidder 9:00 a.m., May 14, 2024, at Mobile Police Impound, 1251 Virginia Street, Lot B, Mobile, AL 36604. Details about vehicles listed for this auction are available at www.mobilepd.org/impounds.
2003 FORD EXPLORER SPORT TRAC
1FMZU67EX3UA89195
2013 HYUNDAI ELANTRA
5NPDH4AE7DH258942
2017 NISSAN VERSA
3N1CN7AP1HL802500
2010 FORD EXPEDITION
1FMJU1H58AEB48654
2004 FORD F-150 SUPER DUTY
1FTSW31PX4EC11087
2008 HYUNDAI SANTA FE
5NMSG13D38H188095
2001 TOYOTA 4 RUNNER
JT3GN86R810212462
2014 FORD F-150
1FTFW1CT6EKD92742
1999 TOYOTA CAMRY
4T1BF28K1XU090265
2006 NISSAN MAXIMA
1N4BA41E36C846207
2005 TOYOTA AVALON
4T1BK36B55U037165
2011 NISSAN VERSA
1HGCR2F5XDA282022
1999 HONDA ACCORD
1HGCG5642XA067933
2011 NISSAN VERSA
3N1BC1AP3BL404761
2016 TOYOTA CAMRY
4T1BF1FK8GU244984
2020 HYUNDAI ELANTRA
5NPD84LF3LH568767
2013 KAWASAKI NINJA
JKAEX8A10DDA06433
2003 VOLVO S60
YV1RS61T532271961
2004 SATURN VUE
5GZCZ23D34S869665
2010 NISSAN ALTIMA
1N4AL2APXAN488368
1996 FORD CROWN VICTORIA
2FALP73W8TX170006
2015 CHEVROLET MALIBU
1G11D5SL2FF175359
2004 TOYOTA COROLLA
2T1BR32E04C297419
1991 TOYOTA CAMRY
JT2SV24E7M3436210
2013 KIA OPTIMA
5XXGM4A7XDG247438
DODGE NITRO
2006 HONDA CRV
JHLRD78986C056902
2000 TOYOTA ECHO
JTDBT1239Y0079905
2014 NISSAN ALTIMA
1N4AL3AP3EC286334
2014 HONDA ACCORD
1HGCR2F32EA240203
2013 HYUNDAI SONATA
5NPEB4AC6DH750463
2006 DODGE DAKOTA
1D7HE28K86S560003
2010 NISSAN VERSA
3N1BC1AP3BL404761
2007 HONDA ACCORD
1HGCM56347A191346
2011 DODGE JOURNEY
3D4PG3FG2BT516594
Call News March 13, 20, 2024
|
The following abandoned vehicles will be auctioned April 17, 2024 at 9 a.m. at 5681 Katherine Hankins Dr Theodore, AL 36582.
2007 INFINITI
FX35 JNRAS08W27X202105
2013 MAZDA 5
JM1CW2CL2D0152770
2007 TOYOTA SIENNA
5TDZK23C87S021527
2016 FORD E SIERS
1FDWE3F68KDC29638
2003 JAGUAR X TPYE
SAJEA51D53XD29648
2003 FORD ESCAPE
1FMYU03113KA69165
2003 BUICK LESABRE
1G4HP53K03U152895
2016 MAZDA 6
JM1GJ1V51G1418531
2014 TOYOTA YARIS
JTDKTUD3XED592664
2007 TOYOTA SIENNA
5TDZK23C87S02152
2005 LIN LS
1LNHM86S25Y628077
2004 JEEP CHEROKEE
1J4GX48S94C210795
2016 NISSAN VERSA
3N1CN7AP9GL835923
Call News March 13, 20, 2024
|
F&S Towing and Recovery 801 Schillinger’s Rd. N. Mobile, AL 36608 will auction off the following vehicles on April 3, 2024 at 9:00 a.m.
2006 Ford F-150
1FTRX12W46NA11878
2008 BMW 3 Series (White)
WBAWB33518PU89232
2011 Cadillac DTS
1G6KD5E6XBU130955
1999 Volvo S80 (White)
YV1TS97D7X1014271
2011 GMC Terrain (Gold)
2CTALUEC6B6215290
2013 Nissan Maxima
1N4AA5AP1DC821094
2004 Nissan Xterra
5N1ED28T14C625270
2000 Mercury Grand Marquis (White)
2MEFM75WXYX625313
Call News March 20, 27, 2024
|
The following vehicles, located at 1850 Shelton Beach Rd., Saraland, Ala., will be auctioned on April 24, 2024 at 9 a.m.
1992 FORD RANGER GREEN
1FTCR14X5NTA78554 482477
2013 CHEVROLET EQUINOX GRAY
2GNALDEK9D6212865 482256 LL
2009 CHRYSLER TN & CNTRY WHITE
2A8HR64X59R660078 482569 LL
2000 HONDA ODYSSEY WHITE
2HKRL1869YH600835 478309
2007 HYUNDAI TUCSON GREEN
KM8JN12D27U687959 482732 LL
2020 NISSAN ALTIMA GRAY
1N4BL4BV0LC220621 483014 LL
2014 NISSAN ALTIMA RED
1N4AL3AP5EN251122 483157 LL
2012 KIA FORTE SILVER
KNAFU4A23C5643128 483303
2003 CHEVROLET TAHOE GREEN
1GNEC13V93R243324 483307
2015 TOYOTA HIGHLANDER SILVER
5TDYKRFH0FS085202 483407 LL
2013 NISSAN ROGUE BLACK
JN8AS5MV9DW130979 483417
2020 KEYSTONE PASSPORT 28’ WHITE
4YDT2822XLD413218 481187
2007 CHEVROLET IMPALA MAROON
2G1WB58K779165265 483581
2010 HONDA ACCORD GOLD
1HGCP2F38AA043360 483717 LL
2019 PETERBILT 579 RED
1XPBDP9X2KD629968 483743
2022 HYUNDAI SANTA FE WHITE
5NMS14AJ2NH436361 483808 LL
2002 FORD EMOTOR HOME WHITE
1FDXE45S62HB74768 483918
2006 GOLF CAVALIER TR TRLR WHITE
1NL1GTR2161019238 483915
Call News March 13, 20, 2024
|
Bay City Paint & Body, Inc., 6220 Theodore Dawes Rd., Theodore, Ala. will auction off the following abandoned vehicles on April 29, 2024 @ 9:00 a.m.
2010 HYUNDAI SONATA
5NPET4ACXAH595747
1997 GMC JIMMY
1GKCS18W8VK507282
2007 GMC YUKON
1GKFC13JX7R138098
2017 HYUNDAI SONATA
5NPE24AF4HH565568
2000 MERCURY MOUNTAINEER
4M2DU66P2YUJ35413
Call News March 20 & 27, 2024